Uncontrollable Force means any cause beyond the control of the Borrower, including: (a) a hurricane, tornado, flood or similar occurrence, landslide, earthquake, fire or other casualty, strike or labor disturbance, freight embargo, act of a public enemy, explosion, war, blockade, terrorist act, insurrection, riot, general arrest or restraint of government and people, civil disturbance or similar occurrence, sabotage, or act of God (provided that the Borrower shall not be required to settle any strike or labor disturbance in which it may be involved) or (b) the order or judgment of any federal, state or local court, administrative agency or governmental officer or body, if it is not also the result of willful or negligent action or a lack of reasonable diligence of the Borrower and the Borrower does not control the administrative agency or governmental officer or body; provided that the diligent contest in good faith of any such order or judgment shall not constitute or be construed as a willful or negligent action or a lack of reasonable diligence of the Borrower.
Uncontrollable Forces means any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the reasonable control of the nonperforming party. It includes, but is not limited to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, and governmental actions.
Uncontrollable Circumstance means any act, event or condition that is:
Probable cause means that there is a substantial objective basis for believing that, more likely than not, an offense has been committed and a person to be arrested has committed it.
Controllable Operating Expenses means all Operating Expenses except property taxes and assessments, capital expenditures that are reasonably required, costs for repairs and maintenance (excluding preventative maintenance), utility charges, insurance charges, costs of services provided under a union contract, payments under covenants, conditions and restrictions or to an owners’ association and costs associated with repairs due to casualty, vandalism or other cause outside of Landlord’s reasonable control.
Controllable Expenses means all expenses, other than Uncontrollable Expenses, incurred by the Company or any Subsidiary of the Company with respect to the Property.
Constructive Termination means:
Total Fund Operating Expenses with respect to a Fund is defined to include all expenses necessary or appropriate for the operation of the Fund including the Adviser’s investment advisory or management fee under the Advisory Agreement and other expenses described in the Advisory Agreement that the Fund is responsible for and have not been assumed by the Adviser, but excludes front-end or contingent deferred loads, taxes, leverage expenses, interest, brokerage commissions, expenses incurred in connection with any merger or reorganization, unusual or infrequently occurring expenses (such as litigation), acquired fund fees and expenses, and dividend expenses, if any.
Constructive Termination Without Cause means a termination of the Executive's employment at his initiative as provided in this Section 10(c) following the occurrence, without the Executive's written consent, of one or more of the following events (except as a result of a prior termination):
Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Total Compensation means the cash and noncash dollar value earned by the executive during the Contractor’s preceding fiscal year and includes the following (for more information see 17 CFR 229.402(c)(2)):
Total Operating Expenses means all costs and expenses paid or incurred by the Company, as determined under generally accepted accounting principles, that are in any way related to the operation of the Company or to Company business, including advisory fees, but excluding (i) the expenses of raising capital such as Organization and Offering Expenses, legal, audit, accounting, underwriting, brokerage, listing, registration, and other fees, printing and other such expenses and tax incurred in connection with the issuance, distribution, transfer, registration and Listing of the Shares, (ii) interest payments, (iii) taxes, (iv) non-cash expenditures such as depreciation, amortization and bad debt reserves, (v) incentive fees paid in compliance with the NASAA REIT Guidelines, (vi) Acquisition Fees and Acquisition Expenses, (vii) real estate commissions on the Sale of Properties, (viii) Financing Coordination Fees and (ix) other fees and expenses connected with the acquisition, disposition, management and ownership of real estate interests, mortgage loans or other property (including the costs of foreclosure, insurance premiums, legal services, maintenance, repair and improvement of property).
Accretion Termination Date As defined in the Series Supplement.
Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of:
(1) any unreasonable delay by Tenant in approving the Plans;
(2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason;
(3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant;
(4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or
(5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.
Reasonable cause as used in this policy means an articulable belief based on specific facts and reasonable inferences drawn from those facts that an employee is more likely than not under the influence of controlled substances or alcohol or has used drugs or alcohol in violation of this policy. Circumstances which can constitute a basis for determining "reasonable cause" may include, but are not limited to:
Common Area Operating Expenses are defined, for purposes of this Lease, as all costs incurred by Lessor relating to the ownership and operation of the Industrial Center, including, but not limited to, the following:
(i) The operation, repair and maintenance, in neat, clean, good order and condition, of the following:
Substantial cause means Employee’s (1) failure to substantially perform Employee’s duties; (2) material breach of this Agreement; (3) misconduct, including but not limited to, use or possession of illegal drugs during work and/or any other action that is damaging or detrimental in a significant manner to the Company; (4) conviction of, or plea of guilty or nolo contendere to, a felony; or (5) failure to cooperate with, or any attempt to obstruct or improperly influence, any investigation authorized by the Board of Directors or any governmental or regulatory agency.
Planned special exposure means an infrequent exposure to radiation, separate from and in addition to the annual occupational dose limits.
Effluent limitation means any restriction imposed by the Director on quantities, discharge rates, and concentrations of pollutants that are discharged from point sources into waters of the United States, the waters of the contiguous zone, or the ocean.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Total suspended solids means measure of all suspended solids in a liquid; typically expressed in mg/L.
Permanent Disablement means a disability falling under one of the items of disablement listed in the scale of compensation in this Policy under Section 1, which was caused by an Accident, as long as the disability lasts for twelve (12) consecutive months from the date of the Accident and at the expiry of that period our appointed Registered Medical Practitioner confirms that the disability is not going to improve after twelve (12) months.
Permanent total disability means incapacity because of accidental injury or occupational disease to earn any wages in any employment for which the employee may become physically suited and reasonably fitted by education, training or experience, including vocational rehabilitation; loss of both hands, or both feet, or both legs, or both eyes, or any two thereof, shall constitute permanent total disability;
Deactivation Avoidable Cost Credit means the credit paid to Generation Owners pursuant to Tariff, Part V, section 114.
Event of Withdrawal has the meaning assigned to such term in Section 11.1(a).
Permanent Total Disablement means a bodily injury caused by accidental, external, violent and visible means, which as a direct consequence thereof totally disables and prevents the insured from attending to any business or occupation of any and every kind or if he/she has no business or occupation, from attending to his/her usual and normal duties that last for a continuous period of twelve calendar months from the date of the accident, with no hopes of improvement in future