Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Quality Assurance Program An employee shall be entitled to leave of absence without loss of earnings from her or his regularly scheduled working hours for the purpose of writing examinations required by the College of Nurses of Ontario arising out of the Quality Assurance Program.
Quality Assurance The parties endorse the underlying principles of the Company’s Quality Management System, which seeks to ensure that its services are provided in a manner which best conforms to the requirements of the contract with its customer. This requires the Company to establish and maintain, implement, train and continuously improve its procedures and processes, and the employees to follow the procedures, document their compliance and participate in the improvement process. In particular, this will require employees to regularly and reliably fill out documentation and checklists to signify that work has been carried out in accordance with the customer’s specific requirements. Where necessary, training will be provided in these activities.
Training and Professional Development 11.1 The Employer will develop and maintain an employee training and development plan and provide such plan to the Union upon request. Staff training is intended to provide an opportunity for classified staff employees for training sponsored by the University Training and Development and the UW Medical Centers Organizational Development and Training. Education/Professional Leave is intended to facilitate employee access to continuing education opportunities. Training and educational/professional leave may be used for the purpose of improving job performance, maintaining and increasing proficiency, preparing staff for greater responsibility, or increasing promotional opportunities within the framework of staff positions available at the University.
11.2 Any release time for training for employees accepted for such classes shall be in accordance with the Executive Order (currently No. 52) governing this matter. In the event that two or more employees request the same training period and supervision must limit the number of persons who may participate at one time due to work requirements, the selection will be made on a mutually agreeable basis within the department.
11.3 The training program is a proper subject for discussion by either departmental or University-wide Joint Union/Management Committees.
11.4 If the Employer requires an employee to receive training, reimbursement will be provided in accordance with the University travel rules. Employee attendance at Employer required training, either during or outside working hours, will be considered time worked and compensated in accordance with the provisions of this Agreement.
11.5 Employee attendance at training not required by the Employer and not covered by Executive Order 52, either on approved leave from or outside of working hours, will be voluntary and not considered time worked.
Attachment A, Scope of Services The scope of services is amended as follows:
Scope of Professional Services 3.1 On the terms and conditions set forth in this Agreement, COUNTY hereby engages CONTRACTOR to provide all labor, materials and equipment to complete the Project/Service in accordance with the Scope of Services, attached hereto and incorporated herein as Attachment A, as modified or clarified by Addendum(s) # , dated , attached hereto and incorporated herein by reference as Attachment B. It is understood that the Scope of Services may be modified by change order as the Project/Service progresses, but to be effective and binding, any such change order must be in writing, executed by the parties, and in accordance with the COUNTY’s Purchasing Policies and Procedures. A copy of these policies and procedures shall be made available to the CONTRACTOR upon request.
3.2 The term of this Agreement shall be as follows (please check box): The parties acknowledge that this is a project specific agreement and that the single Project/Service shall be completed by the CONTRACTOR within ( ) calendar days after the Notice to Proceed is issued. The CONTRACTOR and COUNTY acknowledge that this Agreement is for a twelve (12) month term and that the CONTRACTOR shall complete the work as specified in the Scope of Services. The COUNTY has the option to renewal this Agreement for four (4) additional one (1) year period(s). The prices set forth in this Agreement shall prevail for the full duration of the initial contract term unless otherwise indicated elsewhere in this document. Prior to completion of each exercised contract term, the COUNTY may consider an adjustment to price based on changes in the following pricing index: CPI. It is the CONTRACTOR’s responsibility to request any pricing adjustment in writing under this provision. The CONTRACTOR’s written request for adjustment should be submitted thirty (30) calendar days prior to expiration of the then current contract term and clearly substantiate the requested increase. The written request for adjustment should not be in excess of the relevant pricing index change. If no adjustment request is received from the CONTRACTOR, the COUNTY will assume that the CONTRACTOR has agreed that the optional term may be exercised without pricing adjustment. Any adjustment request received after the commencement of a new option period shall not be considered. The COUNTY reserves the right to reject any written price adjustments submitted by the CONTRACTOR and/or to not exercise any otherwise available option period based on such price adjustments. Continuation of the contract beyond the initial period, and any option subsequently exercised, is a COUNTY’s prerogative, and not a right of the CONTRACTOR. This prerogative will be exercised only when such continuation is clearly in the best interest of the COUNTY. All work shall be performed in accordance with good commercial practice. The work schedule and completion dates shall be adhered to by the CONTRACTOR except in such cases where the completion date will be delayed due to acts of God, strikes, or other causes beyond the control of the CONTRACTOR. In these cases, the CONTRACTOR shall notify the COUNTY of the delays in advance of the original completion so that a revised delivery schedule can be appropriately considered by the COUNTY. No additional days shall be granted for rain delays.
