Governmental Approvals and Permits definition

Governmental Approvals and Permits means and refer to all approvals, permits, licenses, and/or applications of any kind or nature which have been issued by or which are on file with any governmental agencies, departments or authorities with respect to the Real Property, including, without limitation, all zoning approvals, subdivision approvals, special permit approvals, land development permits, building permits, and/or certificates of occupancy.
Sample 1Sample 2Sample 3
Governmental Approvals and Permits means and refer to all consents, authorizations, approvals, permits, licenses, and/or applications of any kind or nature which have been issued by or which are on file with any governmental agencies, departments or authorities with respect to the Real Property, including, without limitation, all zoning approvals, site plan approvals, side development premises, subdivision approvals, special permit approvals, land development permits, building permits, and/or certificates of occupancy.
Sample 1
Governmental Approvals and Permits means and refer to all of Seller’s right, title and interest in and to all approvals, permits, licenses, and/or applications of any kind or nature which have been issued by or which are on file with any governmental agencies, departments or authorities to the extent, and only to the extent, they relate to the Real Property.
Sample 1

Examples of Governmental Approvals and Permits in a sentence

  • CDOT shall assist the Enterprises in complying with their obligation to provide assistance to the Developer in obtaining and modifying Governmental Approvals and Permits under Section 8.4.4 of the C-70 Project Agreement.

  • The Contractor will be responsible for securing all Governmental Approvals and Permits required for the Project from those agencies having jurisdiction over the Project, unless noted otherwise in the Agreement.

  • Willxxxx xxxll cause the Share Trust to obtain and maintain, or cause to be obtained and maintained, in full force and effect all necessary Governmental Approvals and Permits required to be obtained in its name from time to time.

  • WCG shall cause (through WCL) each of the Issuer and the Co-Issuer to obtain and maintain, or cause to be obtained and maintained, in full force and effect all necessary Governmental Approvals and Permits required to be obtained in its name from time to time.

  • One Project Milestone shall be that the Seller secures all Governmental Approvals and Permits necessary to construct the Project on or before the First Permitting Deadline (the “Permitting Milestone”), provided, that the Seller may extend the Permitting Milestone to the Final Permitting Deadline by giving the Purchaser written notice in accordance with Section 15.11 of such extension.

  • Passage shall promptly notify Xxxxx in writing of the achievement of any such Commercial Milestone and Passage shall pay Gemma in full the corresponding Commercial Milestone Payment within [*] after such achievement.

  • The Borrower shall have received, in a form satisfactory to the Agents, the Lenders and the Independent Engineer, all Governmental Approvals and Permits set forth in Section 6.1.10 and all such Governmental Approvals and Permits shall be in final non-appealable form.

  • Without limiting its obligations under Part 2, Section 19.1, the O&M Contractor shall deliver to the Developer copies of all Governmental Approvals and Permits for which it is responsible pursuant to Part 2, Section 8.4.2.a (and copies of any modifications, renewals, extensions and waivers to or of any thereof) promptly following receipt by the O&M Contractor of the same.

  • As long as delays arise from reasonable causes and schedules are adapted with a mind toward possible 24 Seller accountability for failure to obtain Governmental Approvals and Permits under the APSA, even when it is clear that no Force Majeure excuse is applicable, is likewise subject to doubt due to the Project Schedule revision process in Section 10 of the APSA.

  • Finally, the literature was examined for different trust constructs used, if any, such as the classes of trust, trust development over time and trust levels.

Related to Governmental Approvals and Permits

  • Governmental Approvals means all authorizations, consents, approvals, licenses and exemptions of, registrations and filings with, and reports to, all Governmental Authorities.

  • Required Governmental Approvals means the Company Required Governmental Approvals and the Parent Required Governmental Approvals.

  • Governmental Authorizations means any approval, consent, license, permit, waiver, or other authorization issued, granted, given, or otherwise made available by or under the authority of any Governmental Entity or pursuant to any Legal Requirement.

  • Governmental Permits has the meaning specified in Section 5.8.

  • Environmental Approvals means any permit, license, approval, ruling, variance, exemption or other authorization required under applicable Environmental Laws.

