Transition Milestone definition

Transition Milestone means each date identified in the Transition Plan and the applicable Supplement as a milestone by which Supplier shall have completed a key task or set of tasks in accordance with the Transition Plan in a manner acceptable to Kraft.
Transition Milestone means any activity or Deliverable required to be completed pursuant to the Transition Plan for which a date or time for completion is specified.
Transition Milestone. An event designated as such in the Transition Plan. The Transition Milestones shall include those Payment Milestones designated as such in the Transition Plan

Examples of Transition Milestone in a sentence

  • This might have seemed obvious, since the school was using i.t.a. However, i.t.a. teachers generally were not doing this: they were using the teaching style they were familiar with, mostly look-and-say.

  • The Transition Milestone Plan (the “Transition Plan”) is designed to provide economic motivation for Contractor to meet timeline requirements of the Contract during the beginning of Contractor’s engagement based on completion and acceptance of defined transition milestones (“Milestones”).

  • The Successful Respondent will invoice the approved amount determined to be the fair market value for the retained assets as a Transition Milestone.

  • Service Provider shall submit the inventory data to DIR for DIR’s review in accordance with the criteria set forth in the Resource Baseline True-Up Transition Milestone in Exhibit 19.

  • Associate Company in relation to another company, means a company (not a subsidiary) in which that other company has a significant influence and includes a joint venture company.


More Definitions of Transition Milestone

Transition Milestone. Section 6.1
Transition Milestone has the meaning set forth in Section 3.2(B)(1) of the Agreement.
Transition Milestone has the meaning given in Section 4.2(c).
Transition Milestone means each date identified on the applicable Transition Plan as a milestone by which Amdocs shall have completed a certain task or set of tasks in such Transition Plan in a manner acceptable to AT&T.
Transition Milestone means each milestone identified in the Transition Schedule.
Transition Milestone means a date identified on the Transition Plan as a milestone by which IBM shall have completed a certain task or set of tasks in the Transition Plan in a manner acceptable to ACE. The Parties acknowledge and agree that the failure to complete such tasks by the specified dates may have an adverse impact on contract operations.
Transition Milestone means each date identified on the Transition Plan as a milestone by which Amdocs shall have completed a certain task or set of tasks in the Transition Plan in a manner reasonably acceptable to SBC.