3.3 The CONTRACTOR shall be solely responsible for obtaining all necessary approvals and permits to complete the Project/Service.
3.4 The CONTRACTOR shall remain appropriately licensed and/or employ the services of a subcontractor who is appropriately licensed throughout the course of the Project/Service. Failure to maintain all required licenses shall entitle the COUNTY, at its option, to terminate this Agreement.
3.5 Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency facility may be added to this Agreement at the option of the County. When required by the pricing structure of the Agreement, the CONTRACTOR shall be invited to submit price quotes for these additional facilities. The additional site(s) shall be added to this Agreement by formal modification. The COUNTY may obtain price quotes for the additional facilities from other vendors in the event that fair and reasonable pricing is not obtained from the CONTRACTOR or for other reasons at the County’s discretion. Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency may delete service for any facility when such service is no longer required, upon fourteen (14) calendar days written notice.
3.6 The CONTRACTOR acknowledges that it has sufficient understanding of the nature and location of the work; the general and local conditions, including but not limited to, those bearing upon transportation, disposal, handling and storage of materials; availability of labor, water, electric power, and roads; and uncertainties of weather or similar physical conditions at the site; the character of equipment and facilities needed preliminary to and during the completion of the Project/Service. The CONTRACTOR further acknowledges that the CONTRACTOR has satisfied itself as to the character, quality and quantity of surface and subsurface materials, obstacles or conditions of the site. Any failure by the CONTRACTOR to acquaint itself with any aspect of the work or with any of the applicable conditions shall not relieve the CONTRACTOR from responsibility for adequately evaluating the difficulty or cost of successfully performing the work required, nor shall it be considered a basis for any claim for additional time or compensation. The COUNTY assumes no responsibility for any conclusions or interpretations made by the CONTRACTOR on the basis of the information made available by the COUNTY. The COUNTY also assumes no responsibility for any understanding or representations made by its officers or agents during or prior to the execution of this contract, unless such understanding or interpretations are made in writing and incorporated herein by reference.
3.7 If required, the Contractors shall attend a mandatory pre-bid meeting. Whether or not there is a mandatory or non-mandatory pre-bid, the contractor shall be required to carefully examine any supplied drawings and/or specifications and be thoroughly aware regarding any and all conditions that may in any manner affect the work to be performed under the contract. If a pre-bid meeting is not required the Contractor shall visit the site to familiarize themselves with the Project/Service, see existing conditions, and take measurements. No additional allowances will be made for lack of knowledge of these conditions.
3.8 In the event of any conflict between the drawings and specifications contained within this Agreement, the following shall govern:
A. Addenda shall supersede all other contract documents to the extent specified in the addenda. Subsequent addenda shall supersede prior to addenda only to the extent specified therein.
B. Drawings and specifications are intended to agree and be mutually complete. Any item not contained within the drawings, but contained in the specifications, or vice-versa, shall be provided and/or executed as shown in either the drawing or specification at no extra costs to the COUNTY. Should anything not included in either the drawing and/or the specifications be necessary for the proper construction and/or operation of the Project/Service as herein specified, or should any error or disagreement between the specifications and drawings exist or appear to exist, the CONTRACTOR shall not derive unjust benefit thereby, or use such disagreement counter to the best interests of the COUNTY. The CONTRACTOR shall immediately notify the COUNTY’s Project Manager of any discrepancy and await the Project Manager’s direction before proceeding with the work in question.
