Access Rights Upon reasonable notice and supervision by the Granting Party, and subject to any required or necessary regulatory approvals, either the Connecting Transmission Owner or Developer (“Granting Party”) shall furnish to the other of those two Parties (“Access Party”) at no cost any rights of use, licenses, rights of way and easements with respect to lands owned or controlled by the Granting Party, its agents (if allowed under the applicable agency agreement), or any Affiliate, that are necessary to enable the Access Party to obtain ingress and egress at the Point of Interconnection to construct, operate, maintain, repair, test (or witness testing), inspect, replace or remove facilities and equipment to: (i) interconnect the Large Generating Facility with the New York State Transmission System; (ii) operate and maintain the Large Generating Facility, the Attachment Facilities and the New York State Transmission System; and (iii) disconnect or remove the Access Party’s facilities and equipment upon termination of this Agreement. In exercising such licenses, rights of way and easements, the Access Party shall not unreasonably disrupt or interfere with normal operation of the Granting Party’s business and shall adhere to the safety rules and procedures established in advance, as may be changed from time to time, by the Granting Party and provided to the Access Party. The Access Party shall indemnify the Granting Party against all claims of injury or damage from third parties resulting from the exercise of the access rights provided for herein.
Lenders Rights and Remedies (a) Upon the occurrence and continuation of an Event of Default (as defined in the Note), the Lender may exercise in respect of the Collateral, in addition to any and all other rights and remedies provided for herein or otherwise available to it under applicable law, all the rights and remedies of a secured party on default under applicable law, including, but not limited to, the UCC in effect at the time, and the Lender may also, without notice except as specified below, sell the Collateral or any part thereof in one or more parcels at public or private sale, at any exchange, broker’s board or at Lender’s principal office or elsewhere, for cash, on credit or for future delivery, and at such price or prices and upon such other terms as the Lender may deem commercially reasonable. The Lender may require the Company to assemble the Collateral and deliver it to a place designated by the Lender. The Lender may proceed to sell or otherwise dispose of the Collateral at public or private sale for cash or credit; provided, however, that the Company shall be credited with proceeds of such sale only when the proceeds are actually received by the Lender. The Company agrees that, to the extent notice of sale shall be required by law, at least 10 days’ notice to the Company at the time and place of any public sale or the time after which any private sale is to be made shall constitute reasonable notification. The Lender shall not be obligated to make any sale of Collateral regardless of any notice of sale having been given. The Lender may adjourn any public or private sale from time to time by announcement at the time and place fixed therefor and such sale, without further notice, may be made at the time and place to which it was so adjourned. (b) Any cash held by the Lender as Collateral and all cash proceeds by Lender in respect of any sale of, collection from, other realization upon all or any part of the Collateral may, in the sole and arbitrary discretion of the Lender, shall be held by the Lender as Collateral for, and/or then or at any time thereafter applied in whole or in part by the Lender against, all or any part of the expenses and costs to exercise by the Lender of its rights hereunder, and to the Obligations then remaining unpaid as the Lender shall elect. Any surplus of such cash or cash proceeds held by the Lender and remaining after payment in full of the Obligations shall be paid over to the Company or to whomsoever may be lawfully entitled to receive such surplus. (c) All provisions contained herein pertaining to Lender’s remedies shall be and are severable and cumulative.
No Waiver, Rights and Remedies No failure on the part of the Administrative Agent or any Secured Party or any assignee of any Secured Party to exercise, and no delay in exercising, any right or remedy hereunder shall operate as a waiver thereof; nor shall any single or partial exercise of any right or remedy hereunder preclude any other or further exercise thereof or the exercise of any other right. The rights and remedies herein provided are cumulative and not exclusive of any rights and remedies provided by law.
LANDLORD'S RIGHT OF ACCESS Landlord and its contractors and representatives shall have the right to enter the Premises at all reasonable times to perform janitorial and cleaning services and, after verbal notice (except in the case of emergencies), to inspect the same, to make repairs, alterations and improvements, to maintain the Premises and the Building, specifically including, but without limiting the generality of the foregoing, to make repairs, additions or alterations within the Premises to mechanical, electrical and other facilities serving other premises in the Building, to post such reasonable notices as Landlord may desire to protect its rights, to exhibit the Premises to mortgagees and purchasers, and, during the one hundred eighty (180) days prior to the expiration of the Term, to exhibit the Premises to prospective tenants. In the event the Premises is vacant, Landlord may place upon the doors or in the windows of the Premises any usual or ordinary “To Let,” “To Lease,” or “For Rent” signs. Tenant shall permit Landlord to erect, use, maintain and repair pipes, cables, conduit, plumbing, vents and wires, in, to and through the Premises to the extent Landlord may now or hereafter deem necessary or appropriate for the proper operation, maintenance and repair of the Building and any portion of the Premises. In exercising its rights under this Article 16, Landlord will use reasonable efforts to minimize any interference with Tenant’s use or occupancy of the Premises, provided that Landlord will not be obligated to provide overtime labor or perform work after regular Building hours.