Vendor Suspension Sample Clauses

Vendor Suspension. DIR's Right to Suspend Contract for Cause in accordance with this Section. DIR may suspend Vendor’s performance of this Contract, in whole or in part, for a period up to 180 calendar days by following the procedure in this paragraph. When a violation of the contract as set forth below occurs, DIR may send a Notice of Intent to Suspend to the Vendor providing the reasons for the proposed suspension. Vendor shall have five (5) business days from receipt of the Notice of Intent to Suspend to provide a written response. At the expiration of the 5 business days, DIR will make a determination whether a violation(s) of the contract occurred. In those instances where a violation is found to have occurred, DIR shall decide on a period of suspension up to 180 calendar days in length and send a written notice of the period of suspension and the related findings to Vendor. The suspension shall be effective from the date of receipt by Vendor. DIR may issue a Notice of Intent to Suspend under the proper circumstances, which include, but are not limited to the events listed below: 1) Vendor or Vendor's Worker(s) no longer holds necessary license(s) or certificate(s) required to perform the work under any Work Order; 2) Vendor falsifies an invoice for services or travel reimbursement; 3) Vendor is prohibited from contacting a Customer to discuss an “open” competitive solicitation during the Work Order Solicitation; however, Vendor is allowed to market their business to Customers. 4) Vendor or its Workers have engaged in practices prohibited in Section 6+, Purchase Orders, Invoices and Payments hereof; Section 8, Vendor Responsibilities; hereof; and Section 7, Intellectual Property Matters, in the Contract; 5) Vendor or Vendor's Worker commits any material breach or default of any covenant, warranty, obligation or agreement under this Contract, fails to perform the work under this Contract within the time specified herein or any extension thereof, or so fails to pursue the work as to endanger Vendor's performance under this Contract in accordance with its terms.
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
Vendor Suspension. DIR's Right to Suspend Contract for Cause in accordance with this Section. DIR may suspend Vendor’s performance of this Contract, in whole or in part, for a period up to 180 calendar days by following the procedure in this paragraph. When a violation of the contract as set forth below occurs, DIR may send a Notice of Intent to Suspend to the Vendor providing the reasons for the proposed suspension. Vendor shall have five (5) business days from receipt of the Notice of Intent to Suspend to provide a written response. At the expiration of the 5 business days, DIR will make a determination whether a violation(s) of the contract occurred. In those instances where a violation is found to have occurred, DIR shall decide on a period of suspension up to 180 calendar days in length and send a written notice of the period of suspension and the related findings to Vendor. The suspension shall be effective from the date of receipt by Vendor. DIR may issue a Notice of Intent to Suspend under the proper circumstances, which include, but are not limited to the events listed below: 1) Vendor or Vendor's Worker(s) no longer holds necessary license(s) or certificate(s) required to perform the work under any Work Order;
Sample 1

Related to Vendor Suspension

  • Service Suspension 8.1 By giving reasonable notice to you, or if this is not practicable, such notice as is reasonably practicable in the circumstances, we may suspend the Service (or any part of the Service) for reasons to include but not limited to: 8.1.1 for operational reasons in accordance with the service levels, or 8.1.2 if required because of a regulatory or legal change, or 8.1.3 if we are obliged to comply with the order, instruction, or request of a court, government, agency, emergency service organisation, or other competent administrative or regulatory authority, requiring suspension to the Service, or 8.1.4 if your use of the Service may damage or disrupt the proper functioning of the infrastructure and / or equipment used to provide services to our other Customers, or 8.1.5 if we have reasonable grounds to believe that you are in breach of your obligations, and you either fail to remedy that breach or fail to demonstrate to our reasonable satisfaction that no breach took place within two (2) Working Days of written notice of the suspected breach for a serious breach (serious breach to include, but not limited to, a breach likely to cause serious damage to us or our brand, or that of our contractors, or result in legal action by a third party) or within ten (10) Working Days of written notice of the suspected breach for other breach, or 8.1.6 if an undisputed invoice (or an undisputed part of an invoice) is not paid in full by the due date, provided that we have given you at least five (5) Working Days’ notice of such non- payment. 8.2 Suspension of the Service shall cause our service level obligations to be excluded for the period of the suspension. Such suspension of the Service shall continue for as long as any of the circumstances in Clauses 8 continues.