  • Governmental Authorization means any permit, license, authorization, plan, directive, consent order or consent decree of or from any Governmental Authority.

  • Environmental Authorizations means all licenses, permits, orders, approvals, notices, registrations or other legal prerequisites for conducting the business of the Borrower or any Subsidiary required by any Environmental Requirement.

  • Governmental Permit means any license, franchise, permit or other authorization of any Governmental Authority.

  • Governmental Approval is any consent, authorization, approval, order, license, franchise, permit, certificate, accreditation, registration, filing or notice, of, issued by, from or to, or other act by or in respect of, any Governmental Authority.

  • Environmental Authorization Any license, permit, order, approval, consent, notice, registration, filing or other form of permission or authorization required under any Environmental Law.

  • Project Approvals means all approvals, consents, waivers, orders, agreements, authorizations, permits and licenses required under Applicable Laws or under the terms of any restriction, covenant, easement or agreement affecting all or any applicable Phase of the Project, or otherwise necessary or desirable for the ownership, acquisition, construction, development, equipping, use or operation of the Project.

  • Licenses and Permits means, collectively, all of Seller’s right, title and interest, to the extent assignable, in and to licenses, permits, certificates of occupancy, approvals, dedications, subdivision maps and entitlements now or hereafter issued, approved or granted by the Authorities in connection with the Real Property and the Improvements, together with all renewals and modifications thereof.

  • Consents, Clearances and Permits means all authorizations, licenses, approvals, registrations, permits, waivers, privileges, acknowledgements, agreements, or concessions required to be obtained from or provided by any concerned authority for the purpose of setting up of the generation facilities and/ or supply of power;

  • Environmental Permits means any and all permits, licenses, approvals, registrations, notifications, exemptions and other authorizations required under any Environmental Law.

  • Parent Permits has the meaning set forth in Section 4.1.

  • Environmental Approval means any present or future permit, ruling, variance or other Authorisation required under Environmental Laws.

  • Required Permits shall have the meaning set forth in Section 6.24.

  • Government Approvals means all permits, licenses, authorisations, consents, clearances, decrees, waivers, privileges, approvals from and filing with government instrumentalities necessary for the development, construction and operation of the Work.

  • Governmental Authorities means any nation, government, province, state, or any entity, authority or body exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government, including any government authority, agency, department, board, commission or instrumentality of any government or any political subdivision thereof, court, tribunal, arbitrator, the governing body of any securities exchange, and self-regulatory organization, in each case having competent jurisdiction (with each of such Governmental Authorities being referred to as a “Governmental Authority”).

  • Governmental Authority(ies) means any federal, state or local government, and political subdivision(s) thereof, and any entity(ies) exercising executive, legislative, judicial, regulatory or administrative functions having or pertaining to government.

  • Company Permits has the meaning set forth in Section 3.12(a).

  • Governmental Filings means all filings, including franchise and similar tax filings, and the payment of all fees, assessments, interests and penalties associated with such filings with all Governmental Authorities.

  • Environmental Permit means any permit, approval, identification number, license or other authorization required under any Environmental Law.

  • Governmental Requirements means all judgments, orders, writs, injunctions, decrees, awards, laws, ordinances, statutes, regulations, rules, franchises, permits, certificates, licenses, authorizations and the like and any other requirements of any government or any commission, board, court, agency, instrumentality or political subdivision thereof.

  • Regulatory Permits means all Permits granted by the FDA or any comparable Governmental Entity to the Company or any of its Subsidiaries, including investigational new drug applications, Biologics License Applications, manufacturing approvals and authorizations, clinical trial authorizations and ethical reviews, or their national or foreign equivalents.

  • Necessary Authorizations means all approvals and licenses from, and all filings and registrations with, any governmental or other regulatory authority, including, without limiting the foregoing, the Licenses and all approvals, licenses, filings and registrations under the Communications Act, necessary in order to enable the Borrower and its Subsidiaries to own, construct, maintain, and operate communications tower facilities and to invest in other Persons who own, construct, maintain, manage and operate communications tower facilities.