COUNTY’S QUALITY ASSURANCE PLAN The County or its agent will evaluate the Contractor’s performance under this Contract on not less than an annual basis. Such evaluation will include assessing the Contractor’s compliance with all Contract terms and conditions and performance standards. Contractor deficiencies which the County determines are severe or continuing and that may place performance of the Contract in jeopardy if not corrected will be reported to the Board of Supervisors. The report will include improvement/corrective action measures taken by the County and the Contractor. If improvement does not occur consistent with the corrective action measures, the County may terminate this Contract or impose other penalties as specified in this Contract.
Construction Phase Services 3.1.1 – Basic Construction Services
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
Environmental, Health and Safety Matters (a) Comply in all material respects with all applicable Environmental Laws, including, without limitation, obtaining and complying with and maintaining any and all licenses, approvals, notifications, registrations or permits required by applicable Environmental Laws. For purposes of this Section 5.12(a), material noncompliance by the Company, any of its Subsidiaries or any tenant or subtenant, with any applicable Environmental Law shall be deemed not to constitute a breach of this covenant provided that, upon learning of any actual or suspected material noncompliance, the Company and the relevant Subsidiaries shall promptly undertake all reasonable efforts to achieve material compliance (or contest in good faith by appropriate proceedings the alleged violation or applicable Environmental Law at issue and (to the extent required by GAAP) provide on the books of the Company or any of its Subsidiaries, as the case may be, reserves in accordance with GAAP with respect thereto), and provided further that, in any case, such noncompliance, and any other noncompliance with applicable Environmental Law, individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect. (b) Promptly comply in all material respects with all lawful orders and directives of all Governmental Authorities regarding applicable Environmental Laws, except to the extent that the validity thereof is currently being contested in good faith by appropriate proceedings and (to the extent required by GAAP) reserves in accordance with GAAP with respect thereto have been provided on the books of the Company or any of its Subsidiaries, as the case may be. (c) Defend, indemnify and hold harmless the Administrative Agent and the Lenders, and their respective parents, subsidiaries, affiliates, employees, agents, officers and directors, from and against any claims, demands, penalties, fines, liabilities, settlements, damages, costs and expenses of whatever kind or nature, known or unknown, contingent or otherwise, arising out of, or in any way relating to the violation of, noncompliance with or liability under any Environmental Laws applicable to the Company or any of its Subsidiaries or any of their respective operations or properties, or any orders, requirements or demands of Governmental Authorities related thereto, including, without limitation, attorney’s and consultant’s fees, investigation and laboratory fees, response costs, court costs and litigation expenses, except to the extent that any of the foregoing arise out of the gross negligence or willful misconduct of (or, as determined pursuant to a claim initiated by the Company, breach in bad faith of its express obligations under the applicable Loan Documents by) the party seeking indemnification therefor, in each case, as determined by a final non-appealable judgment by a court of competent jurisdiction. This indemnity shall continue in full force and effect regardless of the termination of this Agreement.
Quality Assurance/Quality Control Contractor shall establish and maintain a quality assurance/quality control program which shall include procedures for continuous control of all construction and comprehensive inspection and testing of all items of Work, including any Work performed by Subcontractors, so as to ensure complete conformance to the Contract with respect to materials, workmanship, construction, finish, functional performance, and identification. The program established by Contractor shall comply with any quality assurance/quality control requirements incorporated in the Contract.
Safety Boots Each employee, after 3 months’ continuous service, will be reimbursed (on production of a receipt), the cost of one pair of safety boots (approved by the employer), in each year, to a maximum of $110.00. All protective clothing such as wet weather jackets, safety helmets, welding jackets, welding xxxxxxx, welding gauntlets, rubber boots, etc, (which remain the property of the Company), will be supplied on all occasions deemed necessary.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Health and Safety Plan Consultant shall prepare and submit a Health and Safety Plan (“HASP”) for the portion of Consultant’s work that will involve field work, assessments, or investigations of certain Project elements. The HASP shall describe how Consultant plans to complete field work, assessments, and/or investigations at the RWF. Consultant’s HASP must comply with the CIP HASP and shall be updated as new conditions are encountered.
Health and Safety Representatives The Employer and its Employees will comply with Part 7 of the OHS Act – Representation of Employees in relation to the establishment of designated work groups and the election of Health and Safety Representatives.
Workplace Safety The parties to this Agreement commit themselves to achieving the highest possible standards of occupational health and safety including adherence to the consultative and issue resolution processes included herein. Participation in and support for building and construction industry initiatives to improve construction industry standards in occupational health and safety will form an important part of this commitment. Observance of relevant Acts, Regulations, and Codes of Practice are the minimum level acceptable to enable employers and employees to meet their responsibilities and to work safely and follow health and safety rules in their workplace. On all sites there will be developed a site safety plan and job specific ‘job safety analysis’ to identify and manage the risks associated with work on each particular site. Such safety plan will include suitable procedures for personnel/material access, and site evacuation procedures. The Incolink Safety Handbook ‘SAFE’ (as amended) is endorsed by this Agreement as a proper guide and reference source for safety management and control of risks. 1) The parties agree that the WorkSafe Australia Guidance Notes on Material Safety Data Sheets shall be observed at all times. 2) Hearing tests: Audiometric tests should be conducted within two months of a person commencing employment, and thereafter at intervals of two years.
