Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Scope Change means any change to the scope of a contract to accommodate a need not originally provided for in the contract and which may include the acquisition of additional deliverables or the extension of the term of the contract and which may require an adjustment to the contract price;
Major Change means any event or proposed modification that, in the opinion of the Fund, will involve a major change in, or a restructuring of, a Funded Activity’s scope, structure, design or objectives, including a reallocation of GCF Proceeds beyond the threshold set out in the relevant FAA affecting the Funded Activity’s scope or objectives, or any other change that substantially alters the purpose or benefit of the Funded Activity, in each case, as may be described in detail in the relevant FAA;
Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;
Progress Schedule means a schedule of the Work, in a form satisfactory to Owner, as further set forth in Section 3.02.
Schedule of Work means that schedule attached to the Interconnection Construction Service Agreement setting forth the timing of work to be performed by the Constructing Entity pursuant to the Interconnection Construction Service Agreement, based upon the Facilities Study and subject to modification, as required, in accordance with Transmission Provider’s scope change process for interconnection projects set forth in the PJM Manuals.
Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.
Development Schedule shall have the meaning set forth in Section 1.1.
Program change means any elimination, curtailment or reorganization of a curriculum offering, program or school operation or a reorganization or closing of a school or consolidation of two or more individual schools or school districts that is unrelated to financial exigency.
Specification Schedule means the Schedule containing details of the Specification.
Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.
Service Change has the meaning set forth in Section 2(B) of the Agreement.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.
Design Change is a change in work and/or materials shown in the Schedule of Items and described in Plans or specifications that has been mutually agreed to in writing or ordered by Contracting Officer. Changes of a minor nature (such as adjustment in horizontal and vertical alignment, that do not exceed specified tolerance, necessary to maintain or balance earthwork quantities substantially as designed) and variation in quantities, as described in B5.251, shall not be considered Design Changes.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.
Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.
Shift Schedule means a written statement setting forth the days and hours upon which the employees are required to work.
Project Description means the document that describes the Project's Reduction activities and that uses either the VCS Project Description Template or the project description template specified by the relevant Approved GHG Program;
Product Schedule means the “Product Schedule” that forms part of the Contract.
Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each, and clearly allocate requested grant funding and match contributions to each.
BASE budget means the minimum general fund budget of a district, which includes 80% of the basic
Contract Schedule The list (as such list may be amended from time to time) identifying each Contract constituting part of the corpus of the Trust Fund as of the Cut-off Date, and which (a) identifies each Contract as either a Fixed Rate Contract or Adjustable Rate Contract and by contract number and name and address of the Obligor and (b) sets forth as to each Contract (i) the unpaid principal balance as of the related Transfer Date determined by giving effect to payments received prior to the related Transfer Date, (ii) the amount of each scheduled payment due from the Obligor, and (iii) the APR.
Major Work means any Work to Construct or Maintain the Distribution System that costs more than One Hundred Thousand ($100,000.00) Dollars;