Restricted Changes Sample Clauses

Restricted Changes. Except as provided in this Article, Tenant shall not have any right to make any changes in the Demised Premises without the prior consent of Landlord.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Restricted Changes. Should Tenant desire to make changes to any approved plans which, in the judgment of Landlord, are so substantial as to cause postponement of the Commencement Date reasonably anticipated by Landlord, then, without prejudice to the provisions of Article 3(b) hereof, Landlord shall have the right to refuse to permit the making of such changes unless and until Tenant shall have committed in writing, in a manner reasonably satisfactory to Landlord, to pay to Landlord on the date rent would have commenced hereunder in the absence of such delay, a sum of money equivalent to the rent for the Building for the period during which Tenant would have been obligated to pay rent to Landlord had not the Commencement Date been so delayed. Furthermore, no change requested by Tenant, whether or not substantial, shall be effective unless and until (in addition to any other conditions thereto as herein specified) Landlord and Tenant shall agree in writing upon the basis for any additional cost or credit to Tenant on account thereof.
Sample 1
Restricted Changes. The Borrower shall not change, or allow any change to, any of the following without the Intercreditor Agent's prior written consent (acting reasonably): its financial year end; its constitutional documents (other than in respect of minor administrative matters or as required under Applicable Law); [the Shareholders Agreement]; the rights attaching to its shares; or its Auditor (by way of replacement, dismissal or otherwise), except this paragraph (e) shall not apply to the extent that such restriction on changing its Auditor is prohibited by Applicable Law.
Sample 1
Restricted Changes. Any changes (i) to the location of the elevator shafts in the New Building, (ii) that would require the removal of the piles that have already been installed at the Development Site, and (iii) any changes of the nature of the New Building from a first class general officer, research and development, and laboratory space building. Security Agreement: See definition in Section 12.10.
Sample 1
Restricted Changes. In relation to any change to the Services or the D&EI Systems which the Service Provider does not consider to be a Change:
Sample 1
Restricted Changes. Should Tenant desire to make changes to any approved plans which are so substantial as to cause postponement of the commencement date, without prejudice to the provisions of Article 3(b) hereof, Landlord shall have the right to refuse to permit the making of such changes unless and until Tenant shall have committed in writing, in a manner reasonably satisfactory to Landlord, to pay Landlord on the date rent would have commenced in the absence of such delay, a sum of money equivalent to the rent for the Premises for the period during which Tenant would have been obligated to pay rent to Landlord had the commencement date not been so delayed. Furthermore, no change requested by Tenant, whether or not substantial, shall be effective unless and until (in addition to any other conditions as herein specified) Landlord and Tenant agree in writing as to the additional cost to Tenant on account thereof.
Sample 1

Related to Restricted Changes

  • Business Changes Change in any material respect the nature of the business of the Borrower or its Subsidiaries as conducted on the Effective Date.

  • Interim Changes Since the date of its balance sheets, except as set forth in Exhibit C, there have been no (1) changes in financial condition, assets, liabilities or business of Amalgamated which, in the aggregate, have been materially adverse; (2) damages, destruction or losses of or to property of Amalgamated, payments of any dividend or other distribution in respect of any class of stock of Amalgamated, or any direct or indirect redemption, purchase or other acquisition of any class of any such stock; or (3) increases paid or agreed to in the compensation, retirement benefits or other commitments to its employees.

  • Insignificant Changes No adjustment in the Purchase Price shall be required unless such adjustment would require an increase or decrease of at least 1% in the Purchase Price. Any adjustments which by reason of this Section 11.5 are not required to be made shall be carried forward and taken into account in any subsequent adjustment. All calculations under this Section 11 shall be made to the nearest cent or to the nearest one-hundred thousandth of a Preferred Share or the nearest one-hundredth of a Common Share or other share or security, as the case may be.

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • Room Changes No changes in room assignment will be based upon age, race, religion, national origin, disability, sexual orientation, and online profiles except as needed to provide a reasonable accommodation to residents with eligible disabilities registered with the College Office of Counseling and Disability Services. Room change may only be made with the written approval of College Housing and is dependent upon space availability, timing of the request, and grounds for transfer. Residents who receive approval for a room change may be charged a room change fee as shown on the College Housing website, which will be posted to Resident’s account. Room changes that are not authorized by College Housing will result in a fine as shown on the College Housing website, which will be posted to Resident’s account.

  • Service Changes PBI may modify its Service by giving written notice to you (a “Service Change Notice”), which will state whether the change is material. After receiving a Service Change Notice, if the change is material, you may terminate Service by giving us a termination notice at the address indicated in Section 21 or you may create a case at xxxxxxxxxxx.xxx/xx/xxxxxxx-xx.xxxx (follow the instructions under “how to create a case”).

  • Certain Accounting Changes Change its Fiscal Year end, or make any change in its accounting treatment and reporting practices except as required by GAAP.

  • Staffing Changes The Director’s prior written approval is required for the Consultant to remove, replace or add to any of its staffing identified in Attachment B of an Approved Service Order.

  • Project Changes 1.8.1. All changes shall be administered per the UGC. 1.8.2. Upon authorization by the Owner, the Owner or Architect/Engineer will prepare and issue all changes to the Contract affecting cost, scope and/or time as a formal Change Order to the Contract on the standard University of Texas MD Xxxxxxxx Cancer Center Change Order form. The Change Order may include separate change issues, identified as Change Proposals and field orders. 1.8.3. Upon authorization by the Owner, Change Proposals may be issued to the Architect/Engineer for pricing by the Contractor. Contractor shall submit pricing to the Owner within twenty-one (21) days and pricing shall be indicated on the standard Owner "Change in Work Cost Analysis" ("Cost Analysis") form provided in the Pre-Construction Conference Brochure. Contractor may not include a Change Proposal within a Change Order unless the Owner has accepted the Change Proposal. 1.8.3.1. The Contractor shall summarize all costs for each change at each level of subcontractor and supplier by preparing the "Cost Analysis" form, and shall provide each subcontractor's cost summary on separate "Cost Analysis" forms as backup. Additional support documentation from both the Contractor and Contractor’s subcontractors is encouraged, but such will not replace use of the standard form. 1.8.3.2. When the Contractor believes it is entitled to a time extension, Contractor shall so state as part of Contractor’s response to the Change Proposal, including a justifica- tion for a time extension. Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date". 1.8.3.3. If the Owner’s Project Manager and Contractor cannot mutually agree upon a fair and reasonable cost and time settlement, the Owner’s Project Manager may: 1) Reject the quotation and void the Change Proposal, 2) Issue instructions to the Contractor to proceed on a time and material basis for a price to be determined later not to exceed a fixed maximum dollar and time, or 3) Issue a Unilateral Change Order. 1.8.3.4. The Owner’s Construction Inspector and/or Owner’s Project Manager may issue field orders directly to the Contractor for minor changes to the Contract, which can be negotiated in the field. Pricing backup is at the discretion of the Owner’s Construction Inspector, but pricing backup is required for any field order, the pricing backup is to be outlined on the "Cost Analysis" form. When the Owner and Contractor have signed the field order, the Work is authorized and the field order may be included in the next Change Order. 1.8.4. Request for payment for Change Order work may be submitted only after the Change Order has been fully executed.

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!