Original construction means the first or initial construction
Residential construction means construction on single-family or two-family dwellings occupied or used, or intended to be occupied or used, primarily for residential purposes, and includes real property pursuant to chapter 499B.
Construction Plans means plans, drawings, specifications and related documents, and construction schedules for the construction of the Project, together with all supplements, amendments or corrections, submitted by the Developer and approved by the City in accordance with this Agreement.
Acquisition and Construction Fund means the fund so designated in, and created pursuant to, Section 502 hereof.
Erection, construction, remodeling, repairing means all types of work done on a particular building or work at the site thereof in the construction or development of the project, including without limitation, erecting, construction, remodeling, repairing, altering, painting, and decorating, the transporting of materials and supplies to or from the building or work done by the employees of the Contractor, Subcontractor, or Agent thereof, and the manufacturing or furnishing of
Existing construction means any structure for which the "start of construction" commenced before the effective date of the initial floodplain management code or ordinance adopted by the community as a basis for that community's participation in the NFIP.
Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.
New construction means, for the purposes of determining insurance rates, structures for which the "start of construction" commenced on or after the effective date of an initial FIRM or after December 31, 1974, whichever is later, and includes any subsequent improvements to such structures. For floodplain management purposes, "new construction" means structures for which the "start of construction" commenced on or after the effective date of the floodplain management regulations adopted by a community and includes any subsequent improvements to such structures.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Direct Construction Cost shall have the meaning set forth in Article 11.
Completion of Construction means the date, as determined by the Division after consultation with the Recipient, that the work of building and erection of the Project is substantially complete, and is identified in Exhibit A of this Agreement.
Building construction means any physical activity on the site involved in the erection of a structure, cladding, external finish, formwork, fixture, fitting of service installation and the unloading of plant, machinery, materials or the like.
The constructional plant means all appliances, tools, plants or machinery or whatsoever nature required in or about the execution, completion or maintenance of the works but does not include materials or other things intended to form part of the permanent work.
Interconnection Construction Service Agreement means the agreement entered into by an Interconnection Customer, Interconnected Transmission Owner and the Transmission Provider pursuant to Tariff, Part VI, Subpart B and in the form set forth in Tariff, Attachment P, relating to construction of Attachment Facilities, Network Upgrades, and/or Local Upgrades and coordination of the construction and interconnection of an associated Customer Facility. A separate Interconnection Construction Service Agreement will be executed with each Transmission Owner that is responsible for construction of any Attachment Facilities, Network Upgrades, or Local Upgrades associated with interconnection of a Customer Facility.
Construction Completion Certificate means the certificate issued under ARTICLE 14.
GENERAL AND SPECIAL CONDITIONS OF CONTRACT means the instructions to Tenderer and General and special conditions of contract pertaining to the work for which above tenders have been called for.
Construction project means the same as that term is defined in Section 38-1a-102.
Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.
Begin actual construction means, in general, initiation of physical on-site construction activities on an emissions unit which are of a permanent nature. Such activities include, but are not limited to, installation of building supports and foundations, laying of underground pipework, and construction of permanent storage structures. With respect to a change in method of operation, this term refers to those on-site activities, other than preparatory activities, which mark the initiation of the change.
Pipeline Construction means a substantial disturbance to agricultural land associated with installation, replacement, removal, operation or maintenance of a pipeline, but shall not include work performed during an emergency. Emergency means a condition where there is clear and immediate danger to life or health, or essential services, or a potentially significant loss of property. When the emergency condition ends, pipeline construction will be in accordance with these rules.
Commencement of Construction means the commencement of construction of foundation components or elements (such as footings, rafts or piles) for the home.
Construction and Demolition Debris means and includes:
as constructed plans means as constructed plans as defined in the Building Code;
construction site means a workplace where construction work is being performed;
Construction Contracts means the contracts between Lessee and Contractors for the furnishing of labor, services or materials to the Leased Premises in connection with the construction of the Improvements.
Construction Agreements means agreements to which Tenant is a party for Construction Work, rehabilitation, alteration, repair, replacement or demolition performed pursuant to this Lease.