PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.
Service Delivery Grantee shall:
Notification of Delivery Destination Prior to final acceptance of contract requirements by STATE, PURCHASER shall notify STATE, in a form and manner prescribed by STATE, of the delivery destination of all timber purchased under this contract. STATE may hold PURCHASER's performance bond until satisfactory delivery destination information has been received. Notice of Transfer of State Timber. Prior to selling, trading, exchanging, or otherwise conveying unprocessed timber sold under this contract to any other person, PURCHASER must first obtain a certification of the person's eligibility to purchase unprocessed State timber, and their intent to comply with the terms and conditions contained in OAR 629-031-0005 through 629-031-0045. The certification shall be made in a form and manner prescribed by STATE, and shall be forwarded to STATE upon completion of the transaction. Obtaining the certification shall not relieve PURCHASER of the responsibility to provide STATE with an accounting of the delivery destination of that timber.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract. Delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor, unless otherwise agreed to by the Authorized User and the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of a Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000-000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent flooring inspector to verify the Warranty Holder’s warranty claims. The determination of the flooring inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/geowood-flooring-warranty/. Warranty Exclusions and Limitations: This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s GeoWood flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and (ii) maintained in accordance with Cali Bamboo’s GeoWood flooring care and maintenance guidelines found online at xxxxx://xxx.xxxxxxxxxx.xxx/floor-care-and-maintenance/ (the “Maintenance Guide”). Cali Bamboo will provide copies of these guides upon request by the Warranty Holder. This limited warranty only applies when the Flooring is used under normal traffic and other usage conditions. The limited warranty for Manufacturing Defects does not apply after the Warranty Holder has installed the Flooring, and product variation or error that does not exceed the 5% industry standard is not considered a Manufacturing Defect for purposes of this limited warranty. This limited warranty does not extend to or cover:
Training Delivery Type Code -- Code Short Description Long Description (If Applicable) 01 Traditional Classroom (no technology)
Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded Vendor under this Agreement when the TIPS Member desires goods or services awarded to the Vendor. Notification may occur via phone, the web, courier, email, fax, or in person. Upon notification of a pending request, the awarded Vendor shall acknowledge the TIPS Member’s request as soon as possible, but must make contact with the TIPS Member within two working days. Status of TIPS Members as Related to This Agreement TIPS Members stand in the place of TIPS as related to this agreement and have the same access to the proposal information and all related documents. TIPS Members have all the same rights under the awarded Agreement as TIPS.
Non-Compliant Delivery Overshipments and/or early deliveries may be returned at Supplier’s sole expense, or DXC may delay processing the early delivery invoice until the Delivery Date.
Overnight Delivery When delivered by an overnight delivery service, charges prepaid or charged to the sender’s account, notice is effective on delivery, if delivery is confirmed by the delivery service.