Common use of Schematic Design Phase Services Clause in Contracts

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary written evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner Owner, in writing of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approvalapprovalreview, a preliminary design illustrating the scale and relationship of the Project components. The Owner’s review of the Architect’s documents shall not be for the purpose of determining accuracy, adequacy or completeness. § 3.2.5 Based on onAfter the Owner’s approval review of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approvalapprovalreview. The Owner’s review of the Architect’s documents shall not be for the purpose of determining accuracy, adequacy or completeness. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approvalapprovalreview.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s servicesservices and prepare designs and documents accordingly. As part of this review, the Architect shall attend a series of meetings with the Owner’s project team and the Architect’s consultants. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project.in § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with , including the Owner regarding the requirements feasibility of the Project.incorporating § 3.2.4 Based on the Project requirements agreed upon with the OwnerProject’s requirements, the Architect shall prepare and present, present for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design prepar Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.dr § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work. Architect shall provide for the Owner’s approval a written itemized estimate of the Cost of the Work prepared based upon the Schematic Design package produced by the Architect and at a level of detail satisfactory to the Owner, estimates of Cost of the Work, including the cost of each category of work involved, with costs projected to the scheduled date of completion of the Bidding and Negotiation Phase of Services. If that estimate does not conform to the initial Owner-provided Stated Limitation on Cost of the Work (SLCW), as set forth in accordance with Exhibit A Section 6.3A.1.3 herein, and any Owner- approved amendments thereto, the Architect shall provide a written statement to the Owner describing the specific reasons for the deviation and suggesting alternative designs or changes that can be made to the design in order to bring the Cost of the Work within the then-current SLCW. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approvalapproval in writing.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.the § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect 3.9.1 Consultant shall prepare a preliminary evaluation of the OwnerCity’s program, schedule, budget for the Estimated Cost of the Work, Project site, site and the proposed procurement and or delivery method, method and other Initial Informationinitial information, each in terms of the other, to ascertain the requirements of the Project. The Architect Consultant shall notify the Owner City of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that which reasonably may be reasonably needed for the Project. § 3.2.3 The Architect 3.9.2 Consultant shall present its preliminary evaluation to the Owner City and shall discuss with the Owner present to City alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect Consultant shall consider environmentally responsible and sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the OwnerCity’s program, schedule and budget for the Cost budget. Consultant shall meet City’s requirements of the Work. The Owner may obtain more advanced sustainable design services Project, as a Supplemental Service under Section 4.1.1set out in this Agreement. § 3.2.5.2 The Architect 3.9.3 Consultant shall consider the value of alternative materials, building systems system and equipment, together with other considerations considerations, based on program and aesthetics, in developing a design for the Project that which is consistent with the OwnerCity’s program, schedule, schedule and budget for the Estimated Cost of the Work. § 3.2.6 The Architect 3.9.4 Based on the Project’s requirements, Consultant shall submit to prepare and present, for City’s approval, a preliminary design illustrating the Owner an estimate scale and relationship of the Cost Project components. 3.9.5 Based on City’s approval of the Work prepared preliminary design, Consultant shall prepare Schematic Design Documents for City’s approval. Schematic Design Documents means the drawings and other documents, including a site plan, which shall incorporate the site survey issued by City, preliminary building floor plans, preliminary sections and elevations for all sides of the building, systems evaluations for structural and Mechanical, Electrical and Plumbing (hereafter referred to as “MEP”) solutions. The Schematic Design Documents may include some combination of study models, perspective sketches or digital modeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in accordance with Section 6.3writing. § 3.2.7 The Architect 3.9.6 Consultant shall submit the Schematic Design Documents to the OwnerHistorical Design Review Commission (hereafter referred to as “HDRC”) for initial schematic approval, prior City’s acceptance of the Schematic Design. 3.9.7 Consultant shall submit to City an estimate of the Estimated Cost of Work, prepared in accordance with Article V herein. 3.9.8 Consultant shall submit the Schematic Design Documents to City and request the OwnerCity’s approval. Consultant shall submit two (2) full size and two (2) half size sets of Schematic Design Documents, two (2) sets of any reports and the Estimated Cost of Work. Consultant shall submit an evaluation and comparison of the Estimated Cost of Work to City’s budget and studies, as required. All models and documents also shall be provided in electronic format.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.may § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect 3.9.1 Consultant shall prepare a preliminary evaluation of the OwnerCity’s program, schedule, budget for the Estimated Cost of the Work, Project site, site and the proposed procurement and or delivery method, method and other Initial Informationinitial information, each in terms of the other, to ascertain the requirements of the Project. The Architect Consultant shall notify the Owner City of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that which reasonably may be reasonably needed for the Project. § 3.2.3 The Architect 3.9.2 Consultant shall present its preliminary evaluation to the Owner City and shall discuss with the Owner present to City alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect Consultant shall consider environmentally responsible and sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the OwnerCity’s program, schedule and budget for the Cost budget. Consultant shall meet City’s requirements of the Work. The Owner may obtain more advanced sustainable design services Project, as a Supplemental Service under Section 4.1.1set out in this Agreement. § 3.2.5.2 The Architect 3.9.3 Consultant shall consider the value of alternative materials, building systems system and equipment, together with other considerations considerations, based on program and aesthetics, in developing a design for the Project that which is consistent with the OwnerCity’s program, schedule, schedule and budget for the Estimated Cost of the Work. § 3.2.6 The Architect 3.9.4 Based on the Project’s requirements, Consultant shall submit to prepare and present, for City’s approval, a preliminary design illustrating the Owner an estimate scale and relationship of the Cost Project components. 3.9.5 Based on City’s approval of the Work prepared preliminary design, Consultant shall prepare Schematic Design Documents for City’s approval. Schematic Design Documents means the drawings and other documents, including a site plan, which shall incorporate the site survey issued by City, preliminary building floor plans, preliminary sections and elevations for all sides of the building, systems evaluations for structural and Mechanical, Electrical and Plumbing (hereafter referred to as “MEP”) solutions. The Schematic Design Documents may include some combination of study models, perspective sketches or digital modeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in accordance with Section 6.3writing. § 3.2.7 The Architect 3.9.6 Consultant shall submit the Schematic Design Documents to the OwnerHistorical Design Review Commission (hereafter referred to as “HDRC”) for initial schematic approval, prior City’s acceptance of the Schematic Design. 3.9.7 Consultant shall submit to City an estimate of the Estimated Cost of Work, prepared in accordance with Article V herein. 3.9.8 Consultant shall submit the Schematic Design Documents to City and request the OwnerCity’s approval. Consultant shall submit two (2) full size and two (2) half size sets of Schematic Design Documents, two (2) sets of any reports and the Estimated Cost of Work. Consultant shall submit an evaluation and comparison of the Estimated Cost of Work to City’s budget and studies, as required. All models and documents also shall be provided in electronic format.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.is § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect Engineer shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services.Manager. § 3.2.2 3.3.2 The Architect Engineer shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery methodsite (includes site conditions), and other Initial Project Information, each in terms of the other, to ascertain the requirements of the Project. The Architect Engineer shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect Engineer shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect Engineer shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect Engineer shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect Engineer shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.5.1 The Architect Engineer shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.14.1. § 3.2.5.2 3.3.5.2 The Architect Engineer shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 3.3.