Required Completion Date definition

Required Completion Date means November 1, 2006. Landlord and Tenant acknowledge and agree that: (i) the determination of the Commencement Date shall take into consideration the effect of any Tenant Delays; and (ii) the Required Completion Date shall be postponed by the number of days the Commencement Date is delayed due to events of Force Majeure. Notwithstanding anything herein to the contrary, if Landlord determines in good faith that it will be unable to cause the Commencement Date to occur by the Required Completion Date, Landlord shall have the right to immediately cease its performance of the Landlord Work and provide Tenant with written notice (the "Completion Date Extension Notice") of such inability, which Completion Date Extension Notice shall set forth the date on which Landlord reasonably believes that the Commencement Date will occur. Upon receipt of the Completion Date Extension Notice, Tenant shall have the right to terminate this Lease by providing written notice of termination to Landlord within 5 Business Days after the date of the Completion Date Extension Notice. If Tenant does not terminate this Lease within such 5 Business Day period, the Required Completion Date automatically shall be amended to be the date set forth in Landlord's Completion Date Extension Notice.

Required Completion Date means the date set forth in a Notice to Proceed by which Tenant must complete Approved Project, except as such date may be extended in accordance with the provisions herein.

Required Completion Date means June 1, 2009, provided, however, that the Required Completion Date may be extended by Lender to December 1, 2009 in Lender's sole discretion.

Examples of Required Completion Date in a sentence

• The Required Completion Date may be revised only by the Purchaser by issuing an extension time or an acceleration order in writing.

• The Supplier shall commence execution of the Supplies on the Start Date and shall carry out the Supplies in accordance with the work schedule submitted by the Supplier, as updated with the approval of the Project Supervisor, and complete them by the Required Completion Date.

• Project Float – The difference between the Scheduled Completion Date and Required Completion Date.

• The Improvements shall not have been injured or damaged by fire, explosion, accident, flood or other casualty, unless Lender shall have received insurance proceeds sufficient in the reasonable judgment of Lender to effect the satisfactory restoration of the Improvements and to permit the Completion of the Improvements prior to the Required Completion Date.

• The Project Improvements shall not have been injured or damaged by fire, explosion, accident, flood or other casualty, unless Lender shall be satisfied that sufficient insurance proceeds will be available in the reasonable judgment of Lender to effect the satisfactory restoration of the Project Improvements and to permit the Completion of the Improvements prior to the Required Completion Date.

More Definitions of Required Completion Date

Required Completion Date means the date specified in the Memorandum, subject to any amendment granted by Homes England in accordance with clause 5.5 from time to time

Required Completion Date means with respect to the Required Capital Improvements the applicable date for the applicable component of the Required Capital Improvements identified on Exhibit E.

Required Completion Date means June 30, 2008.

Required Completion Date has the meaning set forth in Section 5.3.

Required Completion Date means the date certain upon which the Grantee agrees to accomplish the activities and tasks described in Attachments 1 and 2 to this Agreement and begin providing the additional service in the corridor as identified in the application submitted to FTA.

Required Completion Date means May 15, 2022. The Required Completion Date is subject to extension, day-for-day, (a) to the extent of any delay caused by the occurrence and continuance of a Force Majeure Event; provided, however, that in no event will the Required Completion Date be extended beyond November 15, 2022, or (b) to the extent of any delay caused by Lender’s failure to make Disbursements in violation of this Agreement following Borrower’s satisfaction of each of the conditions for Disbursement herein.

Required Completion Date means December 31, 2007 with respect to the Base Building Improvements.