Product Schedule means a product schedule documenting the specific terms and conditions applying to a Product as may be amended, updated or replaced from time to time (and includes any Electronic Platform Schedules);
Development Schedule shall have the meaning set forth in Section 1.1.
Project Plan means the document to be developed by the Contractor and approved by WTL, based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalized Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by WTL. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.
Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.
MSAA Indicator Technical Specifications document means, as the context requires, either or both of the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Indicator Technical Specifications November 5, 2018 Version 1.3” and the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Target and Corridor-Setting Guidelines” as they may be amended or replaced from time to time;
low protein modified food product means a food product that is specially formulated to have less than one gram of protein per serving and is intended to be used under the direction of a Practitioner for the dietary treatment of an inherited metabolic disease, but does not include a natural food that is naturally low in protein; and
The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.
Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each and clearly allocate requested grant funding and match contributions to each.
BASE budget means the minimum general fund budget of a district, which includes 80% of the basic
Wind-Down Budget means a budget to be prepared by the Debtors, and reasonably acceptable to the Deerfield Requisite Supporting Noteholders, the Unaffiliated Requisite Supporting Noteholders, and the Committee, which shall be filed with the Court as part of the Plan Supplement, and which may be amended from time to time after entry of the Confirmation Order, subject to the consent of the Oversight Committee, which consent shall not be unreasonably withheld, and which shall estimate the funds necessary to administer the Plan and wind down the Debtors’ affairs, including the costs of holding and liquidating the Estates’ remaining property, objecting to Claims, making the Distributions required by the Plan, prosecuting claims and Causes of Action that may be held by the Estates against third parties that are not released, waived or transferred pursuant to the Plan (including pursuant to Article X) or otherwise, paying Taxes, filing Tax returns, paying professionals’ fees and expenses, paying the fees and expenses of the Oversight Committee, funding payroll and other employee costs, providing for the purchase of errors and omissions insurance and/or other forms of indemnification for the Plan Administrator, and for all such items and other costs of administering the Plan, the Estates and the Liquidating Debtors (other than the Administrative and Priority Claims Reserve, the Disputed Claims Reserve, and the Professional Fee Reserve).
Resting Quote means any firm or indicative bid or offer displayed on an Order Book.
New Service Request means an Interconnection Request, a Completed Application, or an Upgrade Request.
Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.
Development Budget means the cost categories listed on Pages 8 - 11 in Form 3 that are directly related to the proposed Project as submitted in the Application. Indirect or off-site costs not directly related to the development of the project are not valid or eligible costs.
Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:
Development Report means a written account of Licensee’s progress under the Development Plan having at least the information specified on Appendix B to this Agreement, and shall be sent to the address specified on Appendix B.
Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.
Qualified Project Costs means Project Costs that meet each of the following requirements: (i) the costs are properly chargeable to capital account (or would be so chargeable with a proper election by the Borrower or but for a proper election by the Borrower to deduct such costs) in accordance with general Federal income tax principles and in accordance with United States Treasury Regulations §1.103-8(a)(1), provided, however, that only such portion of interest accrued during rehabilitation of the Projects shall be eligible to be a Qualified Project Cost as is so capitalizable and as bears the same ratio to all such interest as the Qualified Project Costs bear to all Project Costs; and provided further that interest accruing after the date of completion of the rehabilitation of the Projects shall not be a Qualified Project Cost; and provided still further that if any portion of any of the Projects is being rehabilitated by an Affiliated Party (whether as a general contractor or a subcontractor), Qualified Project Costs shall include only (A) the actual out-of-pocket costs incurred by such Affiliated Party in rehabilitating the Projects (or any portion thereof), (B) any reasonable fees for supervisory services actually rendered by the Affiliated Party, and (C) any overhead expenses incurred by the Affiliated Party which are directly attributable to the work performed on the Projects, and shall not include, for example, intercompany profits resulting from members of an affiliated group (within the meaning of Section 1504 of the Code) participating in the rehabilitation of the Projects or payments received by such Affiliated Party due to early completion of the rehabilitation of the Projects; (ii) the costs are paid with respect to a qualified residential rental project or projects within the meaning of Section 142(d) of the Code, (iii) the costs are paid after the earlier of 60 days prior to the Inducement Date or the Closing Date, and (iv) if the Project Costs were previously paid and are to be reimbursed with proceeds of the Loan or the Bonds, such costs were (A) costs of issuance of the Issuer Note, (B) preliminary capital expenditures (within the meaning of United States Treasury Regulations §1.139-2(f)(2)) with respect to the Projects (such as architectural, engineering and soil testing services) incurred before commencement of the rehabilitation of the Projects that do not exceed twenty percent (20%) of the issue price of the Bonds (as defined in United States Treasury Regulations §1.148-1), or (C) were capital expenditures with respect to the Projects that are reimbursed no later than eighteen
Project Plans mean the plans for the Project that are attached to this Agreement as Exhibit “B.”
Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.
License Type means the identification of whether the license for a Software Product is for a Perpetual Term or Subscription Term as specified in the Quote.
Research Plan shall have the meaning set forth in Section 2.1.
Non-Microsoft Product means any third-party-branded software, data, service, website or product, unless incorporated by Microsoft in a Product.
Development Plan has the meaning set forth in Section 3.2.