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect Engineer shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect Engineer shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect Engineer shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect Engineer shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect except to the extent Engineer knows, or in the exercise of the standard of care should know, of any inaccuracy, the Engineer shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information specifications furnished by Owner to ascertain the Owner, specific requirements of the Project and shall review lawsarrive at a mutual written understanding of such requirements with Owner. Architect shall include all components of Owner’s program in the Project, codes, and regulations applicable unless specific written agreement to the Architect’s servicesdelete a component is received from Owner. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project, and to ascertain that they are consistent with the requirements of the Project. The Architect shall notify the Owner Owner, in writing, of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. The Architect shall visit the Owner’s Project site and shall provide to Owner a written report evaluating the feasibility of the Owner’s site for the Project based on site conditions, and the Owner’s program, schedule and budget for the Cost of the Work. The Architect shall include, in the written report, an identification and evaluation of the location, availability, adequacy, capacity, and sufficiency of all utilities necessary to serve the completed Project. The Architect shall address with the Owner any existing easements or rights-of-way which may interfere with Owner’s Project. § 3.2.3 The Architect shall present its written preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an a written understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon in writing with the Owner, the Architect shall prepare and present, for the Owner’s approval, a written preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary designdesign and Owner’s schedule and budget for the Work, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall establish the conceptual design of the Project and illustrate the scale and relationship of the Project components. The Schematic Design shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental an Additional Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider consider, and, if applicable, consult with the Construction Manager at Risk regarding the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect When the Project requirements have been sufficiently identified, including Owner’s budgetary constraints, programmatic needs, and expectations as to quality, functionality of systems, maintenance costs, and usable life of equipment and facilities, the Architect, and, if applicable, the Construction Manager at Risk, shall submit to the Owner an prepare a preliminary estimate of the Cost of the Work prepared in accordance with Section 6.3. This estimate may be based on current area, volume or similar conceptual estimating techniques. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval. Architect shall not proceed to the Design Development Document Phase without the approval of Owner’s Commissioners Court, or the Court’s designee; provided, however, this approval shall not relieve Architect of Architect’s responsibility and liability to provide documents which are sufficient for Owner to complete the construction of the Project, and are free from material defects or omissions. Architect shall bear full responsibility for, and all resulting excess costs incurred by Architect in, proceeding without required approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s servicesservices and prepare designs and documents accordingly. As part of this review, the Architect shall attend a series of meetings with the Owner’s project team and the Architect’s consultants. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements One purpose of the Projectreview is to contain c limits. § 3.2.4 Based on the Project requirements agreed upon with the OwnerProject’s requirements, the Architect shall prepare and present, present for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may may, if requested by Owner, include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writingmodeling. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work. Architect shall provide for the Owner’s approval a written itemized estimate of the Cost of the Work prepared based upon the Schematic Design package produced by the Architect and at a level of detail satisfactory to the Owner, estimates of Cost of the Work, including the cost of each category of work involved, with costs projected to the scheduled date of completion of the Bidding and Negotiation Phase of Services. If that estimate does not conform to the initial Owner-provided Stated Limitation on Cost of the Work (SLCW), as set forth in accordance with Exhibit A Section 6.3A.1.3 herein, and any Owner- approved amendments thereto, the Architect shall provide a written statement to the Owner describing the specific reasons for the deviation and suggesting alternative designs or changes that can be made to the design in order to bring the Cost of the Work within the then-current SLCW. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approvalapproval in writing.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.14.1. § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, Owner and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services.Manager. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery methodsite (includes site conditions), and other Initial Project Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.14.1. § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, except to the extent Architect knows, or in the exercise of the standard of care should know, of any inaccuracy, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for p the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components.Proj § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Cost Consultant. The Architect shall meet with the Cost Consultant to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Cost Consultant’s estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 Architects Services. The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, and budget for the Cost of the Work, Project site, site and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, information and (2) other the information or consulting services that may be reasonably needed for the Project. § 3.2.3 . The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approached. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, aesthetics in design developing a design for the Project that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of Work. Upon receipt of the Work. § 3.2.6 The Cost Consultant estimates at the conclusion of the Schematic Design Phase, the Architect shall submit take action as required and request the owner’s approval of the Schematic Design Documents. Of revisions to the Owner an estimate of Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit at the conclusion of the Schematic Design Documents to Phase, the Owner, and request Architect shall incorporate the Owner’s approvalrequired revisions in the Design Development Phase.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and presentpresent to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approvalapproval and the Construction Manager’s review. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, identify agreed upon adjustments to the Project’s size, quality or budget, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.2 Based on the Owner’s approval of the preliminary designArchitect’s Predesign Study, dated April 2023, the Architect shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.2.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientationchoices, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. 1. The LEED Certification is not anticipated for this project. If the Owner may obtain more intends to pursue LEED Certification or similar, this advanced sustainable design services service will be provided as a Supplemental Service under Section 4.1.1Service. § 3.2.5.2 3.3.2.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.3 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.4 Upon receipt of the Construction Manager’s review comments and Cost Estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the subsequent design phase, the Design Development Phase. § 3.3.5 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s servicesservices and the Project. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner and Construction Manager regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, Owner and the budget for the Cost of the Work the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Construction Manager’s review and Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program program, budget, and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate such revisions in the Design Development Phase. § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review Owne be familiar with laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components.for § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.Design § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule schedule, and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. As necessary or appropriate, the Architect and its consultants shall participate in value engineering review meetings with the Owner. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s written approval.

