Time for Giving Notice Sample Clauses

Time for Giving Notice. The written general explanation or description regarding any optional forms of benefit available under the Plan shall be provided to a Participant or former Participant no less than 30 days and no more than 90 days before his Annuity Starting Date unless he legally waives this requirement.
Sample 1Sample 2Sample 3See All (15)
AutoNDA by SimpleDocs
Time for Giving Notice. Notice of dispute or potential Claim must be given in writing by the CONTRACTOR as follows: (a) For a potential Claim of an increase in the Contract Sum, CONTRACTOR shall give the AGENCY written notice thereof within ten (10) days after the occurrence of the event giving rise to such Claim; in addition, this notice shall be given by CONTRACTOR before proceeding to execute the portion of the Work to which the Claim relates, except in an emergency endangering life or property, and except where CONTRACTOR could not reasonably have discovered the facts giving rise to the Claim prior to commencement of that portion of the Work. (b) For a potential Claim of an extension of time, CONTRACTOR shall give written notice to the AGENCY no more than ten (10) days after the occurrence of the delay; otherwise they shall be waived. In the case of a continuing cause of delay, only one (1) Claim is necessary. (c) In all other cases, notice shall be given within ten (10) days after the happening of the event, thing, or occurrence giving rise to the potential Claim.
Sample 1
Time for Giving Notice. Notice of any Change(s) shall be given to you at least fifteen (15) days before the effective date that the change applies. EFTA requires twenty-one (21) days' notice for certain changes. If EFTA applies to a Change, we will provide twenty-one (21) days' notice. If any other federal or state law requires a longer notice period, we will comply with that requirement.
Sample 1
Time for Giving Notice. Except as specified below in this paragraph (b) or as permitted under paragraph (d), the QJSA Notice shall be provided to a Participant or former Participant no less than thirty days and no more than ninety days before his Annuity Starting Date. If the Participant or former Participant, after having received the QJSA Notice, affirmatively elects a form of distribution with the consent of the Participant or former Participant’s Spouse (if necessary), the thirty-day timing requirement of this paragraph (b) will not apply if all of the following conditions are satisfied: (1) the Sponsor informs the Participant or former Participant in writing that the Participant or former Participant has a right to at least thirty days to consider whether to waive the QJSA and consent to a form of distribution other than a QJSA, (2) the Participant or former Participant is permitted to revoke an affirmative distribution election at least until the Annuity Starting Date, or, if later, at any time prior to the expiration of the seven-day period that begins the day after the QJSA Notice is provided to the Participant or former Participant, (3) the Annuity Starting Date is after the date the QJSA Notice is provided to the Participant or former Participant, and (4) a distribution of the Participant or former Participant’s benefit in accordance with the Participant or former Participant’s affirmative election does not commence before the expiration of the seven-day period that begins the day after the QJSA Notice is provided to the Participant or former Participant. The ninety-day timing requirement of this paragraph (b) will not be failed merely because, due solely to administrative delay, a distribution commences more than ninety days after the QJSA Notice is provided to the Participant or former Participant.
Sample 1
Time for Giving Notice. The notice of claim must be given to the Project Manager as follows: (a) If the claim is for an increase in the contract sum, he shall give the Project Manager written notice thereof within ten (10) days after the occurrence of the event giving rise to such claim; in addition, this notice shall be given by the Contractor before proceeding to execute the portion of the work to which the claim relates, except in an emergency endangering life or property, and except where the Contractor could not reasonably have discovered the facts giving rise to the claim prior to commencement of that portion of the work. (b) All claims for extension of time shall be made, in writing, to the Project Manager no more than ten (10) days after the occurrence of the delay; otherwise they shall be waived. In the case of a continuing cause of delay, only one claim is necessary. (c) In all other cases, notice shall be given within ten (10) days after the happening of the event, thing, or occurrence giving rise to the claim.
Sample 1

Related to Time for Giving Notice

  • Giving Notice Except as otherwise permitted by Section 2.14 with respect to borrowing notices, all notices and other communications provided to any party hereto under the Agreement or any other Loan Document shall be in writing and addressed or delivered to such party at its address set forth below its signature hereto or at such other address (or to counsel for such party) as may be designated by such party in a notice to the other parties. Any notice, if mailed and properly addressed with postage prepaid, shall be deemed given when received; any notice, if transmitted by facsimile, shall be deemed given when transmitted.

  • Manner of Giving Notice All notices and other communications required by this Master Agreement must be in writing, and must be made via e-mail, personal service or United States mail, postage prepaid.

  • Method of Giving Notice Unless the Business Corporations Act or these Articles provides otherwise, a notice, statement, report or other record required or permitted by the Business Corporations Act or these Articles to be sent by or to a person may be sent by any one of the following methods: (1) mail addressed to the person at the applicable address for that person as follows: (a) for a record mailed to a shareholder, the shareholder’s registered address; (b) for a record mailed to a director or officer, the prescribed address for mailing shown for the director or officer in the records kept by the Company or the mailing address provided by the recipient for the sending of that record or records of that class; (c) in any other case, the mailing address of the intended recipient; (2) delivery at the applicable address for that person as follows, addressed to the person: (a) for a record delivered to a shareholder, the shareholder’s registered address; (b) for a record delivered to a director or officer, the prescribed address for delivery shown for the director or officer in the records kept by the Company or the delivery address provided by the recipient for the sending of that record or records of that class; (c) in any other case, the delivery address of the intended recipient; (3) sending the record by fax to the fax number provided by the intended recipient for the sending of that record or records of that class; (4) sending the record by email to the email address provided by the intended recipient for the sending of that record or records of that class; (5) physical delivery to the intended recipient.

  • Notice of Completion The Interconnection Customer shall notify the Transmission Provider and the Interconnected Transmission Owner in writing when it has completed construction of (i) the Customer Facility;

  • Notice to NASD In the event any person or entity (regardless of any NASD affiliation or association) is engaged to assist the Company in its search for a merger candidate or to provide any other merger and acquisition services, the Company will provide the following to the NASD and EBC prior to the consummation of the Business Combination: (i) complete details of all services and copies of agreements governing such services; and (ii) justification as to why the person or entity providing the merger and acquisition services should not be considered an "underwriter and related person" with respect to the Company's initial public offering, as such term is defined in Rule 2710 of the NASD's Conduct Rules. The Company also agrees that proper disclosure of such arrangement or potential arrangement will be made in the proxy statement which the Company will file for purposes of soliciting stockholder approval for the Business Combination.

  • Termination Warning Notice B The Secretary of State may serve a Termination Warning Notice where he considers that:

  • Advance Notice of Layoff Unless legislation is more favourable to the Employees, the Employer shall notify Employees who are laid off with a written notice thirty (30) calendar days prior to the effective date of layoff. If the Employee has not had the opportunity to work the days as provided in this Article, they shall be paid for the days for which work was not made available.

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • NOTICE TO BUYER Do not sign this agreement before you read it or if it contains any blank spaces. This is a legal instrument. All pages of this contract are binding. Read both sides of all pages before signing. You are entitled to an exact copy of the agreement, school catalog, and any other papers you may sign, and are required to sign a statement acknowledging receipt of those.

  • Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!