We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Authority’s Engineer definition

Authority’s Engineer shall have the meaning set forth in Clause 18.1;
Authority’s Engineer shall have the meaning set forth in Clause 18.1; “Authority Representative” means such person or persons as may be authorized in writingbytheAuthoritytoactonitsbehalfunderthisAgreementandshallincludeany person or persons having authority to exercise any rights or perform and fulfill any obligations of the Authority under this Agreement; “Bank” means a bank incorporated in India and recognized by the Reserve Bank of IndiaBank Rate” means the standard rate at which Reserve Bank of India is prepared to buy or re-discount bills of exchange or other commercial paper eligible for purchase under the Reserve Bank of India Act 1934. “Base Rate” means the floor rate of interest announced by the State Bank of India for all its lending operations; “Base Date” means the last date of the calendar month, which precedes the Bid Due Date by at least 28 (twenty eight) days; “Bid” means the documents in their entirety comprised in the bid submitted by the [selected bidder/ Joint venture] in response to the Request for Proposal in accordance with the provisions thereof; “Bid Security” means the bid security provided by the Contractor to the Authority in accordance with the Request for Proposal, and which is to remain in force until substituted by the Performance Security; “Change in Law” means the occurrence of any of the following after the Base Date: (a) the enactment of any new Indian law; (b) the repeal, modification or re-enactment of any existing Indianlaw; Contract AgreementPage 18 of 159 Widening & Upgradation to 4-lane with paved shoulder from km 16.700 (end of Seer Hamdan Bypass) to km 39.450 (start of Pahalgam Bypass), Package-II of Khanabal - Pahalgam - Chandanwadi - Baltal section of NH-501 in the UT of Jammu & Kashmir on EPC Mode January’ 2024
Authority’s Engineer shall have the meaning set forth in Article 20.1.1 of the Concession Agreement.

Examples of Authority’s Engineer in a sentence

  • If, as a result of an examination, inspection, measurement or testing, any Plant, Materials, design or workmanship is found to be defective or otherwise not in accordance with the provisions of this Agreement, the Authority’s Engineer shall reject the Plant, Materials, design or workmanship by giving notice to the Contractor, with reasons.

  • In respect of the work which the Authority’s Engineer is entitled to examine, inspect, measure and/or test before it is covered up or put out of view or any part of the work is placed thereon, the Contractor shall give notice to the Authority’s Engineer whenever any such work is ready and before it is covered up.

  • Provided, however, that if any work is of a continuous nature where it is not possible or prudent to keep it uncovered or incomplete, the Contractor shall notify the schedule of carrying out such work to give sufficient opportunity, not being less than 3 (three) business days’ notice, to the Authority’s Engineer to conduct its inspection, measurement or test while the work is continuing.

  • Provided that any such direction issued by the Authority’s Engineer shall specify the reasons for the removal of such person.

  • Also the Contractor shall provide licenced copy of software used to develop Works Programme to the Authority and Authority’s Engineer.

  • The test checks by the Authority’s Engineer shall comprise at least 50% (fifty percent) of the quantity or number of tests prescribed for each category or type of test for quality control by the Contractor.

  • The Authority’s Engineer shall require the Contractor to carry out or cause to be carried out tests to determine that such remedial measures have brought the Works into compliance with the Specifications and Standards, and the procedure shall be repeated until such Works conform to the Specifications and Standards.

  • The Authority’s Engineer shall then either carry out the examination, inspection or testing without unreasonable delay, or promptly give notice to the Contractor that the Authority’s Engineer does not require to do so.

  • The principal Works Programmer shall hold reputable professional qualifications acceptable to the Authority’s Engineer including at least five (5) years relevant experience in programming civil engineering works.

  • Provided further that in the event the Contractor receives no response from the Authority’s Engineer within a period of 3 (three) business days from the date on which the Contractor’s notice hereunder is delivered to the Authority’s Engineer, the Contractor shall be entitled to assume that the Authority’s Engineer would not undertake the said inspection.


More Definitions of Authority’s Engineer

Authority’s Engineer means Authority’s field representative to whom Owner and Authority make known decisions, instructions and interpretations. Each Notice to Owner may have a different Authority’s Engineer. With the exception of the types of notices described in Section 8.2, notices given the Authority’s Engineer shall be deemed notices given to Authority.

Related to Authority’s Engineer

  • Independent Engineer means XxXxxxxx and XxxXxxxxxxx or any other third party engineering firm acceptable to the Administrative Agent in its sole discretion.

  • Engineer means the representative of the Architect/consultant.

  • Site Engineer means an Engineer appointed by the SBIIMS at site as their representative for day-to-day supervision of work and to give instructions to the contractors.

  • City Engineer s Representative” shall mean an assistant of the City Engineer i.e. rank of Executive Engineer who will be called as Engineer-in-charge of work notified in writing to the Contractor by the City Engineer.

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • The Engineer means the Engineer appointed by the Purchaser for the purpose of this contract.