Schematic Design Phase Services. § 3.2.1 2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, schedule and budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3Work. § 3.2.7 2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner and Construction Manager regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Construction Manager’s review and Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.and § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider discuss with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit the Schematic Design Documents to the Owner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. The Construction Manager shall prepare a Schematic Design level estimate. The Architect and the Construction Manager shall agree to an estimate of the Cost of the Work prepared prior to the Design Development Phase and shall report same in accordance with Section 6.3writing to the Owner. The Architect will present schematic plans to different levels of Owner’s staff as reasonably requested by Owner. § 3.2.7 The Architect shall submit Upon receipt of the Construction Manager’s review comments and the completion of the cost estimate as provided in Section 3.2.6 at the conclusion of the Schematic Design Documents Phase, the Architect shall take action as required under Section 6.4, identify agreed upon adjustments to the OwnerProject’s size, quality or budget, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate such revisions in the Design Development Phase. § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and p present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components.for § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review Owne laws, codes, and regulations applicable to the Architect’s servicesservices and shall arrive at a mutua requirements with the Owner. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project.schedu § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; elevations and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. In addition, Architect shall furnish a building code and planning analysis, outline specifications and other documents illustrating the design intent, scale and relationship of Project components. The outline specifications shall identify major materials and systems and generally establish their quality levels. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit During the Schematic Design Documents Phase, the Architect (and its Consultants, as required) will attend bi-weekly project meetings with the Owner (and others). Attention is directed to the Owner, and request the Owner’s approval.Section 3.1.7

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider consider, if requested by the Owner, sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services, including but not limited to verifying initial permit and land use requirements with the authority having jurisdiction ("AHJ") over the Project. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project.inconsistencies § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project, including the feasibility of incorporating sustainable design approaches, and consideration of the implementation of the Owner’s sustainable objective, if any. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and presentpresent to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approvalapproval and the Construction Manager’s review. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writingmodeling. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, implications of sustainable code requirements enacted in the relevant jurisdiction, if any, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced other sustainable design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, identify agreed upon adjustments to the Project’s size, quality, or budget, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. For Schematic Design Phase Services, references to the Construction Manager apply only to the extent a Construction Manager has been selected. § 3.2.1 3.3.1 The Architect shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. The Architect will advise the Owner of design alternatives, which could result in savings to the Owner, including savings in the construction cost and the cost of operating the Project when completed. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project, including the feasibility of incorporating sustainable design approaches, and consideration of the implementation of the Owner’s sustainable objective, if any. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. The Architect shall coordinate and conduct Schematic Design meetings with the Construction Manager and Owner. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, implications of sustainable code requirements enacted in the relevant jurisdiction, if any, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services not included as a Supplemental Basic Services, as an Additional Service under Section 4.1.1subject to Owner’s prior written authorization in accordance with this Agreement. § 3.2.5.2 3.3.5.2 The Architect shall consider and discuss with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program program, life cycle costs, operating costs, staffing costs and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the Owner and the Construction Manager, including copies of any applicable design narrative and/or project manual. The Architect shall meet with the Construction Manager and Owner to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Owner’s comments and Construction Manager’s review comments and Cost Estimate, if any, at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.5 and 6.6, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, if any, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 6.1 The Architect Cost of the Work shall submit be the Schematic Design Documents total cost to the OwnerOwner to construct all elements of the Project designed or specified by the Architect and shall include contractors’ general conditions costs, overhead and profit. The Cost of the Work also includes the reasonable value of labor, materials, and request equipment, donated to, or otherwise furnished by, the Owner’s approval. The Cost of the Work does not include the compensation of the Architect; the costs of the land, rights-of-way, financing, or contingencies for changes in the Work; or other costs that are the responsibility of the Owner.)

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches if requested by Owner. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable consider, if requested by the Owner, environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to review the Owner an hired XXXX’x estimate of the Cost of the Work prepared in accordance with Section 6.3prepared. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 2.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 2.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 2.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 2.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 2.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.may § 3.2.5.1 2.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.13.1.1. § 3.2.5.2 2.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 2.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.35.3. § 3.2.7 2.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. IA § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, Own codes, and regulations applicable to the Architect’s services.. The Architect shall submit rep review, and deliverables as defined in EXH-B Project Design Milestones & Deliverables, A G202-2013, and E203-2013. nd shall review laws, G20 contracts , documents for 1-2013, § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.Owner as defined in EXH-B Design Milestones & Deliverables, and request the Owner’s approval before proceeding with Design Development Documents as defined in EXH-B Design Milestones & Deliverables.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Cost Consultant. The Architect shall meet with the Cost Consultant to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Cost Consultant’s estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.other § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and presentpresent to the ng t e Sc tic Design Documents iminetc l be Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and illustrati relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design prepar Documents for the Owner’s approvalapproval and the Construction Manager’s review. The Schematic Design Documents Schema shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, prel sections and elevations; and may include some combination of study models, perspective sketches, or digital representationssk modeling. Preliminary selections of major building systems and construction materials shall be noted on the shal drawings or described in writing.. he scale and hematic Design ary building plans, hes, or digital noted on the § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, identify agreed upon adjustments to the Project’s size, quality or budget, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 Upon receipt of a Notice to Proceed with the schematic design phase from MassDevelopment, the Designer and its appropriate Consultants shall meet with agents of MassDevelopment to arrive at a mutual understanding of the requirements of the Study or Program furnished for MassDevelopment. The Architect Designer shall submit a proposed design work plan for the Designer's Services pursuant to this Contract including anticipated tasks and submittals. The Designer shall submit a proposed Contract Schedule consistent with any project schedule included in the Study or Scope of Services referenced in Attachment A. The schedule shall contain dates for submittals, deliverables, actions, milestones, design workshops, meetings and the critical path through all design service activities. It shall include allowances of time for MassDevelopment's review and Approval of submittals and for necessary submissions for Permits in connection with the program Project. When Approved by MassDevelopment, the work plan and other information furnished the Contract Schedule shall govern the Designer's duties hereunder. The work plan shall also include a Work Plan Schedule of Values consistent with the payment schedule for the Basic Fee specified in Section 8.2 which shall be the basis of which payments of the Basic Fee within