Qualifying Work Sample Clauses

Qualifying Work. The only work that qualifies for Work Units are new 2-D and 3-D seismic surveys and Exploration Xxxxx carried out during the Exploration Period in the Area. Work shall include any seismic surveys for the purpose of locating Exploration Well and Exploration Xxxxx drilled in Development Areas during the Exploration Period. Any work carried out as an Appraisal Program or as part of the development of a Commercial Discovery shall not qualify for Work Units.
Sample 1
AutoNDA by SimpleDocs
Qualifying Work. Subject to the terms of this Agreement, the Lessee can claim for reimbursement (Lessor’s “Maintenance Contribution” obligations) in respect of the following work and net costs thereof (“Qualifying Work”):
Sample 1
Qualifying Work. In order to qualify for holiday pay, all employees shall work their last regularly scheduled work day before the holiday and their first regularly scheduled work day after the holiday unless excused. However, an employee calling in "sick" on their scheduled work day before or after a holiday, regardless if approved, shall render them ineligible for "holiday pay" pursuant to Section 10.3 below, unless they produce verification of illness.
Sample 1

Related to Qualifying Work

  • Qualifying Terminations Any of the following events resulting in a cessation of the Employee’s employment by the Company during the Covered Employment Term shall constitute a “Qualifying Termination”: (i) discharge by the Company without Cause (as hereinafter defined); or (ii) the Employee’s resignation with Good Reason.

  • Qualifying Termination If the Executive is subject to a Qualifying Termination, then, subject to Sections 4, 9, and 10 below, Executive will be entitled to the following benefits:

  • Base Building Work Landlord shall construct the Base Building Work as further set forth on Exhibit 10.03, attached.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.

  • Vesting Commencement Date Exercise Price per Share: Total Number of Shares Subject to the Option: Total Exercise Price: Expiration Date: Type of Option: Nonstatutory Stock Option

  • Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • Termination After a Change in Control You will receive Severance Benefits under this Agreement if, during the Term of this Agreement and after a Change in Control has occurred, your employment is terminated by the Company without Cause (other than on account of your Disability or death) or you resign for Good Reason.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!