  • No Suspension Trading in the Common Stock shall not have been suspended on the Exchange and the Common Stock shall not have been delisted from the Exchange.

  • CERTIFICATION REGARDING DEBARMENT OR SUSPENSION Contractor certifies that neither Contractor or its principals; its subcontractors or their principals; the sub-recipients (if applicable) or their principals are suspended, debarred, proposed for debarment, voluntarily excluded from covered transactions, or otherwise disqualified by any federal department or agency from doing business with the Federal Government pursuant to Executive Orders 12549 and 12689. Contractor specifically covenants that neither the Contractor or its principals, its sub-contractors or their principals, or the sub-recipients (if applicable) or their principals are included on the Excluded Parties List System (“EPLS”) maintained by the General Services Administration (“GSA”).

  • Post Suspension 1. Without prejudice to the procedures in Article 190 (Examination of the Benefit Suspension Level), if the Party complained against considers that it has eliminated the non-conformity that the Panel has found, it may provide written notice to the complaining Party with a description of how non-conformity has been removed. If the complaining Party has disagreement, it may refer the matter to the original Panel within 60 days after receipt of such written notice. Otherwise, the complaining Party shall promptly stop the suspension of benefits. 2. The Panel shall release its report within 60 days after the referral of the matter. If the Panel concludes that the Party complained against has eliminated the non-conformity, the complaining Party shall promptly stop the suspension of benefits.

  • No Suspension, Etc Trading in the Company’s Common Stock shall not have been suspended by the Commission or the OTC Bulletin Board (except for any suspension of trading of limited duration agreed to by the Company, which suspension shall be terminated prior to the Closing), and, at any time prior to the Closing Date, trading in securities generally as reported by Bloomberg Financial Markets (“Bloomberg”) shall not have been suspended or limited, or minimum prices shall not have been established on securities whose trades are reported by Bloomberg, or on the New York Stock Exchange, nor shall a banking moratorium have been declared either by the United States or New York State authorities, nor shall there have occurred any material outbreak or escalation of hostilities or other national or international calamity or crisis of such magnitude in its effect on, or any material adverse change in any financial market which, in each case, in the judgment of such Purchaser, makes it impracticable or inadvisable to purchase the Securities to be issued as of the Closing.

  • Debarment/Suspension Contractor is prohibited from making any award or permitting any award at any tier to any party which is debarred or suspended or otherwise excluded from or ineligible for participation in federal assistance programs under Executive Order 12549, Debarment and Suspension. Contractor and its subcontractors shall comply with the Certification Requirements for Recipients of Grants and Cooperative Agreements Regarding Debarments and Suspensions.

  • Termination; Suspension Your right to use the Online Backup Feature will terminate on expiration of the Service Period. Symantec may immediately suspend or terminate use of the Online Backup Feature during the Service Period for Your failure to or Symantec’s reasonable belief that You have failed to comply with these terms and conditions (other than a trivial or inconsequential breach) or any other misuse of the Online Backup Feature. Following the expiration or termination of the Service Period:  Symantec may permanently delete any Data stored to the online backup space provided with Your Software and Services ;  Symantec will not be obligated to maintain such Data, forward such Data to You or a third party, or migrate such Data to another backup service or account; and  You will not be able to store the Data to any additional backup space that You may have purchased separately unless and until the Service Period is renewed.

  • TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:

  • Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.

  • Service Termination, Cancellation, or Suspension If you wish to cancel the Service, you may contact us as set forth in Section 6 of the General Terms above. Any payment(s) that have begun processing before the requested cancellation date will be processed by us. You agree that we may terminate or suspend your use of the Service at any time and for any reason or no reason. Neither termination, cancellation nor suspension shall affect your liability or obligations under this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!