Site Engineers definition

Site Engineers means the Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by Institute works department.
Sample 1Sample 2Sample 3
Site Engineers means the AEE (Civil)/ Junior Engineer (Civil)/Junior Engineer (Electrical) appointed by Works & Estate department.
Sample 1Sample 2Sample 3
Site Engineers means the AEE (Civil)/ Junior Engineer (Civil)/Junior
Sample 1Sample 2Sample 3

Examples of Site Engineers in a sentence

  • Duties & Powers : i) Site Engineers : The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship employed in connection with the works, and to test and examine any materials to be used.

  • He shall have no authority to relieve the contractor of any of his duties or obligations under the contract, except as expressly provided here under, nor to order any work involving delay or any extra payment by the Institute and to make any variation in the works.The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them.

  • The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them.

  • The work being carried out by the contractor will be supervised and inspected by our Site Engineers under the overall supervision of BHEL Resident Engineer.

  • The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship employed in connection with the works, and to test and examine any materials to be used.

  • Site Engineers are familiar with the location of the documents in the event of an emergency situation.

  • The Engineer-in-charge, from time to time in writing, delegate to the Site Engineer(s) any of the powers and authorities vested in them.

  • He shall have no authority to relieve the contractor of any of his duties or obligations under the contract, except as expressly provided hereunder, nor to order any work involving delay or any extra payment by the Institute and to make any variation in the works.The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them.

  • The bank may also determine the number of Site Engineers and the supporting staff at site office to assist them and also whether the Site Engineer shall be temporary or permanent.

  • One Site Engineers with 3 years of experience having Civil Engineering.


More Definitions of Site Engineers

Site Engineers means the Project Manager, Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by Institute works department. 2. DUTIES & POWERS:2.1 Site Engineers:The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship in connection with the works, and to test and examine any materials to be used. He shall have no authority to relieve the contractor of any of his duties or obligations under the contract, except as expressly provided here under, nor to order any work involving delay or any extra payment by the Institute and to make any variation in the works.The Engineer‐in‐charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them. Any written instruction or written approval given by the Site Engineer (s) to the contractor within the terms of such delegation (but not otherwise) shall bind the contractor and the Institute as though it had been given by the Engineer‐in‐charge provided always as follows :
Sample 1
Site Engineers means the AEE /Assistant Engineer (Electrical)/ Engineer appointed by the Works & Estate department.
Sample 1Sample 2
Site Engineers means the Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by Institute works department. 2. DUTIES & POWERS : 2.1 Site Engineers : The duties of the Site Engineer(s) are to watch and supervise the works and the workmanship in connection with the works, and to test and examine any materials to be used. He shall have no authority to relieve the contractor of any of his duties or obligations under the contract, except as expressly provided here under, nor to order any work involving delay or any extra payment by the Institute and to make any variation in the works.The Engineer-in-charge, from time to time in writing, delegates to the Site Engineer(s) any of the powers and authorities vested in them. Any written instruction or written approval given by the Site Engineer (s) to the contractor within the terms of such delegation (but not otherwise) shall bind the contractor and the Institute as though it had been given by the Engineer-in-charge provided always as follows : Failure of the Site Engineer (s) to disapprove any work or materials shall not prejudice the power of the Engineer in-charge to subsequently disapprove such work or materials and to order the pulling down, removal or breaking up thereof. If the contractor is dissatisfied by reason of any decision of the Site Engineer (s), he shall be entitled to refer the matter to the Engineer-in-charge, who shall thereupon confirm reverse or vary such decision. 3. ASSIGNMENT & SUBLETTING: 3.1 The contractor shall not assign the contract or any part thereof or any benefit or interest therein or there under without the written consent of the Engineer in-charge. The whole of the works included in the contract shall be executed by the contractor except where otherwise provided in the contract. The contractor shall not sublet any part of the works without the written consent of the Engineer in-charge and such consent, if given, shall not relieve the contractor from any liability or obligation under the contract, and he shall be responsible for the acts, defaults and neglects of sub-contractor, his agents, servants or workmen, as if they were the acts, defaults or neglects of the contractor provided always that the provision of labour contracts on a piece work basis shall not be deemed to be a subletting under this clause. 4. SCOPE OF CONTRACT:The contract comprises the construction, completion and maintenance of the works for twelve (12) months after the completion, and the provision of all labou...
Sample 1
Site Engineers means the appointed by Institute works department.
Sample 1
Site Engineers means the Assistant Executive Engineer, Assistant Engineer & Jr. Engineer (Civil / Electrical)/ Project Site Engineer (Civil/Electrical) appointed by Institute works department.
Sample 1
Site Engineers means the Assistant Engineer & Jr. Engineer (Civil / Electrical) appointed by the Institute.
Sample 1

Related to Site Engineers

  • Site Engineer means an Engineer appointed by the SBIIMS at site as their representative for day-to-day supervision of work and to give instructions to the contractors.

