Written Change Orders Clause Samples
The Written Change Orders clause establishes that any modifications to the original contract must be documented and agreed upon in writing by all parties involved. In practice, this means that if there are changes to the scope of work, pricing, or project timeline, these adjustments cannot be made verbally or informally; instead, a formal written document must be executed and signed. This clause ensures that all parties have a clear, mutual understanding of any changes, thereby preventing disputes and misunderstandings about the terms of the contract.
POPULAR SAMPLE Copied 1 times
Written Change Orders. The general scope of this contract and the Services to be performed or supplies to be delivered will not be altered, amended, modified, added to or subtracted from unless agreed in writing and signed by Contractor and GJHA (“Change Order”). All Change Orders will contain a description of the change in the Services to be performed or supplies to be delivered, the amount of adjustment to the Contract Price, if any, and the extent of any adjustment in the Completion Date. Any change, modification or refinement of the general scope of this contract in the Services to be performed or supplies to be delivered, will constitute a Change Order.
Written Change Orders a. Oral change orders are not permitted. No change in this Contract shall be made unless the Contracting Officer gives prior written approval, therefore. The Contractor shall be liable for all costs resulting from, and/or for satisfactorily correcting, any specification changes not properly ordered by written modification to the Contract and signed by the Contracting Officer.
Written Change Orders. Design/Builder shall not be entitled to payment for additional work unless a written Change Order or Extra Work Order, in form and content prescribed by Owner, has been executed by the Owner prior to starting the additional work; on all such Change Orders and Extra Work Orders, Design/Builder shall specify the increased and/or decreased costs and whether it believes any extensions of time will be necessary to complete its Work as modified by the Change Order or Extra Work Order. In no event, however, will the Design/Builder be entitled to collect for overhead and profit for such changes more than the percentages of Design/Builder’s actual and direct cost incurred in such change as set forth on the corresponding Change Order. If additional work is performed on the basis of an Extra Work Order, a corresponding Change Order shall be prepared, approved and processed by Owner before payment can be made to Design/Builder.
Written Change Orders. The documents listed in Subarticle 6.1. are attached to this Contract (except as expressly stated otherwise above).
Written Change Orders. It is specifically understood and agreed that the Owner may make additions, modifications, alterations or substitutions in the work of the Contractor to be performed hereunder by adding to, omitting from or deviating from the plans and specifications previously provided by Owner to Contractor. Provided, however, that any additions, deletions, omissions or substitutions must be evidenced by a written change order fully executed by all of the parties hereto on a change order form to be provided by the Contractor. All written change orders shall be dated and attached to this Contract as an additional exhibit or addendum thereto and shall be made a part hereof. The provisions of this Contract shall apply to all additions, deletions, omissions or substitutions with the same effect as if such were embodied in the original the Plans. No claim for any additions, deletions, omissions or substitutions to this Contract or delay in completion attributable to any change in the work shall be valid unless authorized by the parties hereto, as evidenced by a fully executed change order.
Written Change Orders. It is specifically understood and agreed that the Owner may make additions, modifications, alterations or substitutions in the work of the Contractor to be performed hereunder by adding to, omitting from or deviating from the attached plans, blueprints and specifications. Provided, however, that any additions, deletions, omissions or substitutions must be evidenced by a written change order fully executed by all of the parties hereto on a change order form to be provided by the Contractor. All such change orders shall contain or reflect the value of any additional or other work or materials and the amount so agreed upon shall be added to or deducted from the Contractor’s Fee as herein set forth. All written change orders shall be dated and attached to this Contract as an additional exhibit or addendum thereto and shall be made a part hereof. The provisions of this Contract shall apply to all additions, deletions, omissions or substitutions with the same effect as if such were embodied in the original the Plans. No claim for any additions, deletions, omissions or substitutions to this Contract or delay in completion attributable to any change in the work shall be valid unless authorized by the parties hereto, as evidenced by a fully executed change order.