each phase shall be made. The Work Plan Schedule of Values shall identify deliverables within each phase and percentages of the phase fee payable upon completion of such deliverable. When Approved by MassDevelopment, the Owner, Work Plan Schedule of Values shall govern the timing of payments of the Basic Fee upon completion of deliverables within each phase and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 as each phase progresses. The Architect Designer shall prepare a preliminary evaluation of MassDevelopment’s Program, Study and construction budget requirements subject to the Owner’s programlimitations described in subsection iv below. If the Designer is the Designer that performed the Study, scheduleMassDevelopment may at its option permit the Designer to develop the preferred Study alternative. Otherwise the Designer shall develop at least three alternative designs to a pre-schematic level. For the purposes of the preceding sentence "pre-schematic" means a general design concept level including program space and building envelope, budget footprint, massing, volume, orientation, and site context. Each pre-schematic alternative shall include a Construction Cost Estimate in CSI Masterformat with revisions accepted in 2014 with 50 Divisions of work, or any more recent amendments, or as may be otherwise mutually accepted within individual delivery orders for specific projects. The Designer shall review with MassDevelopment the alternative designs and shall make a recommendation as to the preferred alternative. Upon selection by MassDevelopment of the preferred alternative, the Designer shall develop the preferred alternative to a full schematic design level. Designer shall provide the following schematic design-level documentation which shall include and incorporate MassDevelopment comments: drawings, concept sketches, three-dimensional representations, and specifications; a building code analysis; an environmental assessment; a preliminary life cycle cost analysis to determine which design decisions related to all energy and water consuming devices and overall building operation and maintenance are the most cost effective [M.G.L. c. 149, § 44M and c. 7C, §29]; a summary of applicable public-utility incentive-programs as determined by MassDevelopment and a plan for implementation or inclusion of such incentives; an analysis of the design's compliance with the Americans with Disabilities Act and Massachusetts Architectural Access Board requirements; a space measurement analysis for the design, which shall verify that the sum of all program floor areas in the Project plus all other floor areas in the Project equal the Gross Floor Area of the Project; and a Construction Cost Estimate for the design in CSI Masterformat with revisions accepted in 2014 with 50 Divisions of work, or any more recent amendments, or as may be otherwise mutually accepted within individual delivery orders for specific projects with aggregated unit rates and quantities supporting each item and verified as accurate and complete by the cost estimator and/or Owner's Project Manager, if any, employed by MassDevelopment. Schematic design level documentation shall also include a summary comparing the schematic plans, specifications and Estimated Construction Cost of the Workdesign to the Program and Study requirements and shall explain any deviation therefrom. Schematic design phase drawings, Project sitespecifications, Construction Cost Estimates and other submittals shall be subject to the written Approval of MassDevelopment. Unless a lesser number is requested by MassDevelopment, the proposed procurement and delivery methodDesigner shall submit to MassDevelopment for approval six (6) copies of schematic design drawings, specifications, cost estimates, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Projectsubmittals. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner and Construction Manager regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a up to three preliminary design designs illustrating the scale and relationship of the Project components. The Owner may request additional preliminary design options beyond three as a Supplemental Service under Section 4.1.1. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Construction Manager’s review and Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate such revisions in the Design Development Phase. § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 2.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services.Owner. § 3.2.2 2.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, site (includes site conditions), the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 2.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. Project, including the feasibility of incorporating environmentally responsible design approaches consistent with Owner’s Sustainability Objective. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 2.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 2.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 2.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.13.1.1. § 3.2.5.2 2.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 2.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.35.3. § 3.2.7 2.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches approaches, if any, to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 6.1 The Architect Cost of the Work shall submit be the Schematic Design Documents total cost to the OwnerOwner to construct all elements of the Project designed or specified by the Architect and shall include contractors’ general conditions costs, overhead and profit. The Cost of the Work also includes the reasonable value of labor, materials, and request equipment, donated to, or otherwise furnished by, the Owner’s approval. The Cost of the Work does not include the compensation of the Architect; the costs of the land, rights-of-way, financing, or contingencies for changes in the Work; or other costs that are the responsibility of the Owner.)

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget provided by the Construction Manager for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and presentpresent to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approvalapproval and the Construction Manager’s review. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall assist Construction Manager in preparing its estimate of the Cost of the Work. § 3.2.5.2 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 3.2.5.3 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work.aesthetics in § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, identify agreed upon § 3.2.8 In the further development of the Drawings and request Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services, and shall prepare designs and documents accordingly. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the 3.3.5 The Architect shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s written approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.14.1. § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, identify agreed upon adjustments to the Project’s size, quality, or budget, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. , including the feasibility of incorporating sustainable design approaches, and consideration of the implementation of the Owner’s sustainable objective, if any.. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval and the Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling.representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, implications of sustainable code requirements enacted in the relevant jurisdiction, if any, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more othermore advanced sustainable design services as a Supplemental Service under Section 4.1.1ArticleSection 4.1. § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, identify agreed upon adjustments to the Project’s size, quality, or budget, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 2.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 2.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project.Project, including but not limited to additional soils information. § 3.2.3 2.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 2.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 2.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 2.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.13.1.1. § 3.2.5.2 2.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 2.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work based on area, volume or other unit costs per standard estimating practice and prepared in accordance with Section 6.35.3. § 3.2.7 2.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and presentpresent to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approvalapproval and the Construction Manager’s review. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, identify agreed upon adjustments to the Project’s size, quality or budget, and request the Owner’s approvalapproval of the Schematic Design Documents. If § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review and analyze the program and other information furnished by the Owner to ascertain the requirements of the Project, shall arrive at a mutual understanding of such requirements with the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare original (re-drawn) Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of original (re-drawn) drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The . If the Architect’s Cost of the Work estimate does not conform to the Initial Cost of the Work (Section 6.2) and any Owner approved modification, the Architect shall submit the Schematic Design Documents provide a written statement to the Owner, and request Owner to suggest alternative designs or change to the designs to bring the Architect’s estimate within the Initial Cost of the Work. The parties shall agree upon any changes required to the extent such estimate exceeds the Owner’s approval.budget for the Cost of the Work, which changes the Architect will incorporate as part of the Section 3.3

