Completion Longstop Date definition

Completion Longstop Date means 30 November 2032, or such other date as the Seller and Purchaser may agree in writing.
Sample 1Sample 2Sample 3
Completion Longstop Date means the date falling three hundred and sixty five (365) days after Planned Completion Date as such Planned Completion Date may be extended pursuant to Article 25 (Delay Events);
Sample 1
Completion Longstop Date means the date falling 24 months from the Substantial Completion Date.
Sample 1

Examples of Completion Longstop Date in a sentence

  • The Company has requested a further short-term extension of the Project Completion Longstop Date from KfW.

  • The Borrower shall repay to the Administrative Agent for the ratable account of the Lenders on the Project Completion Longstop Date (or if such day is not a Business Day, payment shall be made on the immediately preceding Business Day) the aggregate principal amount of all Liquidity Buffer Loans outstanding on such date.

  • The Company is also in discussions with KfW to achieve a longer-term extension of the Project Completion Longstop Date to a date in 2023, the deferral of debt servicing by twelve months and the temporary deferral of compliance with certain financial covenants under the Amended KfW Facility as the Underground Mine continues to ramp-up.

  • In addition, the KfW Amendment Agreement will extend the Project Completion Longstop Date until June 2023 and provide for certain minimum liquidity and liquidity reporting requirements.

  • Project Completion has not occurred on or prior to the Completion Longstop Date.

  • The primary reason for the increase in the Company’s working capital deficiency is the classification of the Amended KfW Facility (as defined below) as a current liability, pending the extension of the Project Completion Longstop Date (as defined below).

  • The Company is also in discussions with KfW to achieve a longer- term extension of the Project Completion Longstop Date to a date in 2023, the deferral of debt servicing by twelve months and the temporary deferral of compliance with certain financial covenants under the Amended KfW Facility as the underground mine continues to ramp-up.

  • On June 30, 2021, the Company received a waiver from KfW, which provided for a 60-day extension to the Project Completion Longstop Date from June 30, 2021 to August 31, 2021.

  • The Project Completion Longstop Date requires the Underground Mine to be operating at five thousand tonnes per day (tpd) for ninety consecutive days by June 2023.

  • In the event PREP A elects to place the Vessel On Hire from the Substantial Completion Longstop Date until the In-Service Date, PREPA may subsequently elect to cease paying Hire prior to the In-Service Date, in which case EE shall again have the right to terminate this Charter as set out in this Clause 3.2( d).


More Definitions of Completion Longstop Date

Completion Longstop Date means the date 4 months after the date hereof;
Sample 1
Completion Longstop Date means the date 54 months after the Unconditional Date or such later date as is fixed under Clause 20 (Time for completion of the Infrastructure Works ).
Sample 1
Completion Longstop Date has the meaning given in subclause 3.2;
Sample 1

Related to Completion Longstop Date

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Longstop Date means 20 September 2020;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Final Completion Date means the date on which Final Completion occurs.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Start-up period means up to a maximum of 7 Academy Financial Years and covers the period up to and including the first Academy Financial Year in which all age groups are present at the Academy (that is, all the pupil cohorts relevant to the age-range of the Academy will have some pupils present).

  • Construction Completion Certificate means a certificate of the I-Bank to the effect that the construction of the Project is complete.

  • Completion Payment means the payment for the 20% of the Charges for each Apprenticeship that under the ESFA Rules is only paid once an Apprentice takes their end point assessment, including as the case may be Apprenticeships funded by Transferred Levy Funds;