  • Geotechnical engineer means a professional engineer registered with the Association of Professional Engineers, Geologists, and Geophysicists of the Northwest Territories and whose principal field of specialization is the design and construction of earthworks in a permafrost environment;

  • Architect/Engineer or “A/E” means the Person identified in the Agreement responsible for providing professional design services and construction contract administration for the Project. The A/E shall be (1) a registered architect holding a license and certificate of authorization issued by the Ohio Architects Board pursuant to ORC Chapter 4703, (2) a landscape architect holding a license and certificate of authorization issued by the Ohio Landscape Architects Board pursuant to ORC Chapter 4703, or (3) a professional engineer or professional surveyor holding a license and certificate of authorization issued by the Ohio Engineers and Surveyors Board pursuant to ORC Chapter 4733. As used in the Agreement, the term A/E may include a criteria architect or engineer for a Design-Build project.

  • Engineers Certificate" shall mean a certificate of the Consulting Engineers or of such other engineer or firm of engineers having a favorable repute for skill and experience in the engineering matters with respect to which such certification is required by this Master Indenture.

  • Architect/Engineer (A/E means a person registered as an architect pursuant to Tex. Occ. Code Ann., Ch. 1051, as a landscape architect pursuant to Tex. Occ. Code Ann., Ch. 1052, a person licensed as a professional engineer pursuant Tex. Occ. Code Ann., Ch. 1001, and/or a firm employed by Owner or Design-Build Contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • SBI Engineer means The Civil/Electrical Engineer in-charge of the Project, as nominated by the AGM (P&E), SBI, RAJKOT

  • Project Architect means the architect retained by Lessee to design and supervise construction of the Improvements.

  • Architect or Engineer means an individual, firm, partnership, association, properly qualified person or the legally authorized representative(s), designated by the Owner, experienced in and legally qualified to practice the profession involved for the administration of the contract, inspections and testing. The term shall apply to the Owner when the Owner is acting as its own Architect or Engineer.

  • Structural Engineer means the Engineer appointed or to be appointed from time to time by Promoter for the preparation of the structural design and drawings of the buildings .

  • Consulting Engineers means the independent engineer or engineering firm or corporation employed in connection with any Project to perform and carry out the duties of the Consulting Engineer under this Indenture or any Supplemental Indenture.

  • Banks Engineer means any Engineer who is employed by SBI or any other Engineer appointed from time to time by the Employer, and certified in writing to the Architect and the contractor, to act as Engineer for the purpose of the Contract in place of the said engineer.

  • State Engineer means the person holding the position as head of the state engineer’s office.

  • Systems Engineering means preparing specifications, identifying and resolving interface problems, developing test requirements, evaluating test data, and supervising design.

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • Value Engineering (VE) means a discipline of engineering that studies the relative monetary values of various materials and construction techniques, including the intial cost, maintenance cost, energy usage, replacement cost, and life expectancy of the materials, equipment or systems under consideration.

  • Project Engineer means the surveyor or engineer employed by or private

  • Professional Engineer means a person entitled to practise as a Professional Engineer in the Province of Ontario under a licence issued under the Professional Engineers Act;

  • Design engineer means a person professionally qualified and duly licensed in New Jersey to perform engineering services that may include, but not necessarily be limited to, development of project requirements, creation and development of project design and preparation of drawings and specifications.

  • Architects means any Architect whom the Vendors and the Builder have appointed as the Architects for the Project / Buildings time to time.

  • COMPANY ENGINEER means the following:

  • Civil engineer means a professional engineer registered in the state of California to practice in the field of civil engineering.

  • Independent Engineer means XxXxxxxx and XxxXxxxxxxx or any other third party engineering firm acceptable to the Administrative Agent in its sole discretion.

  • The Engineer means the Engineer appointed by the Purchaser for the purpose of this contract.

  • City Engineer s Representative” shall mean an assistant of the City Engineer i.e. rank of Executive Engineer who will be called as Engineer-in-charge of work notified in writing to the Contractor by the City Engineer.

  • Authority’s Engineer shall have the meaning set forth in Clause 18.1;

  • County Engineer means the holder of the statutory office of County Engineer for Harris County or the employee designated by the County Engineer to perform a task required by these Regulations.