3.9 CONTRACTOR acknowledges and agrees that CONTRACTOR shall utilize the U.S. Department of Homeland Security’s E-Verify system in accordance with the terms governing use of the system to confirm the employment eligibility of:
A. All persons employed by the CONTRACTOR during the term of this Agreement to perform employment duties within Lake County; and
B. All persons, including subcontractors, assigned by the CONTRACTOR to perform work pursuant to the contract.
3.10 CONTRACTOR acknowledges and agrees that, in accordance with Section 255.099, Florida Statutes, if the Project/Service assigned to CONTRACTOR is being supported in whole or in part by State funding the CONTRACTOR shall give preference to the employment of state residents in the performance of the work on the Project/Service if state residents have substantially equal qualifications to those of non- residents. If the CONTRACTOR is required to employ state residents, the CONTRACTOR shall contact the Department of Economic Opportunity to post the employment needs in the State’s job bank system. However, in work involving the expenditure of federal aid funds, this section may not be enforced in such a manner as to conflict with or be contrary to federal law prescribing a labor preference to honorably discharged soldiers, sailors, or marines, or prohibiting as unlawful any other preference or discrimination among the citizens of the United States.
Training and Orientation (a) No employee shall be required to work on any job or operate any piece of equipment until he/she has received proper training and instruction.
(b) The Employer shall provide sufficient and adequate training and/or orientation to any employee working in a new or unfamiliar work area or position.
Quality Management Grantee will:
1. comply with quality management requirements as directed by the System Agency.
2. develop and implement a Quality Management Plan (QMP) that conforms with 25 TAC § 448.504 and make the QMP available to System Agency upon request. The QMP must be developed no later than the end of the first quarter of the Contract term.
3. update and revise the QMP each biennium or sooner, if necessary. Xxxxxxx’s governing body will review and approve the initial QMP, within the first quarter of the Contract term, and each updated and revised QMP thereafter. The QMP must describe Xxxxxxx’s methods to measure, assess, and improve -
i. Implementation of evidence-based practices, programs and research-based approaches to service delivery;
ii. Client/participant satisfaction with the services provided by Xxxxxxx;
iii. Service capacity and access to services;
iv. Client/participant continuum of care; and
v. Accuracy of data reported to the state.
4. participate in continuous quality improvement (CQI) activities as defined and scheduled by the state including, but not limited to data verification, performing self-reviews; submitting self-review results and supporting documentation for the state’s desk reviews; and participating in the state’s onsite or desk reviews.
5. submit plan of improvement or corrective action plan and supporting documentation as requested by System Agency.
6. participate in and actively pursue CQI activities that support performance and outcomes improvement.
7. respond to consultation recommendations by System Agency, which may include, but are not limited to the following:
i. Staff training;
ii. Self-monitoring activities guided by System Agency, including use of quality management tools to self-identify compliance issues; and
iii. Monitoring of performance reports in the System Agency electronic clinical management system.
Professional Conduct Any Firm providing legal services to Citizens shall ensure that its personnel complies with all applicable standards of ethics and rules of professional responsibility, including the Florida Rules of Professional Conduct promulgated by the Florida Supreme Court for attorneys practicing in Florida (or similar standards applicable to attorneys practicing outside the State of Florida). Such standards include rules related to conflicts of interest and confidentiality that are intended to protect Citizens and Citizens’ information. Additionally, in keeping with the vision and mission of Citizens as entrusted by the Florida legislature, Citizens expects all attorneys and legal professionals acting on its behalf, or on behalf of Citizens’ insureds, to adhere to the initiatives for Professional Conduct as promoted by the Florida Bar Center for Professionalism. On January 30, 2015 the Florida Bar Board of Governors approved “Professionalism Expectations.” In keeping with the vision and mission of Citizens as entrusted by the Florida legislature, Citizens expects all attorneys and legal professionals acting on its behalf, or on behalf of Citizens’ insureds, to adhere to the letter and spirit of Professional Conduct as promoted by the Florida Bar’s Standing Committee on Professionalism expressed within this document.
