Responsibility for Damage and Tort Claims Sample Clauses

Responsibility for Damage and Tort Claims. The Project Sponsor and the Project Sponsor's surety shall indemnify and save harmless the State, its officers and employees, from all suits, actions or claims of any character brought because of any injuries or damages received or sustained by any person, persons or property on account of the operations of the Project Sponsor; or on account of or in consequence of any neglect in safeguarding the work; or because of any act or omission, neglect or misconduct of the Project Sponsor; or because of any claims or amounts recovered for any infringement by the Project Sponsor of patent, trademark or copyright; or from any claims or amounts arising or recovered under the Worker's Compensation Act, relating to the Project Sponsor's employees; or any other law, ordinance, order or decree relating to the Project Sponsor's operations. So much of the money due the Project Sponsor under and by virtue of the contract as shall be considered necessary by the State for such purposes, may be retained for the use of the State; or, in case no money or insufficient money is retained, the Project Sponsor's surety may be held until such suit or suits, action or actions, claim or claims for injuries or damages as aforesaid shall have been settled and suitable evidence to that effect furnished to the State; except that money due the Project Sponsor will not be withheld when the Project Sponsor produces satisfactory evidence that the Project Sponsor is adequately protected by public liability and property damage insurance. The Project Sponsor also shall comply with all of the above requirements indemnifying and saving harmless the county, town, or municipality in which the improvement is made and each of them separately or jointly and officers and employees. The State shall not be liable to the Project Sponsor for damages or delays resulting from work by third parties. The State also shall be exempt from liability to the Project Sponsor for damages or delays resulting from injunctions or other restraining orders obtained by third parties except where the damage or delay is a direct result of an injunction or restraining order obtained by a citizen's action alleging violations of 42 U.S.C. 4331 - 4332, 23 U.S.C. 138 or Public Law 91-646. It shall be the Project Sponsor's responsibility to see that all of the contract operations incident to the completion of the contract are covered by public liability and property damage liability insurance so the general public or any representativ...
AutoNDA by SimpleDocs

Related to Responsibility for Damage and Tort Claims

  • Responsibility for Damage Resident is solely responsible for any damage, defacement or loss within the assigned bedroom space. All assigned residents of an apartment are jointly and severally responsible for any damage, defacement or loss to common areas, other parts of the facility, fixtures or appliances, except for the portion of damages over $100,000 where it is finally established that Resident or one or more other residents of the apartment were solely at fault for the entire loss, in which case such person(s) will be solely responsible. Resident is fully responsible for the conduct of Resident’s guests, visitors, licensees and invitees (“Guests”), including without limitation harm to individuals or damage or defacement of any part of the Property or its fixtures or property of third parties (including other residents) by such Guests.

  • Responsibility for Damages Contractor is responsible for all damage that occurs as a result of Contractor’s fault or negligence or that of its’ employees, agents, or representatives in connection with the performance of this Contract. Contractor shall immediately report any such damage to people and/or property to the Contract Administrator.

  • Liability for Damage Each party shall be liable to the other for all damage to the property of the other negligently, recklessly or intentionally caused by that party (or their agents, employees or invitees), except to the extent the loss is insured and subrogation is waived under the owner's policy.

  • Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.

  • NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED BY TIPS/ESC REGION 8. Per Texas Education Code §44.032(f), reasonable Attorney’s fees are recoverable by the prevailing party in any dispute resulting in litigation. State of Texas Franchise Tax By signature hereon, the bidder hereby certifies that he/she is not currently delinquent in the payment of any franchise taxes owed the State of Texas under Chapter 171, Tax Code.

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages.

  • Indemnification by Customer Customer shall indemnify, defend and hold harmless MSIL and its affiliates from and against any loss, liability, damage, cost or expense (including attorneys' and accountants' fees and expenses incurred in the defense of any demands, claims or lawsuits) actually and reasonably incurred arising from any act, omission, conduct, or activity undertaken by MSIL on behalf of Customer, including, without limitation, any demands, claims or lawsuits initiated by a limited partner (or assignee thereof); provided that (i) MSIL has determined, in good faith, that the act, omission, conduct, or activity giving rise to the claim for indemnification was in the best interests of the Customer, and (ii) the act, omission, conduct or activity that was the basis for such loss, liability, damage, cost or expense was not the result of misconduct or negligence. Notwithstanding the foregoing, no indemnification of MSIL or its affiliates by Customer shall be permitted for any losses, liabilities or expenses arising from or out of any alleged violation of federal or state securities laws unless (i) there has been a successful adjudication on the merits of each count involving alleged securities law violations as to the particular indemnitee, or (ii) such claims have been dismissed with prejudice on the merits by a court of competent jurisdiction as to the particular indemnitee, or (iii) a court of competent jurisdiction approves a settlement of the claims against the particular indemnitee and finds that indemnification of the settlement and related costs should be made, provided with regard to such court approval, the indemnitee must apprise the court of the position of the SEC and the positions of the respective securities administrators of Massachusetts, Missouri, Tennessee and/or those other states and jurisdictions in which the plaintiffs claim that they were offered or sold Units, with respect to indemnification for securities laws violations before seeking court approval for indemnification. Furthermore, in any action or proceeding brought by a limited partner in the right of Customer to which MSIL or any affiliate thereof is a party defendant, any such person shall be indemnified only to the extent and subject to the conditions specified in the Delaware Revised Uniform Limited Partnership Act, as amended, and this Section 2. The Customer shall make advances to MSIL or its affiliates hereunder only if: (i) the demand, claim lawsuit or legal action relates to the performance of duties or services by such persons to Customer; (ii) such demand, claim lawsuit or legal action is not initiated by a limited partner; and (iii) such advances are repaid, with interest at the legal rate under Delaware law, if the person receiving such advance is ultimately found not to be entitled to indemnification hereunder.

  • Responsibility for Content Vendor is solely responsible for administration, content, intellectual property rights, and all materials at Vendor’s website. DIR reserves the right to require a change of listed content if, in the opinion of DIR, it does not adequately represent the Contract.

Time is Money Join Law Insider Premium to draft better contracts faster.