Final Approved Punch List definition

Final Approved Punch List means a list, approved pursuant to Article 14.2.2, specifying those items of Work to be completed by the Contractor after Substantial Completion and dates for the completion of each item of Work.
Sample 1Sample 2Sample 3
Final Approved Punch List means a list, approved in writing by the Project Manager, Engineer or Architect, specifying those items of Work to be completed by the Contractor after Substantial Completion and dates for the completion of each item of Work.
Sample 1Sample 2Sample 3
Final Approved Punch List means a list, approved in writing by the Engineer, specifying those items of Work to be completed by the Contractor after Substantial Completion and dates for the completion of each item of Work.
Sample 1Sample 2Sample 3

Examples of Final Approved Punch List in a sentence

  • The date of approval of the Final Approved Punch List, shall be the date of Substantial Completion.

  • In addition to the right to declare the Contractor in default pursuant to this Chapter X, the Commissioner shall have the absolute right, in his/her sole discretion and without a hearing, to complete or cause to be completed in the same manner as described in Articles 51 and 53, any or all unsatisfactory or uncompleted punch list Work that remains after the completion date specified in the Final Approved Punch List.

  • In addition to the right to declare the Contractor in default pursuant to the provisions of Article 80 through Article 86, the Commissioner shall have the absolute right, in his/her sole discretion and without a hearing, to complete or cause to be completed in the same manner as described in Article 83 and Article 85, any or all unsatisfactory or uncompleted punch list Work that remains after the completion date specified in the Final Approved Punch List.

  • In addition to the right to declare the Contractor in default pursuant to the provisions of Article 81 through Article 87, the Commissioner shall have the absolute right, in his/her sole discretion and without a hearing, to complete or cause to be completed in the same manner as described in Article 84 and Article 86, any or all unsatisfactory or uncompleted punch list Work that remains after the completion date specified in the Final Approved Punch List.

  • The Work will be accepted as final and complete as of the date of the Resident Engineer’s inspection if, upon such inspection, the Resident Engineer finds that all items on the Final Approved Punch List are complete and no further Work (or approvals) remains to be done.

  • The date of approval of the Final Approved Punch List shall be the date of Substantial Completion.

  • The Work will be accepted as final and complete as of the date of DOT’s inspection if, upon such inspection, DOT finds that all items on the Final Approved Punch List are complete and no further Work remains to be done.

  • The Work in a Home will be accepted as final and complete as of the date of the Commissioner’s Representative's inspection if, upon such inspection, the Commissioner’s Representative finds that all items on the Final Approved Punch List are complete and no further Work in the Home remains to be done and that the contractor has obtained all regulatory approvals for the Work performed on a Home pursuant to this Agreement..

  • The Work will be accepted as final and complete as of the date of the Commissioner’s Representative's inspection if, upon such inspection, the Commissioner’s Representative finds that all items on the Final Approved Punch List are complete and no further Work under the Task Order remains to be done and that the contractor has obtained all regulatory approvals for the Work performed under the Task Order pursuant to this Agreement.

Related to Final Approved Punch List

  • Final Approval means the Court’s order granting final approval of the Settlement.

  • Final Approval Order means the proposed Order Granting Final Approval to the Settlement, to be entered by the Court with terms to be agreed upon by the Parties and consistent with this Agreement.

  • Final Approval Date means the date upon which Final Approval occurs.

  • Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • Approved Project means the Scheme application of the Applicant approved by the CIC.

  • Plans and Specifications means the plans, drawings and specifications reasonably necessary to properly assess and review proposed Work prior to issuance of any approval that may be required under this Agreement;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Approved program or approved State means a State administered NPDES program which has been approved or authorized by EPA under 40 CFR Part 123.

  • Final Approval Order and Judgment means an order and judgment that the Court enters after the Final Approval Hearing, which finally approves the Settlement Agreement, certifies the Settlement Class, dismisses the Action with prejudice, and otherwise satisfies the settlement-related provisions of Federal Rule of Civil Procedure 23, and is consistent with all material provisions of this Agreement, substantially in the form annexed hereto as Exhibit 5.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Initial approval means authorization to admit students and enter into contractual agreements for clinical facilities. It is granted only after an application has been submitted, reviewed and a survey visit made by the Board. No students shall be admitted to the program until the institution has received written notification that initial approval has been granted. Failure to comply will delay initial approval.

  • Final Approval Hearing means the hearing before the Court where the Parties will request the Final Judgment to be entered by the Court approving the Settlement Agreement, the Fee Award, and the incentive award to the Class Representative.

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.

  • Wind-Down Budget means a budget to be prepared by the Debtors, and reasonably acceptable to the Deerfield Requisite Supporting Noteholders, the Unaffiliated Requisite Supporting Noteholders, and the Committee, which shall be filed with the Court as part of the Plan Supplement, and which may be amended from time to time after entry of the Confirmation Order, subject to the consent of the Oversight Committee, which consent shall not be unreasonably withheld, and which shall estimate the funds necessary to administer the Plan and wind down the Debtors’ affairs, including the costs of holding and liquidating the Estates’ remaining property, objecting to Claims, making the Distributions required by the Plan, prosecuting claims and Causes of Action that may be held by the Estates against third parties that are not released, waived or transferred pursuant to the Plan (including pursuant to Article X) or otherwise, paying Taxes, filing Tax returns, paying professionals’ fees and expenses, paying the fees and expenses of the Oversight Committee, funding payroll and other employee costs, providing for the purchase of errors and omissions insurance and/or other forms of indemnification for the Plan Administrator, and for all such items and other costs of administering the Plan, the Estates and the Liquidating Debtors (other than the Administrative and Priority Claims Reserve, the Disputed Claims Reserve, and the Professional Fee Reserve).

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.

  • Project Improvements means site improvements and facilities that are:

  • Standard Specifications means a compilation in book form of specifica- tions approved for general application and repetitive use;

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.