Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
CAISO Monthly Billed Fuel Cost [for Geysers Main only] The CAISO Monthly Billed Fuel Cost is given by Equation C2-1. CAISO Monthly Billed Fuel Cost Equation C2-1 = Billable MWh ◆ Steam Price ($/MWh) Where: • Steam Price is $16.34/MWh. • For purposes of Equation C2-1, Billable MWh is all Billable MWh Delivered after cumulative Hourly Metered Total Net Generation during the Contract Year from all Units exceeds the Minimum Annual Generation given by Equation C2-2. Equation C2-2 Minimum Annual Generation = (Annual Average Field Capacity ◆ 8760 hours ◆ 0.4) - (A+B+C) Where: • Annual Average Field Capacity is the arithmetic average of the two Field Capacities in MW for each Contract Year, determined as described below. Field Capacity shall be determined for each six-month period from July 1 through December 31 of the preceding calendar year and January 1 through June 30 of the Contract Year. Field Capacity shall be the average of the five highest amounts of net generation (in MWh) simultaneously achieved by all Units during eight-hour periods within the six-month period. The capacity simultaneously achieved by all Units during each eight-hour period shall be the sum of Hourly Metered Total Net Generation for all Units during such eight-hour period, divided by eight hours. Such eight-hour periods shall not overlap or be counted more than once but may be consecutive. Within 30 days after the end of each six-month period, Owner shall provide CAISO and the Responsible Utility with its determination of Field Capacity, including all information necessary to validate that determination. • A is the amount of Energy that cannot be produced (as defined below) due to the curtailment of a Unit during a test of the Facility, a Unit or the steam field agreed to by CAISO and Owner. • B is the amount of Energy that cannot be produced (as defined below) due to the retirement of a Unit or due to a Unit’s Availability remaining at zero after a period of ten Months during which the Unit’s Availability has been zero. • C is the amount of Energy that cannot be produced (as defined below) because a Force Majeure Event reduces a Unit’s Availability to zero for at least thirty (30) days or because a Force Majeure Event reduces a Unit’s Availability for at least one hundred eighty (180) days to a level below the Unit Availability Limit immediately prior to the Force Majeure Event. • The amount of Energy that cannot be produced is the sum, for each Settlement Period during which the condition applicable to A, B or C above exists, of the difference between the Unit Availability Limit immediately prior to the condition and the Unit Availability Limit during the condition.
Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Supervisory Differential Adjustment 99. The Appointing Officer may adjust the compensation of a supervisory employee whose schedule of compensation is set herein subject to the following conditions:
GMP Cost Limitation The Guaranteed Maximum Price shall not be in excess of the GMP Cost Limitation.
Construction Cost Adjustment Contracting Officer, as provided in B5.21, B5.212, B5.251, B5.252, and B5.253, shall adjust Specified Road construction cost estimates in the Schedule of Items and show the adjustments as credits or debits to Timber Sale Account in the month when the road segment is accepted.
Least-cost Selection Services for assignments which the Association agrees meet the requirements of paragraph 3.6 of the Consultant Guidelines may be procured under contracts awarded on the basis of Least-cost Selection in accordance with the provisions of paragraphs 3.1 and 3.6 of the Consultant Guidelines.
Construction Cost 3.1. Construction Cost does not include the fees of the ARCHITECT/ENGINEER and consultants, the cost of the land, rights- of-way, or other costs, which is the responsibility of the State as provided in Paragraphs 2.2 through 2.3. or any of the contingencies available for the project unless specifically stated otherwise.
Cost 5.2.1.2. Ability to meet completion dates in proposed project schedule
Workforce Adjustment (a) The Parties recognize that workforce adjustment may be necessary due to the elimination of positions resulting from a reduction in the amount of work required to be done by the Commission, reorganization or program termination.
