Unavoidable Delay; Extension of Time Sample Clauses

Unavoidable Delay; Extension of Time. Neither party hereunder shall be deemed to be in default, and performance shall be excused, where delays or defaults are caused by war, national disasters, terrorist attacks, insurrection, strikes, walkouts, riots, floods, earthquakes, fires, casualties, third-party lawsuits, or acts of God. If written notice of any such delay is given to one Party or the other within thirty (30) days after the commencement thereof, an automatic extension of time, unless otherwise objected to by the party in receipt of the notice within thirty (30) days of such written notice, shall be granted coextensive with the period of the enforced delay, or longer as may be required by circumstances or as may be subsequently agreed to between City and Master Developer.
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Unavoidable Delay; Extension of Time. ‌ Neither party hereunder shall be deemed to be in default, and performance shall be excused, where delays or defaults are caused by war, insurrections trikes, walkouts, riots, floods, earthquakes, fires casualties, acts of God, restrictions imposed or mandated by governmental entities, failure of governmental agencies (other than the City) to perform acts or deeds necessary to the performance of this Agreement, enactment of conflicting state or federal laws or regulations, new or supplementary environmental regulations, litigation or similar matters beyond the control of the parties. In addition, nonperformance of a party hereunder shall be excused as a result of the failure of the other party to perform under this Agreement which failure of the other party actually causes such nonperformance. If written notice of any such delay is given to the City within thirty (30) days after the commencement thereof, an automatic extension of time, unless otherwise objected to by the City within thirty (30) days of such written notice, shall be granted coextensive with the period of the enforced delay, or longer as may be required by circumstances or as may be subsequently agreed to between the City and Developer. Any such extensions of time shall have no effect upon the timing of and the conclusions reached in the reviews to be conducted pursuant to 5.1 above.
Sample 1
Unavoidable Delay; Extension of Time. Neither party hereunder shall be deemed to be in default, and performance shall be excused, where delays or defaults are caused by war, insurrection, strikes, walkouts, riots, floods, earthquakes, fires, casualties, acts of God, restrictions imposed or mandated by governmental entities, failure of governmental agencies (other than County) to perform acts or deeds necessary to the performance of this Agreement, enactment of conflicting state or federal laws or regulations, new or supplementary environmental regulations, litigation, or similar matters beyond the control of the parties (“Force Majeure”). In addition, nonperformance of a party hereunder shall be excused as a result of the failure of the other party to perform under this Agreement which failure of the other party actually causes such nonperformance. If written notice of any such delay is given to County within sixty (60) days after the commencement of a Force Majeure, an automatic extension of time, unless otherwise objected to by County within thirty (30) days of such written notice, shall be granted coextensive with the period of the Force Majeure, or longer as may be required by circumstances or as may be subsequently agreed to between County and Developer.
Sample 1
Unavoidable Delay; Extension of Time. Neither party hereunder shall be deemed to be in default, and performance shall be excused, where delays or defaults are caused by war, insurrection, strikes, walkouts, riots, floods, earthquakes, fires, casualties, or acts of God. If written notice of any such delay is given to one Party or the other within thirty (30) days after the commencement thereof, an automatic extension of time, unless otherwise objected to by the party in receipt of the notice within thirty (30) days of such written notice, shall be granted coextensive with the period of the enforced delay, or longer as may be required by circumstances or as may be subsequently agreed to between City and Master Developer. Any such extensions of time shall have no effect upon the timing of and the conclusions reached in the reviews to be conducted pursuant to Section 9 above.
Sample 1

Related to Unavoidable Delay; Extension of Time

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • Extension of Defects Liability Period The Defects Liability Period shall be deemed to be extended till the identified Defects under Clause 17.2 have been remedied or rectified.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!