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner and Construction Manager regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Construction Manager’s review and Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate such revisions in the Design Development Phase. § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 5.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 5.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 5.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 5.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 5.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 5.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article . § 3.2.5.2 5.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 5.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 5.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval. The Architect shall make the required submittals to the South Carolina Department of Education’s Office of School Planning and Facilities, and participate fully in the plan review process for the same.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect Constructor shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval. Owner and Constructor, and request the Owner’s approval. § 3.2.8 Upon receipt of the Constructor’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.2, and request the Owner’s approval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate such revisions in the Design Development Phase. § 3.2.9 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Constructor under the Constructor’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 2.2.1 The Architect shall review the program and other information information, including Owner objectives, schedules, space requirements and other building and site considerations, furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 2.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The In preparation for, and in conjunction with, the Schematic Design Phase, the Architect shall notify also modify the provided program information into a formalized concise program document which includes, at a minimum, the following for Owner approval: 1. Listing of (1) any inconsistencies discovered Building Program spaces and sizes in the information, net square feet with delineation of existing versus new. 2. Documentation of required program space relationships. 3. Listing of special needs for each programmed space. 4. Target net square foot to gross square foot efficiency ratio. 5. Special building characteristics and (2) other information or consulting services that may requirements which should be reasonably needed for included in design and construction parameters of the Project. § 3.2.3 2.2.2.1 The Architect shall advise the Owner of a need for tests, analyses, studies, reports, documentation of existing conditions or consultants’ services not previously provided for in this Agreement. § 2.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 2.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 2.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 2.2.5..1 The Architect shall respond in writing, in the format requested by the Owner, to all written comments from the Owner and Construction Manager regarding the Architect’s Schematic Design Phase submittal and shall secure Owner’s final written approval of such submittal. Schematic Design Documents shall, if reasonably requested by the Owner, be revised and resubmitted incorporating modifications needed to obtain such approval. § 2.2.5.1.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.13.1.1, if not previously defined as a Basic Service. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project.any § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.. nd a de r m xxxxx ign t y obt equipment § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building a b orientation, together with other considerations based on program and aesthetics, in developing a design that is s consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more Owne a advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work.and § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review and validate the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. The Architect shall review the program, schedule, and construction budget to ascertain the requirements for the Project and shall arrive at a mutual understanding of such requirements with the Owner and modify as required. Based on the estimate of the Cost of the Work, the Architect is to prepare all necessary drawings, specifications, and other documents required for the construction and completion of the Project based on the Owner’s budget. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. The Schematic Design Document shall provide options for size, location, and configuration of the Owner-approved design on the site. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. Architect shall prepare written description of structural, mechanical, electrical, plumbing, and technology work, along with preliminary layouts as needed for cost estimating. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is d equip oject me that is d in accord consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together an with other considerations based on program and aesthetics, in developing a design for the Project that is consistent Pr with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with prepare Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s servicesservices and the Project. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Informationinitial information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the errors discovere Project. § 3.2.3 The Architect shall present Xxxxxx regarding its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project.recom § 3.2.4 Based on the Project requirements agreed upon with and the directives and selections of Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design that consists of programming information, drawings, narratives, and other documents illustrating the scale scale, character, and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary designBas program, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.Schematic § 3.2.5.1 The Architect shall consider consider, and advise and consult with Owner regarding, sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s goals and objectives regarding sustainability and energy consumption and the Owner’s program, schedule and budget for the Cost of the Work. The Architect will complete a LEED checklist, or perform a similar exercise for another sustainability standard if requested, and advise and consult with Owner regarding options for achieving certain certifications or standards. Unless otherwise set forth in the Architect Contract, Owner may obtain more advanced sustainable design services as a Supplemental an Additional Service under Section 4.1.1in accordance with Article 4. § 3.2.5.2 The Architect shall consider consider, and advise and consult with Owner regarding, the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.5.3 The Schematic Design Documents shall include drawings and outline specifications or narratives specifying the parameters, design assumptions, and design philosophies of all major building systems, including structural, mechanical, electrical, and plumbing. If requested by Owner, Architect will prepare a utility impact statement that documents and evaluates the location, size, and capacity of all existing utility infrastructure necessary to support the proposed building utility systems, including, at a minimum, steam, chilled water, domestic water, fire protection water, gas, electrical power, sanitary sewer, storm drainage, and low voltage wiring of telecommunications, data, and security. Zoning information, including the zoning district, bulk regulations, and use restrictions, must be indicated in the drawings either on the cover sheet, title sheet, index sheet, or legend sheet. § 3.2.5.4 If applicable, Architect or its consultants shall perform survey(s) of the existing facilities to establish and document existing conditions and to identify conflicts or inconsistencies between existing conditions and existing drawings. The surveys shall include above lay-in ceiling inspections, but not concealed areas such as below grade or behind drywall ceilings or partitions unless selective destructive investigation is recommended by Architect and approved Owner in writing. The surveys shall include elements such as duct routing, pipe routing, panel board inspections, fan locations, equipment conditions and locations, etc. To the extent feasible without destructive testing, information and conditions from drawings provided by Owner or must be field verified. § 3.2.6 The Architect shall submit to the Owner an estimate schedule, coordinate, and obtain initial/preliminary plan reviews of the Cost of Schematic Design Documents by the Work prepared in accordance with Section 6.3applicable local and state agencies. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner for approval and report to Owner regarding any results of the initial codes reviews. § 3.2.8 Architect shall consider, and request advise and consult with Owner regarding, the estimates, value engineering suggestions, and constructability concerns of any potential contractors. If estimates are inconsistent with the Owner’s approvalbudget for the Cost of the Work, Architect shall assist Owner and potential contractors with identifying the specific reasons for the deviation and suggest alternatives and modifications to bring the Project within budget. Architect shall incorporate into the Schematic Design Documents those alternatives and modifications that are approved by Owner in a manner that is consistent with the Project requirements and the budget for the Cost of the Work. § 3.2.9 Architect shall not proceed with the Design Development Phase Services until Owner has approved the Schematic Design Documents in writing.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the existing program and other information furnished by the Owner, including but not limited to a systems assessment addressing reuse and integration of new systems, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall promptly notify the Owner of of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating sustainable design approaches, and consideration of the implementation of the Owner’s sustainable objective, if any. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and presentpresent to the Owner, for the Owner’s approval, a detailed program that addresses functional needs to serve and support the planned uses of the Project and preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents as needed to clearly describe the work to be constructed, including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials including but not limited to MEP systems, low-voltage system, finishes, and any other pertinent information to represent the program and basic design intent, shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, implications of sustainable code requirements enacted in the relevant jurisdiction, if any, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced other sustainable design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider with the Owner the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit [Deleted]. § 3.2.8 During the Schematic Design Documents to Phase, the Ownerfollowing design and building components will be analyzed for recommendations or for identification of alternate materials, systems, equipment, and request the Owner’s approval.development of conceptual design solutions, as applicable: .1 Demolition plans .2 Alternate structural systems .3 Energy sources .4 Energy conservation .5 Heating and ventilating .6 Air conditioning .7 Plumbing .8 Fire protection .9 General space requirements .10 Conveying systems .11 Power service and distribution .12 Lighting

