Suspension by the Design Professional for Nonpayment Sample Clauses

Suspension by the Design Professional for Nonpayment. If the Owner should fail to pay the Design Professional or provide a proper notice of dispute of the invoice within sixty calendar days of presentation of a proper notice pursuant to Paragraph 4.1.4.5, then the Design Professional may, upon seven calendar days written notice to the Owner, suspend services or terminate this Contract and recover from the Owner payment for all services properly performed and expenses properly incurred through the date of suspension. Upon payment, all drawings, specifications and other documents relating to the design of the Project or Construction Contract Administration of the work shall be surrendered forthwith by the Design Professional to the Owner. The Design Professional shall have no liability to the Owner for damage or the delay of the Project resulting from a proper suspension or termination. The Owner will pay reasonable costs incurred by the Design Professional as a result of the proper suspension or termination. If the services are resumed, reasonable adjustments to the Design Professional’s compensation and the Project schedule will be made.
Sample 1Sample 2Sample 3See All (47)
AutoNDA by SimpleDocs
Suspension by the Design Professional for Nonpayment. If the Owner should fail to pay the Design Professional amounts due and payable hereunder, then sixty (60) days after Owner receives the Notice specified in Section 4.1.13, Design Professional may, upon seven (7) additional calendar days written Notice to the Owner, suspend services or terminate this Contract and recover from the Owner payment for all services properly performed and expenses properly incurred through the date of suspension in the amounts provided hereunder. No right to suspend or terminate will arise from Owner’s nonpayment of amounts not properly due and payable, amounts deducted or withheld pursuant to any provision hereunder, or amounts subject to a dispute under Section 5. Upon payment, all drawings, specifications and other documents relating to the design of the Project or Construction Contract Administration of the Work shall be surrendered forthwith by the Design Professional to the Owner. The Design Professional shall have no liability to the Owner for damage or the delay of the Project resulting from a proper suspension or termination. The Owner will pay reasonable costs incurred by the Design Professional as a result of the proper suspension or termination. If services are resumed after a proper suspension, then reasonable adjustments to the Design Professional’s compensation and the Project schedule will be made.
Sample 1

Related to Suspension by the Design Professional for Nonpayment

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Termination by ICANN (a) ICANN may, upon notice to Registry Operator, terminate this Agreement if: (i) Registry Operator fails to cure (A) any fundamental and material breach of Registry Operator’s representations and warranties set forth in Article 1 or covenants set forth in Article 2, or (B) any breach of Registry Operator’s payment obligations set forth in Article 6 of this Agreement, each within thirty (30) calendar days after ICANN gives Registry Operator notice of such breach, which notice will include with specificity the details of the alleged breach, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in fundamental and material breach of such covenant(s) or in breach of its payment obligations, and (iii) Registry Operator fails to comply with such determination and cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction. (b) ICANN may, upon notice to Registry Operator, terminate this Agreement if Registry Operator fails to complete all testing and procedures (identified by ICANN in writing to Registry Operator prior to the date hereof) for delegation of the TLD into the root zone within twelve (12) months of the Effective Date. Registry Operator may request an extension for up to additional twelve (12) months for delegation if it can demonstrate, to ICANN’s reasonable satisfaction, that Registry Operator is working diligently and in good faith toward successfully completing the steps necessary for delegation of the TLD. Any fees paid by Registry Operator to ICANN prior to such termination date shall be retained by ICANN in full. (c) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator fails to cure a material breach of Registry Operator’s obligations set forth in Section 2.12 of this Agreement within thirty (30) calendar days of delivery of notice of such breach by ICANN, or if the Continued Operations Instrument is not in effect for greater than sixty (60) consecutive calendar days at any time following the Effective Date, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in material breach of such covenant, and (iii) Registry Operator fails to cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction. (d) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator makes an assignment for the benefit of creditors or similar act, (ii) attachment, garnishment or similar proceedings are commenced against Registry Operator, which proceedings are a material threat to Registry Operator’s ability to operate the registry for the TLD, and are not dismissed within sixty (60) calendar days of their commencement, (iii) a trustee, receiver, liquidator or equivalent is appointed in place of Registry Operator or maintains control over any of Registry Operator’s property, (iv) execution is levied upon any material property of Registry Operator, (v) proceedings are instituted by or against Registry Operator under any bankruptcy, insolvency, reorganization or other laws relating to the relief of debtors and such proceedings are not dismissed within sixty (60) calendar days of their commencement, or (vi) Registry Operator files for protection under the United States Bankruptcy Code, 11 U.S.C. Section 101, et seq., or a foreign equivalent or liquidates, dissolves or otherwise discontinues its operations or the operation of the TLD. (e) ICANN may, upon thirty (30) calendar days’ notice to Registry Operator, terminate this Agreement pursuant to Section 2 of Specification 7 or Sections 2 and 3 of Specification 11, subject to Registry Operator’s right to challenge such termination as set forth in the applicable procedure described therein. (f) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator knowingly employs any officer who is convicted of a misdemeanor related to financial activities or of any felony, or is judged by a court of competent jurisdiction to have committed fraud or breach of fiduciary duty, or is the subject of a judicial determination that ICANN reasonably deems as the substantive equivalent of any of the foregoing and such officer is not terminated within thirty (30) calendar days of Registry Operator’s knowledge of the foregoing, or (ii) any member of Registry Operator’s board of directors or similar governing body is convicted of a misdemeanor related to financial activities or of any felony, or is judged by a court of competent jurisdiction to have committed fraud or breach of fiduciary duty, or is the subject of a judicial determination that ICANN reasonably deems as the substantive equivalent of any of the foregoing and such member is not removed from Registry Operator’s board of directors or similar governing body within thirty (30) calendar days of Registry Operator’s knowledge of the foregoing. (g) ICANN may, upon thirty (30) calendar days’ notice to Registry Operator, terminate this Agreement as specified in Section 7.5. (h) [Applicable to intergovernmental organizations or governmental entities only.] ICANN may terminate this Agreement pursuant to Section 7.16.

  • Termination by the University i) The university may terminate this agreement under the following circumstances:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!