Project Development Schedule shall have the meaning set forth in Section 3.2.1(m) hereof.

Project Development Schedule means the project development schedule of milestone activities and milestone completion dates set forth in Schedule B to this Agreement.

Examples of Project Development Schedule in a sentence

If Owner fails to complete a milestone activity specified in the Project Development Schedule by the associated milestone completion date, and if, in ISO’s reasonable judgment, such failure compromises Owner’s ability to Deliver Committed Capability commencing on April 1, 2001, ISO shall have the right to terminate this Agreement under Section 12.3 (Termination for Default).
Each such monthly report shall describe Owner’s progress with respect to each milestone activity specified in the Project Development Schedule and shall identify any event or circumstance that will affect, or may reasonably be expected to affect, Owner’s ability to successfully complete the activity by the associated milestone completion date.
Material obligations under this Agreement shall include, without limitation, Owner’s obligations to develop the Project in accordance with the Project Development Schedule under Article 3, to make refunds under Article 5 and to Deliver Committed Capability under Article 6.
In addition, Owner shall notify ISO in writing upon its successful completion of each milestone activity specified in the Project Development Schedule.

More Definitions of Project Development Schedule

Project Development Schedule means the schedule referred to in Section 2.2 and shown on Exhibit B.

Project Development Schedule means the terms and other conditions including the time schedule related to the development by Ultimatte of the Keyer Unit, such project Development Schedule to be mutually agreed upon by SBS and Ultimatte and when agreed upon shall be deemed to be a part of this Agreement.

Project Development Schedule means the final development schedule forthe Project, including the Public Components and Private Components thereof, which shall include a proposed timeline for the completion of all pre-development, development, and construction activities relating to the Project, as approved in accordance with this Agreement, which when finalized and agreed to shall be incorporated in (and subject to amendment as may be provided by) each of the respective Ground Leases, the Construction Contract, or the Contingency Agreement.

Project Development Schedule means the schedule for completion of the Work and other Collaboration Activities necessary to commence the Academic Programs, which schedule is set forth on Exhibit C.

Project Development Schedule means the schedule referred to in Section 2.4 and shown on

Project Development Schedule means the progressive Project milestones set forth in