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The 3.9.1 Architect shall prepare a preliminary evaluation of the OwnerCity’s program, schedule, budget for the Estimated Cost of the Work, Project site, site and the proposed procurement and or delivery method, method and other Initial Informationinitial information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner City of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that which reasonably may be reasonably needed for the Project. § 3.2.3 The 3.9.2 Architect shall present its preliminary evaluation to the Owner City and shall discuss with the Owner present to City alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider environmentally responsible and sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the OwnerCity’s program, schedule and budget for the Cost budget. Architect shall meet City’s requirements of the Work. The Owner may obtain more advanced sustainable design services Project, as a Supplemental Service under Section 4.1.1set out in this Agreement. § 3.2.5.2 The 3.9.3 Architect shall consider the value of alternative materials, building systems system and equipment, together with other considerations considerations, based on program and aesthetics, in developing a design for the Project that which is consistent with the OwnerCity’s program, schedule, schedule and budget for the Estimated Cost of the Work. § 3.2.6 The 3.9.4 Based on the Project’s requirements, Architect shall submit to prepare and present, for City’s approval, a preliminary design illustrating the Owner an estimate scale and relationship of the Cost Project components. 3.9.5 Based on City’s approval of the Work prepared preliminary design, Architect shall prepare Schematic Design Documents for City’s approval. Schematic Design Documents means the drawings and other documents, including a site plan, which shall incorporate the site survey issued by City, preliminary building floor plans, preliminary sections and elevations for all sides of the building, systems evaluations for structural and Mechanical, Electrical and Plumbing (hereafter referred to as “MEP”) solutions. The Schematic Design Documents may include some combination of study models, perspective sketches or digital modeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in accordance with Section 6.3writing. § 3.2.7 The 3.9.6 Architect shall submit the Schematic Design Documents to the OwnerHistorical Design Review Commission (hereafter referred to as “HDRC”) for initial schematic approval, prior City’s acceptance of the Schematic Design. 3.9.7 Architect shall submit to City an estimate of the Estimated Cost of Work, prepared in accordance with Article V herein. 3.9.8 Architect shall submit the Schematic Design Documents to City and request the OwnerCity’s approval. Architect shall submit two (2) full size and two (2) half size sets of Schematic Design Documents, two (2) sets of any reports and the Estimated Cost of Work. Architect shall submit an evaluation and comparison of the Estimated Cost of Work to City’s budget and studies, as required. All models and documents also shall be provided in electronic format.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, and budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project, and to ascertain that they are consistent with the requirements of the Project. The Architect shall notify the Owner in writing of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. The Architect shall visit the Owner’s Project site and shall provide to Owner a written report evaluating the feasibility of the Owner’s site for the Project based on site conditions, and the Owner’s program, schedule and budget for the Cost of the Work. The Architect shall include, in the written report, an identification and evaluation of the location, availability, adequacy, capacity, and sufficiency of all utilities necessary to serve the completed Project. The Architect shall address with the Owner any existing easements or rights-of-way which may interfere with Owner’s Project. § 3.2.3 3.3.3 The Architect shall present its written preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an a written understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon in writing with the Owner, the Architect shall prepare and present, for the Owner’s approval, a written preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary designdesign and Owner’s schedule and budget for the Work, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.Design § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost implications of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.code § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work.aesthetics in § 3.2.6 3.3.6 The Architect shall submit the Schematic Design Documents to the Owner an and request the Owner’s § 3.3.7 When the Project requirements have been sufficiently identified, including Owner’s budgetary constraints, programmatic needs, and expectations as to quality, functionality of systems, maintenance costs, and usable life of equipment and facilities, the Architect and the Construction Manager, shall prepare a preliminary estimate of the Cost of the Work prepared in accordance with Section 6.3. This estimate may be based on current area, volume or similar conceptual estimating techniques. § 3.2.7 The 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall submit be entitled to rely on the Schematic Design Documents accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project, and (3) any anticipated impact that the selected delivery method may have on the scheduled completion of the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches if requested by the Owner and incorporated into the project specific contract amendment. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, and based upon the Owner’s then-current budget, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.preliminary § 3.2.5.1 The Architect shall consider discuss with the Owner sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services, including but not limited to verifying initial permit and land use requirements with the authority having jurisdiction (“AHJ”) over the Project. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review Owne laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.is § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review and analyze the program and other information furnished by the Owner to ascertain the requirements of the Project, shall arrive at a mutual understanding of such requirements with the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare original (re-drawn) Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of original (re-drawn) drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The . If the Architect’s Cost of the Work estimate does not conform to the Initial Cost of the Work (Section 6.2) and any Owner approved modification, the Architect shall submit the Schematic Design Documents provide a written statement to the Owner, and request Owner to suggest alternative designs or change to the Ownerdesigns to bring the Architect’s approval.estimate within the Initial Cost of the Work. The

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.other § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect 3.9.1 Consultant shall prepare a preliminary evaluation of the OwnerCity’s program, schedule, budget for the Estimated Cost of the Work, Project site, site and the proposed procurement and or delivery method, method and other Initial Informationinitial information, each in terms of the other, to ascertain the requirements of the Project. The Architect Consultant shall notify the Owner City of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that which reasonably may be reasonably needed for the Project. § 3.2.3 The Architect 3.9.2 Consultant shall present its preliminary evaluation to the Owner City and shall discuss with the Owner present to City alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect Consultant shall consider environmentally responsible and sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the OwnerCity’s program, schedule and budget for the Cost budget. Consultant shall meet City’s requirements of the Work. The Owner may obtain more advanced sustainable design services Project, as a Supplemental Service under Section 4.1.1set out in this Agreement. § 3.2.5.2 The Architect 3.9.3 Consultant shall consider the value of alternative materials, building systems system and equipment, together with other considerations considerations, based on program and aesthetics, in developing a design for the Project that which is consistent with the OwnerCity’s program, schedule, schedule and budget for the Estimated Cost of the Work. § 3.2.6 The Architect 3.9.4 Based on the Project’s requirements, Consultant shall submit to prepare and present, for City’s approval, a preliminary design illustrating the Owner an estimate scale and relationship of the Cost Project components. 