Phase Completion Date definition

Phase Completion Date. [means, as the context may require, the Phase 1 Completion Date and/or the Phase 2 Completion Date;]
Sample 1Sample 2
Phase Completion Date with respect to each Phase, the earlier to occur of (i) Completion of such Phase, (ii) (x) as to the Initial Phases for the Applicable Sites located in Miami, Florida and San Antonio, Texas, October 21, 1997, (y) as to all other Initial Phases, the date which is six months after the Phase Commencement Date for such Phase, and (z) as to all Subsequent Phases, June 30, 2000, and (iii) the last day of the Acquisition Period.
Sample 1
Phase Completion Date means the date that XXX.XXXXXX notifies CUSTOMER that the Products for a given phase are installed and available for customer use (including for the purpose of configuration and beta testing by CUSTOMER) The provisions of this Agreement shall be deemed included in accompanying Addendums or Attachments to this Agreement, except if there is a conflict with a provision in any such separate Agreement, in which event, the separate Agreement shall control.
Sample 1

Examples of Phase Completion Date in a sentence

  • Without prejudice to Clauses 40 (DBFM Co Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the Completion Date [Phase Completion Date] and the Actual Completion Date [relevant Phase Actual Completion Date].

  • The following chart presents the projected data for each phase of the Project: Phase # of Homes Effective Date Phase Completion Date Minimum Phase Valuation Phase Approx.

  • Notwithstanding that the Works [relating to a Phase] may have been completed in accordance with this Agreement, the Actual Completion Date [Phase Actual Completion Date] may only occur on a date on or after the Completion Date [Phase Completion Date] unless the Authority, in its absolute discretion, agrees otherwise in writing.

  • Without prejudice to Clauses 40 (Sub-hubco Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the Completion Date [Phase Completion Date] and the Actual Completion Date [relevant Phase Actual Completion Date].

  • Without prejudice to Clause 40 (Project Co Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the Completion Date [Phase Completion Date] and the Actual Completion Date [relevant Phase Actual Completion Date].

  • Sub-hubco shall complete the Works [relating to a Phase] by the Completion Date [relevant Phase Completion Date].

  • Provided that performance of this Agreement has not been suspended or terminated by the City under Article VII hereof, the City shall pay any Loan Advances attributable to each phase of the Project which is approved by any one or more Requisitions under this Article to the Developer within twenty-one (21) calendar days after (i) each Phase Completion Date, and (ii) the approval of any such Requisition(s) applicable thereto, whichever in (i) and (ii) occurs last.

  • Not less than [sixty (60)] Business Days prior to the [first Phase] Completion Date and each subsequent renewal date in respect of each of the Operational Insurances, Project Co must inform the Authority’s Representative of the forthcoming requirement to place or renew an Operational Insurance and its proposals for obtaining competitive quotations from at least ([three (3)] suitable insurers.

  • Without prejudice to Clause 40 (Project Co Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the [Completion Date] [Phase Completion Date] and the [Actual Completion Date] [relevant Phase Actual Completion Date].

  • Without prejudice to Clause 44 (Project Co Event of Default), 46 (Authority Voluntary Termination), 50 (Compensation on Termination) and 51 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the [Completion Date] [Phase Completion Date] and the [Actual Completion Date] [relevant Phase Actual Completion Date].


More Definitions of Phase Completion Date

Phase Completion Date with respect to each Phase, the earlier to occur of (i) Completion of such Phase, (ii) the date which is six months after the Phase Commencement Date for such Phase, and (iii) the last day of the Acquisition Period.
Sample 1
Phase Completion Date means the date on which the Completion Certificate is issued under the provisions of Article 13;
Sample 1
Phase Completion Date means for each relevant Phase the date falling 10 Working Days after the later of the following:- (a) the Pre Emption Satisfaction Date (b) the date of receipt by the Agency of a Developer's Drawdown Request for the relevant Phase
Sample 1

Related to Phase Completion Date

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Final Completion Date means the date on which Final Completion occurs.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Commercial Operations Date or "COD": The date on which Facility first achieves Commercial Operations.