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Default Rights and Remedies If an Event of Default exists, the Agent shall have the following rights and remedies: (a) In addition to all other rights and remedies granted to the Agent in this Agreement or in any other Loan Document or by applicable law, the Agent shall have all of the rights and remedies of a secured party under the UCC (whether or not the UCC applies to the affected Collateral). Without limiting the generality of the foregoing, the Agent may (A) without demand or notice to it, collect, receive or take possession of the Collateral or any part thereof and for that purpose the Agent may enter upon any premises on which the Collateral is located and remove the Collateral therefrom or render it inoperable, and/or (B) sell, lease or otherwise dispose of the Collateral, or any part thereof, in one or more parcels at public or private sale or sales, at the Agent's offices or elsewhere, for cash, on credit or for future delivery, and upon such other terms as the Agent may deem commercially reasonable or otherwise as may be permitted by law. The Agent shall have the right at any public sale or sales, and, to the extent permitted by applicable law, at any private sale or sales, to bid (which bid may be, in whole or in part, in the form of cancellation of indebtedness) and become a purchaser of the Collateral or any part thereof free of any right or equity of redemption on the part of the Debtor, which right or equity of redemption is hereby expressly waived and released by the Debtor. Upon the request of the Agent, the Debtor shall assemble the Collateral and make it available to the Agent at anyplace designated by the Agent that is reasonably convenient to it and the Agent. The Debtor agrees that the Agent shall not be obligated to give more than ten (10) days prior written notice of the time and place of any public sale or of the time after which any private sale may take place and that such notice shall constitute reasonable notice of such matters. The Agent shall not be obligated to make any sale of Collateral if it shall determine not to do so, regardless of the fact that notice of sale of Collateral may have been given. The Agent may, without notice or publication, adjourn any public or private sale or cause the same to be adjourned from time to time by announcement at the time and place fixed for sale, and such sale may, without further notice, be made at the time and place to which the same was so adjourned. The Debtor shall be liable for all reasonable expenses of retaking, holding, preparing for sale or the like, and all reasonable attorneys' fees, legal expenses and other costs and expenses incurred by the Agent in connection with the collection of the Obligations and the enforcement of the Agent's rights under this Agreement. The Debtor shall remain liable for any deficiency if the Proceeds of any sale or other disposition of the Collateral applied to the Obligations are insufficient to pay the Obligations in full to the extent provided in the Loan Documents. The Agent may apply the Collateral against the Obligations as provided in the Credit Agreement. The Debtor waives all rights of marshalling, valuation and appraisal in respect of the Collateral. Any cash held by the Agent as Collateral and all cash proceeds received by the Agent in respect of any sale of, collection from or other realization upon all or any part of the Collateral may, in the discretion of the Agent, be held by the Agent as collateral for, and then or at any time thereafter applied in whole or in part by the Agent against, the Obligations in the order permitted by the Credit Agreement. Any surplus of such cash or cash proceeds and interest accrued thereon, if any, held by the Agent and remaining after payment in full of all the Obligations shall be promptly paid over to the Debtor or to whomsoever may be lawfully entitled to receive such surplus; provided that the Agent shall have no obligation to invest or otherwise pay interest on any amounts held by it in connection with or pursuant to this Agreement. (b) The Agent may cause any or all of the Collateral held by it to be transferred into the name of the Agent or the name or names of the Agent's nominee or nominees. (c) The Agent may exercise any and all of the rights and remedies of the Debtor under or in respect of the Collateral, including, without limitation, any and all rights of it to demand or otherwise require payment of any amount under, or performance of any provision of, any of the Collateral. (d) The Agent may collect or receive all money or property at any time payable or receivable on account of or in exchange for any of the Collateral, but shall be under no obligation to do so. (e) On any sale of the Collateral, the Agent is hereby authorized to comply with any limitation or restriction with which compliance is necessary, in the view of the Agent's counsel, in order to avoid any violation of applicable law or in order to obtain any required approval of the purchaser or purchasers by any applicable Governmental Authority.
Waivers, Rights and Remedies Except as expressly provided in this Agreement, no failure or delay by any Party in exercising any right or remedy relating to this Agreement shall affect or operate as a waiver or variation of that right or remedy or preclude its exercise at any subsequent time. No single or partial exercise of any such right or remedy shall preclude any further exercise of it or the exercise of any other remedy.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
No Waiver of Rights, Powers and Remedies No failure or delay by a party hereto in exercising any right, power or remedy under this Agreement, and no course of dealing between the parties hereto, shall operate as a waiver of any such right, power or remedy of such party. No single or partial exercise of any right, power or remedy under this Agreement by a party hereto, nor any abandonment or discontinuance of steps to enforce any such right, power or remedy, shall preclude such party from any other or further exercise thereof or the exercise of any other right, power or remedy hereunder. The election of any remedy by a party hereto shall not constitute a waiver of the right of such party to pursue other available remedies. No notice to or demand on a party not expressly required under this Agreement shall entitle the party receiving such notice or demand to any other or further notice or demand in similar or other circumstances or constitute a waiver of the rights of the party giving such notice or demand to any other or further action in any circumstances without such notice or demand.
Right of Access 2.3.1 Upon reasonable notice, the NYISO and/or Connecting Transmission Owner may send a qualified person to the premises of the Interconnection Customer at or immediately before the time the Small Generating Facility first produces energy to inspect the interconnection, and observe the commissioning of the Small Generating Facility (including any required testing), startup, and operation for a period of up to three Business Days after initial start-up of the unit. In addition, the Interconnection Customer shall notify the NYISO and Connecting Transmission Owner at least five Business Days prior to conducting any on-site verification testing of the Small Generating Facility. 2.3.2 Following the initial inspection process described above, at reasonable hours, and upon reasonable notice, or at any time without notice in the event of an emergency or hazardous condition, the NYISO and Connecting Transmission Owner each shall have access to the Interconnection Customer’s premises for any reasonable purpose in connection with the performance of the obligations imposed on them by this Agreement or if necessary to meet their legal obligation to provide service to their customers. 2.3.3 Each Party shall be responsible for its own costs associated with following this article.