3.9.5 Based on City’s approval of the Work prepared preliminary design, Consultant shall prepare Schematic Design Documents for City’s approval. Schematic Design Documents means the drawings and other documents, including a site plan, which shall incorporate the site survey issued by City, preliminary building floor plans, preliminary sections and elevations for all sides of the building, systems evaluations for structural and Mechanical, Electrical and Plumbing (hereafter referred to as “MEP”) solutions. The Schematic Design Documents may include some combination of study models, perspective sketches or digital modeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in accordance with Section 6.3writing. § 3.2.7 The Architect 3.9.6 Consultant shall submit the Schematic Design Documents to the OwnerHistorical Design Review Commission (hereafter referred to as “HDRC”) for initial schematic approval, prior City’s acceptance of the Schematic Design. 3.9.7 Consultant shall submit to City an estimate of the Estimated Cost of Work, prepared in accordance with Article V herein. 3.9.8 Consultant shall submit the Schematic Design Documents to City and request the OwnerCity’s approval. Consultant shall submit two (2) full size sets, four (4) half size sets and one (1) digital copy of Schematic Design Documents, two (2) sets of any reports and the Estimated Cost of Work. Consultant shall submit an evaluation and comparison of the Estimated Cost of Work to City’s budget and studies, as required. All models and documents also shall be provided in electronic format.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 .1 Based on the Project Project’s requirements agreed upon with the Owner, the Architect Design-Builder shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 .2 Based on the Owner’s approval of the preliminary design, the Architect Design-Builder shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. The Schematic Design Documents will identify any systems, materials or equipment for which contractors will provide design services or certifications (“Delegated Design Components”), which Delegated Design Components shall be consistent with this Agreement and subject to Owner’s approval. § 3.2.5.1 .3 The Architect Design-Builder shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 .4 The Architect Design-Builder shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 .5 The Architect Design-Builder shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3Work. § 3.2.7 .6 The Architect Design-Builder shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval. Before the Design-Builder proceeds with the Design Development Phase, the Design-Builder shall make a presentation of its Schematic Design to the Owner including, but not .7 Following the approval of the Owner, the Design-Builder shall seek and secure review of Schematic Design Documents by all regulatory and certification agencies as may be necessary or appropriate, and obtain approval by those agencies. The Design-Builder shall participate in public hearings or presentations, if required, in order to receive approval of the regulatory agencies. .8 The Schematic Design Phase shall include a thorough code search by Design-Builder identifying in writing all applicable building codes and ordinances and certification requirements.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider consider, if requested by the Owner, sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 3.3.1 The Architect shall review the program program, and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 3.3.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 3.3.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for Construction Manager’s review and the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 3.3.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.14.1. § 3.2.5.2 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 3.3.6 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections plans and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall may consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, Owner and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 2.2.1 The Architect Engineer shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services.Owner. § 3.2.2 2.2.2 The Architect Engineer shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, site (includes site conditions), the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect Engineer shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 2.2.3 The Architect Engineer shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect the Project, including the feasibility of incorporating environmentally responsible design approaches consistent with Owner’s Sustainability Objective. The Engineer shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 2.2.4 Based on the Project requirements agreed upon with the Owner, the Architect Engineer shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 2.2.5 Based on the Owner’s approval of the preliminary design, the Architect Engineer shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 2.2.5.1 The Architect Engineer shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.13.1.1. § 3.2.5.2 2.2.5.2 The Architect Engineer shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 2.2.6 The Architect Engineer shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.35.3. § 3.2.7 2.2.7 The Architect Engineer shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project.of § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review lawsand comply with lLaws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies or errors discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall advise and consult discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall advise and consult with the Owner regarding consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall advise and consult with the Owner regarding consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, take any action required under Section 6.5, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review and analyze the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any fault or defect in the Project, including errors, omissions or inconsistencies in the Architect’s Instruments of Service. If and to the extent that the Educational Specifications document developed in cooperation with the Owner, as provided in Paragraph 5.1, requires clarification or supplementation to accurately reflect such mutual understanding of the Project’s requirements , the Architect shall furnish such clarification or supplementation to the Owner in writing. The Architect shall visit the site and conduct an appropriate evaluation of actual conditions and other data necessary for proper design and analysis, as needed . § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.that § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the OwnerOwner and Construction Manager, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner and Construction Manager regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, to the Owner and Construction Manager, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Construction Manager’s review and Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.is § 3.2.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Construction Manager. The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Construction Manager’s review comments and cost estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate such revisions in the Design Development Phase. Such revisions shall be completed as part of the Architect’s basic services. § 3.2.8 In the further development of the Drawings and Specifications during this and subsequent phases of design, the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work, which are to be provided by the Construction Manager under the Construction Manager’s agreement with the Owner.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design, including the feasibility of incorporating environmentally responsible design and construction of the Projectapproaches. The Architect shall reach an understanding with the Owner and the CM/GC regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing.other § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, construction methods, and future maintenance requirements, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the OwnerOwner and the Cost Consultant. The Architect shall meet with the Cost Consultant to review the Schematic Design Documents. § 3.2.7 Upon receipt of the Cost Consultant’s estimate at the conclusion of the Schematic Design Phase, the Architect shall take action as required under Section 6.4, and request the Owner’s approvalapproval of the Schematic Design Documents. If revisions to the Schematic Design Documents are required to comply with the Owner’s budget for the Cost of the Work at the conclusion of the Schematic Design Phase, the Architect shall incorporate the required revisions in the Design Development Phase.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. The Architect shall respond in the design of the Project to requirements imposed by governmental authorities having jurisdiction over the Project. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall review such information to ascertain that it is consistent with the requirements of the Project and shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. The Architect shall respond in the design of the Project to requirements imposed by governmental authorities having jurisdiction over the Project. