Special Events For the purposes of this Agreement, “special events” are defined as:
Additional Events of Default Section 4.1 For purposes of this Supplemental Indenture and the Notes, in addition to the Events of Default set forth in Section 501 of the Indenture, each of the following also shall constitute an “Event of Default:”
(a) default in the payment of the principal of or any premium on the Notes at Maturity;
(b) there shall occur a default under any bond, debenture, note or other evidence of indebtedness of the Company, or under any mortgage, indenture or other instrument of the Company (including a default with respect to Securities of any series other than that series) under which there may be issued or by which there may be secured any indebtedness of the Company (or by any Subsidiary, the repayment of which the Company has guaranteed or for which the Company is directly responsible or liable as obligor or guarantor), whether such indebtedness now exists or shall hereafter be created, which default shall constitute a failure to pay an aggregate principal amount exceeding $10,000,000 of such indebtedness when due and payable after the expiration of any applicable grace period with respect thereto and shall have resulted in such indebtedness in an aggregate principal amount exceeding $10,000,000 becoming or being declared due and payable prior to the date on which it would otherwise have become due and payable, without such indebtedness having been discharged, or such acceleration having been rescinded or annulled, within a period of 10 days after there shall have been given, by first class mail, to the Company by the Trustee or to the Company and the Trustee by the Holders of at least a majority in principal amount of the Outstanding Notes a written notice specifying such default and requiring the Company to cause such indebtedness to be discharged or cause such acceleration to be rescinded or annulled and stating that such notice is a “Notice of Default” under the Indenture; and
(c) the entry by a court of competent jurisdiction of one or more judgments, orders or decrees against the Company or any of its Subsidiaries in an aggregate amount (excluding amounts covered by insurance) in excess of $10,000,000 and such judgments, orders or decrees remain undischarged, unstayed and unsatisfied in an aggregate amount (excluding amounts covered by insurance) in excess of $10,000,000 for a period of 30 consecutive days.
Section 4.2 Notwithstanding any provisions to the contrary in the Indenture, upon the acceleration of the Notes in accordance with Section 502 of the Indenture, the amount immediately due and payable in respect of the Notes shall equal the Outstanding principal amount thereof, plus accrued and unpaid interest, plus the Make-Whole Amount.
Liquidity Events of Default If (a) any Liquidity Event of Default has occurred and is continuing and (b) there is a Performing Note Deficiency, the Liquidity Provider may, in its discretion, deliver to the Borrower a Termination Notice, the effect of which shall be to cause (i) the obligation of the Liquidity Provider to make Advances hereunder to expire on the fifth Business Day after the date on which such Termination Notice is received by the Borrower, (ii) the Borrower to promptly request, and the Liquidity Provider to promptly make, a Final Advance in accordance with Section 2.02(d) hereof and Section 3.5(i) of the Intercreditor Agreement, (iii) all other outstanding Advances to be automatically converted into Final Advances for purposes of determining the Applicable Liquidity Rate for interest payable thereon, and (iv) subject to Sections 2.07 and 2.09 hereof, all Advances (including, without limitation, any Provider Advance and Applied Provider Advance), any accrued interest thereon and any other amounts outstanding hereunder to become immediately due and payable to the Liquidity Provider.
Notice of Events of Default The Issuer shall give a Responsible Officer of the Indenture Trustee and each Rating Agency prompt written notice of each Event of Default hereunder and each default on the part of the Servicer or the Seller of its obligations under the Sale and Servicing Agreement.
Material Events any other event occurs or circumstance arises which, in the opinion of the Agent (following consultation with the Banks), is likely materially and adversely to affect either (i) the ability of any Security Party to perform all or any of its obligations under or otherwise to comply with the terms of any of the Security Documents or (ii) the security created by any of the Security Documents; or
Actions following an Event of Default On, or at any time after, the occurrence and during the continuation of an Event of Default:
(a) the Agent may, and if so instructed by the Majority Lenders, the Agent shall:
(i) serve on the Borrowers a notice stating that all or part of the Commitments and of the other obligations of each Lender to the Borrowers under this Agreement are cancelled; and/or
(ii) serve on the Borrowers a notice stating that all or part of the Loan together with accrued interest and all other amounts accrued or owing under this Agreement are immediately due and payable or are due and payable on demand; and/or
(iii) take any other action which, as a result of the Event of Default or any notice served under paragraph (i) or (ii), the Agent and/or the Lenders are entitled to take under any Finance Document or any applicable law; and/or
(b) the Security Trustee may, and if so instructed by the Agent, acting with the authorisation of the Majority Lenders, the Security Trustee shall take any action which, as a result of the Event of Default or any notice served under paragraph (a)(i) or (a)(ii), the Security Trustee, the Agent and/or the Lenders and/or the Swap Counterparties are entitled to take under any Finance Document or any applicable law.
Special Event Redemption Prior to March 30, 2010, upon the occurrence and during the continuation of a Special Event, the Company may, at its option, redeem the Securities, in whole but not in part, at a Redemption Price equal to one hundred seven and one half percent (107.5%) of the principal amount thereof, together, in the case of any such redemption, with accrued interest, including any Additional Interest, through but excluding the date fixed as the Redemption Date (the “Special Redemption Price”).
Indirect Political Event An Indirect Political Event shall mean one or more of the following acts or events:
(a) an act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo, riot, insurrection, terrorist or military action, civil commotion or politically motivated sabotage;
(b) industry-wide or State-wide strikes or industrial action for a continuous period of 24 (twenty four) hours and exceeding an aggregate period of 7 (seven) days in an Accounting Year;
(c) any civil commotion, boycott or political agitation which prevents collection of Fee by the Concessionaire for an aggregate period exceeding 7 (seven) days in an Accounting Year;
(d) any failure or delay of a Contractor to the extent caused by any Indirect Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(e) any Indirect Political Event that causes a Non-Political Event; or
(f) any event or circumstances of a nature analogous to any of the foregoing.
Events of Default and Termination Events The following Events of Default and Termination Events shall apply to Party A and Party B as set forth below:
Political Event A Political Event shall mean one or more of the following acts or events by or on account of any Government Instrumentality:
(a) Change in Law, only if consequences thereof cannot be dealt with under and in accordance with the provisions of Article 37 and its effect, in financial terms, exceeds the sum specified in Clause 37.1;
(b) compulsory acquisition in national interest or expropriation of any Project Assets or rights of the Concessionaire or of the Contractors;
(c) unlawful or unauthorised or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Concessionaire or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Concessionaire's or any Contractor's inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, licence, authorisation, no objection certificate, exemption, consent, approval or permit;
(d) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; or
(e) any event or circumstance of a nature analogous to any of the foregoing.
