Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.
Application for Payment The form acceptable to Owner that is to be used by the Contractor during the course of the Work in requesting payment from the Owner and that is to be accompanied by such supporting documentation as is required by the Contract Documents.
Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.
Payment Authorization and Payment Remittance By providing the Service with names and account information of Billers to whom you wish to direct payments, you authorize the Service to follow the Payment Instructions that it receives through the Site. In order to process payments more efficiently and effectively, the Service may edit or alter payment data or data formats in accordance with Xxxxxx directives. When the Service receives a Payment Instruction, you authorize the Service to debit your Eligible Transaction Account and remit funds on your behalf so that the funds arrive as close as reasonably possible to the Scheduled Payment Date designated by you. You also authorize the Service to credit your Eligible Transaction Account for payments returned to the Service by the United States Postal Service or Xxxxxx, or payments remitted to you on behalf of another authorized user of the Service. The Service will attempt to make all your payments properly. However, the Service shall incur no liability and any Service Guarantee (as described in Section 3 of the Bill Payment Terms) shall be void if the Service is unable to complete any payments initiated by you because of the existence of any one or more of the following circumstances:
Certification Regarding Entire TIPS Agreement for Part 1 and Part 2 Contracts 5 This is a two part solicitation. Part 1 is solicited for TIPS sales that are not considered a "public work" construction project. Part 1 permits the sale of goods and non-construction/non-"public work" services such as maintenance and minor repairs. Part 2 Job Order Contract (JOC) is solicited for projects considered by your TIPS Member Customers to be a "public work" construction project. The determination of whether or not a TIPS sale amounts to a "public work" construction project requiring a Part 2 JOC contract is made by the TIPS Member Customer at the time of each TIPS sale. Thus, Vendors are encouraged to respond to both Parts 1 and 2 in case your TIPS Member Customers require that a sale be made under one Part or the other. However, responding to both Parts is not required. If Vendor responds and is awarded to both Parts, Vendor will have one contract for Part 1 and a separate contract for Part 2.
Notice to Proceed (NTP Following the JOA and purchase order issuance, the County will issue a Notice to Proceed (NTP) that will provide the construction start date, the Work duration period, and the Substantial Completion date. The Contractor agrees to begin and complete construction within the dates specified on the NTP. The County must approve all extensions of time in writing. The County may also issue an Emergency Notice to Proceed (NTP). In the event the County requires the Contractor to respond to an immediate request for work, a Job Order will be created and an Emergency NTP will be issued. The Contractor will be required to perform the Scope of Work included with the Emergency NTP as directed by the County’s Project Manager or designee. The Detailed Scope of Work, Quotation, Subcontractor Listing, Shop Drawings and required Non Pre-priced backup documentation will be submitted upon completion of the emergency work in accordance with the Ordering Procedures detailed in Section III above.
Final Certificate, Design Professional’s Certificate of Final Completion The Certificate issued by the Design Professional stating that all work has been completed in accordance with the terms of the Contract Documents. See Section 6,
Disclosure Statement for Xxxx IRAs 1. Am I Eligible to Contribute to a Xxxx XXX? Anyone with compensation income whose Modified Adjusted Gross Income (AGI) does not exceed the limits described below is eligible to contribute to a Xxxx XXX. (For convenience, all future references to compensation are deemed to mean “earned income” in the case of a self- employed individual.) Employers may also contribute to Xxxx IRAs established for the benefit of their employees. You may also establish a Xxxx XXX to receive rollover contributions or transfers from another Xxxx XXX or, in some cases, from a Traditional IRA. A Qualified Rollover Contribution can be made to a Xxxx XXX and is a distribution from an IRA that meets the requirements of section 408(d)(3), a rollover from a designated Xxxx account described in section 402A, or a rollover from an eligible retirement plan as described in section 402(c)(8)(B).
Doctor's Certificate of Inability to Work The Employer may require an employee who is unable to work because of illness or injury to provide a statement from:
Your Billing Rights: Keep This Document For Future Use This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