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall immediately, in writing, notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project; and (3) any impact that the selected delivery method may have on the scheduled completion of the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of i environmentally responsible design approaches if requested by the Owner. The Architect shall reach an sha understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components.p § 3.2.5 Based on the Owner’s approval of the preliminary design, and based upon the Owner’s then-current budget, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.is § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, meet with the Owner to review Schematic Design Documents, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect A/E shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the ArchitectA/E’s services. § 3.2.2 The Architect A/E shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect A/E shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project. The Architect shall reach an understanding with , including the Owner regarding the requirements feasibility of the Projectincorporating environmentally responsible design approaches. § 3.2.4 Based on the Project requirements agreed upon with the OwnerProject’s requirements, the Architect A/E shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect A/E shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may may, if requested by the Owner, include some combination of study models, perspective sketches, or digital representationsmodeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect A/E shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect A/E shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect A/E shall submit to the Owner an estimate of the Cost of the Work. A/E shall provide for the Owner’s approval a written itemized estimate of the Cost of the Work prepared based upon the Schematic Design package produced by the A/E, with cost project to the schedule date of completion of the Bidding and Negotiation Phase of Services. If that estimate does not conform to the initial Owner-approved budget, and any Owner-approved amendments thereto, the A/E shall provide a written statement to the Owner describing the specific reasons for the deviation and suggesting alternative designs or changes that can be made to the design in accordance with Section 6.3order to bring the Cost of the Work within the then-current Owner budget. § 3.2.7 The Architect A/E shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and proposed delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project.) § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital modeling or representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1.is § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s approval. § 3.2.8 The Schematic Design Documents will identify any systems, materials or equipment for which contractors or others not engaged by Architect will provide design services or certifications (“Delegated Design Components”), which Delegated Design Components shall be consistent with this Agreement and subject to Owner’s approval. § 3.2.9 The Schematic Design Phase shall include a thorough code search by Architect identifying in writing all applicable building codes and ordinances and certification requirements. § 3.2.10 Before the Architect proceeds with the Design Development Phase, the Architect shall make a presentation of its Schematic Design to the Owner including, but not limited to, explaining its conformance with and any approved exceptions to the Owner’s design guidelines. § 3.2.11 Following the approval of the Owner, the Architect shall seek and secure review of Schematic Design Documents by all regulatory and certification agencies as may be necessary or appropriate, and obtain approval by those agencies. The Architect shall participate in public hearings or presentations, if required, in order to receive approval of the regulatory agencies.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement and or delivery method, method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project Project’s requirements agreed upon with the Owner, the Architect shall prepare and present, present for the Owner’s approval, approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representationsmodeling if requested by the Owner prepared in-house by the Architect to assist in communicating the design concepts to the Owner’s project committee. If provided, such models and sketches would be working tools and would not be intended to be suitable for presentation for fundraising or other similar presentation purposes. Finished models, renderings or digital modeling for presentation purposes, if requested by the Owner, would be addressed as Additional Services. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider sustainable environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable other environmentally responsible design services as a Supplemental Service under Section 4.1.1Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, aesthetics in developing a design for the Project that is consistent with the Owner’s program, schedule, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner’s written approval. § 3.2.7.1 Schematic Design Phase written approval by the Owner will include the following basic decisions subject to the Owner’s agreement that sufficient information has been provided by the Architect for these decisions to be made and subject to compliance with the Cost of the Work as approved by the Owner: .1 The final project program. .2 The site location and the basic scope of site work to be included in the project. .3 The basic size, shape and massing, plan and sectional relationships of project components and layout of the spaces of the new building. .4 Selection of the primary exterior and interior materials to be used in the new building. .5 Selection of the basic structural materials and systems. .6 Selection of the basic mechanical and electrical systems. § 3.2.8 The Architect shall review and comment upon the Owner’s detailed preliminary estimate of Construction Cost prepared by the Owner's cost estimator and/or contractor ("value engineer" and/or "VE") based on current area, volume or similar conceptual estimating techniques which estimate shall indicate the cost of each category of work involved in constructing each Phase of the Project and shall establish an elapsed time factor for the period of time from the commencement to the completion of the construction of the Project. The Architect’s basic services related to VE are further described in Section 12.18.8.

Schematic Design Phase Services. § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner’s program, schedule, budget for the Cost of the Work, Project site, the proposed procurement and delivery method, and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. In preparation for, and in conjunction with, the Schematic Design Phase, the Architect shall also modify the provided program information into a formalized concise program document which includes, at a minimum, the following for Owner approval: 1. Listing of Building Program spaces and sizes in net square feet with delineation of existing versus new. 2. Documentation of required program space relationships. 3. Listing of special needs for each programmed space. 4. Target net square foot to gross square foot efficiency ratio. 5. Special building characteristics and requirements which should be included in design and construction parameters of the Project. § 3.2.2.1 The Architect shall notify advise the Owner of (1) any inconsistencies discovered a need for tests, analyses, studies, reports, documentation of existing conditions or consultants’ services not previously provided for in the information, and (2) other information or consulting services that may be reasonably needed for the Projectthis Agreement. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project requirements agreed upon with the Owner, the Architect shall prepare and present, for the Owner’s approval, a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner’s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner’s approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.0.1 The Architect shall respond in writing, in the format requested by the Owner, to all written comments from the Owner regarding the Architect’s Schematic Design Phase submittal and shall secure Owner’s final written § 3.2.5.1 The Architect shall consider sustainable design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner’s program, schedule and budget for the Cost of the Work. The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1.1. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner’s program, schedule, and budget for the Cost of the Work. § 3.2.6 The 3.2.5.3 Schematic Design documentation shall also include, but not be limited to, the following: .1 An evaluation of HVAC systems including a narrative and drawings of at least three alternative system strategies delineating advantages, disadvantages, flow diagrams, approximate loads, sizing and capacity information, and relative order of magnitude costs for operation and installation. .2 A written description, flow diagrams, and design loads of the preferred mechanical and electrical systems for the Project. After review and approval by the Owner, these documents will serve as the "Basis of Design" for the mechanical and electrical systems of the Project. .3 Schematic Design documentation shall include drawings and/or narrative description of and performance criteria for all principal construction materials and systems proposed for the Project, including exterior and interior building materials and finishes; structural systems; plumbing and piping systems and fixtures, HVAC systems including major equipment items and control systems; lighting concept and fixture types; electrical power and telecommunications systems; and other significant building or site components as required to complete a detailed construction cost estimate for the full scope of the Project. .4 Tabular comparisons of all room areas shown in Owner’s building program compared to all room areas as shown in schematic design document. § 3.2.5.4 When Schematic Design Documents have been prepared by the Architect, the Architect shall submit to prepare for review by the Owner an estimate of construction costs with supporting data. The Estimate shall be in the Cost Construction Specification Institute’s (CSI’s) format and shall include separate line item costs, projected to the scheduled construction dates, for all major systems and components of the Work prepared in accordance with Section 6.3. § 3.2.7 Work. The Architect shall submit also prepare comparative estimates for cost evaluations of alternative materials and systems. The Owner is not required to approve the Schematic Design Documents unless and until all of the following conditions have been met: 1. The Schematic Design Documents have been completed; 2. The Owner has completed an estimate of construction costs based upon the Schematic Design Documents; 3. The Architect has completed an estimate of construction costs based on the Schematic Design Documents; 4. The construction cost estimates of the Owner and the Architect have been reconciled ("Reconciled Cost Estimates"); 5. The Reconciled Cost Estimates are mutually determined by the Architect and the Owner to be within the construction budget; 6. The Owner has reviewed the Schematic Design Documents; 7. The Architect has modified the Schematic Design Documents to conform with the Owner, budget reconciliation and request the Owner’s approvalreview comments. The modifications shall be as mutually agreed by the Architect and Owner to establish a revised construction scope which is within the budget constraints.