Termination of Purchase Order For Convenience Sample Clauses

Termination of Purchase Order For Convenience. DMC Stratex may terminate any Purchase Order, in whole or part, at any time, by giving written notice to MTI specifying the extent to which performance under the Purchase Order is terminated. Immediately upon receipt of such notice, MTI shall stop performing under the Purchase Order, and within six (6) weeks after such notice, MTI shall submit to DMC Stratex its written termination claim. Failure of MTI to submit its termination claim as provided herein shall constitute an unconditional and absolute waiver by MTI of any claim arising from DMC Stratex's notice termination, except where the damage or claim in connection with such termination is not assessable or determinable within such six (6) week period but only if MTI submits such damage claim as soon as it is finally assessed or determined. MTI shall reasonably assess its damage to determine whether or not any excess items may be used by MTI for the manufacture of associated products or diverted for any other purpose, and to correspondingly reduce MTI's termination claim by the value of such items, and MTI shall exercise commercially reasonable effort to so divert or otherwise dispose of such items to reduce its termination claim. When settlement has been made, title to any such items determined not useable by MTI and charged to DMC Stratex in the termination claim shall vest in DMC Stratex upon payment of the claim and forthwith be delivered to DMC Stratex at DMC Stratex's expense, under DMC Stratex's shipping instructions; provided that MTI shall be entitled to dispose of such items at its own discretion if DMC Stratex does not instruct on delivery to DMC Stratex or other disposition of such items within six (6) months after the settlement of the termination claim. In no event shall MTI be entitled to incidental or consequential damages, attorney's fees or agent's commissions as a result of DMC Stratex's termination in accordance with this Section 7.6. DMC Stratex reserves the right to verify claims hereunder, within sixty (60) calendar days after receipt of MTI's termination claim, and MTI shall make available to DMC Stratex upon its request, all relevant books, records, inventories and facilities for DMC Stratex's inspection and audit. DMC Stratex shall not unreasonably withhold, and shall promptly pay within five (5) calendar days following MTI's termination claim, the undisputed compensation or payment for the damages arising from DMC Stratex's termination for convenience set forth in this Section...
AutoNDA by SimpleDocs

Related to Termination of Purchase Order For Convenience

  • Termination for Convenience TIPS may, by written notice to Vendor, terminate this Agreement for convenience, in whole or in part, at any time by giving thirty (30) days’ written notice to Vendor of such termination, and specifying the effective date thereof.

  • Cancellation for convenience 19.1 The Commonwealth may cancel this Agreement by notice, due to (a) a change in government policy; or (b) a Change in the Control of the Grantee, which the Commonwealth believes will negatively affect the Grantee’s ability to comply with this Agreement. 19.2 The Grantee agrees on receipt of a notice of cancellation under clause 19.1 to: (a) stop the performance of the Grantee's obligations as specified in the notice; and (b) take all available steps to minimise loss resulting from that cancellation. 19.3 In the event of cancellation under clause 19.1, the Commonwealth will be liable only to: (a) pay any part of the Grant due and owing to the Grantee under this Agreement at the date of the notice; and (b) reimburse any reasonable expenses the Grantee unavoidably incurs that relate directly to the cancellation and are not covered by 19.3(a). 19.4 The Commonwealth’s liability to pay any amount under this clause is subject to: (a) the Grantee's compliance with this Agreement; and (b) the total amount of the Grant. 19.5 The Grantee will not be entitled to compensation for loss of prospective profits or benefits that would have been conferred on the Grantee.

  • Termination for Convenience of City The City shall have the right at any time by written notice to Contractor to terminate and cancel this contract, without cause, for the convenience of the City, and Contractor shall immediately stop work. In such event City shall not be liable to Contractor except for payment for actual work performed prior to such notice in an amount proportionate to the completed contract price and for the actual costs of preparations made by Contractor for the performance of the cancelled portions of the contract, including a reasonable allowance of profit applicable to the actual work performed and such preparations. Anticipatory profits and consequential damages shall not be recoverable by Contractor.

  • Termination by the Owner for Convenience § 13.2.4.1 The Owner may, at any time, terminate the Contract for the Owner’s convenience and without cause. § 13.2.4.2 Upon receipt of written notice from the Owner of such termination for the Owner’s convenience, the Design-Builder shall

  • Cancellation or reduction for convenience 20.1 The Commonwealth may cancel or reduce the scope of this Agreement by notice, due to: (a) a change in government policy; or (b) a Change in the Control of the Grantee which the Commonwealth reasonably believes will negatively affect the Grantee’s ability to comply with this Agreement. 20.2 On receipt of a notice of reduction or cancellation under this clause, the Grantee agrees to: (a) stop or reduce the performance of the Grantee's obligations as specified in the notice; and (b) take all available steps to minimise loss resulting from that reduction or cancellation; and (c) continue performing any part of the Activity or the Agreement not affected by the notice if requested to do so by the Commonwealth; (d) report on, and return any part of the Grant to the Commonwealth, or otherwise deal with the Grant, as directed by the Commonwealth. 20.3 In the event of reduction or cancellation under this clause, the Commonwealth will be liable only to: (a) pay any part of the Grant due and owing to the Grantee under this Agreement at the date of the notice; and (b) reimburse any reasonable and substantiated expenses the Grantee unavoidably incurs that relate directly and entirely to the reduction in scope or cancellation of the Agreement. 20.4 In the event of reduction, the amount of the Grant will be reduced in proportion to the reduction in the scope of the Agreement. 20.5 The Commonwealth’s liability to pay any amount under this clause is: (a) subject to the Grantee's compliance with this Agreement; and (b) limited to an amount that when added to all other amounts already paid under the Agreement will not exceed the total amount of the Grant. 20.6 The Grantee will not be entitled to compensation for loss of prospective profits or benefits that would have been conferred on the Grantee but for the cancellation or reduction in scope of the Agreement under clause 20.1. 20.7 The Commonwealth will act reasonably in exercising its rights under this clause.

  • Termination for Cause and Convenience As detailed within Clause No. 3 of, Form HUD-5370-C, General Conditions for Non- Construction Contracts, Section I—(Within or without Maintenance Work).

  • For Convenience By written notice, this Contract may be terminated at any time by the Commissioner for convenience upon sixty calendar days written notice or other specified period without penalty or other early termination charges due. Such termination of the Contract shall not affect any project or Purchase Order that has been issued under the Contract prior to the date of such termination. If the Contract is terminated pursuant to this subdivision, the Authorized User shall remain liable for all accrued but unpaid charges incurred through the date of the termination. Contractor shall use due diligence and provide any outstanding deliverables.

  • Suspension for Convenience The School District shall have the right, at any time during the term of this Contract, to suspend all or any part of the Services, for the convenience of the School District, for the period of time that the School District, in its sole discretion, determines to be in the best interest of the School District, upon thirty (30) days’ prior written notice to the Architectural Designer (except that in the event of a public emergency, as determined by the School District, no such period of notice shall be required.). 13.2.1 If a suspension of the Services pursuant to this Paragraph 13.2 is for greater than thirty (30) days, the Architectural Designer shall have the right to submit a claim to the School District for the payment of costs for all Services performed and Reimbursable Expenses incurred in accordance with the provisions of this Contract prior to the effective date of the suspension. 13.2.2 The Architectural Designer shall be entitled to a one-day extension of the time of performance provided in this Contract for each day that it is suspended pursuant to this Paragraph 13.2. 13.2.3 The School District shall have the right, during the period of any suspension pursuant to this Paragraph 13.2, to terminate this Contract as provided in this Section 14, in Section 6, and elsewhere in this Contract.

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!