Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Post-Closing Access (a) Each of Seller and Buyer shall, and Buyer shall cause the Company to, preserve and keep all books and records and other information relating to the accounting, legal, Tax, regulatory, business and financial affairs of the Company and the Rolling Mill Business for a period of seven (7) years after the Closing Date (or, in the case of information relating to Taxes, until the expiration of any applicable statute of limitations), or for a longer period if (i) required by Law (including any statute of limitations and applicable extensions thereof) or any Governmental Authority or (ii) reasonably necessary with respect to the prosecution or defense of any audit or other legal or regulatory action that is then pending or threatened so long as the requesting Party has notified the other Party with prior written notice of the need to retain such books, records or information.
(b) Following the Closing, for so long as such information is retained by Buyer in accordance with Section 5.8(a), Buyer shall, and shall cause the Company, to permit Seller and its authorized Representatives, at Seller’s sole cost and expense, to have reasonable access and duplication rights during normal business hours, upon reasonable prior written notice to Buyer to the information described in Section 5.8(a) to the extent that such access may be reasonably required in connection with (i) the preparation of any Tax Return, accounting records or with respect to any Tax Claim or similar proceedings, (ii) any Action relating to Seller, the Company or the Rolling Mill Business, (iii) any Governmental Filing or matter (including investigations by Governmental Authorities) or (iv) any other valid legal or business purpose. Notwithstanding the foregoing, Seller shall have no right of access to, and Buyer shall have no obligation to provide, (A) any information if doing so would reasonably be expected to (1) violate any Contract or Law to which Buyer or any of its Affiliates (including the Company) is a party or is subject, (2) result in a loss of the ability to successfully assert a claim of privilege (including the attorney-client and work product privileges), (3) result in the disclosure of any competitively sensitive information of Buyer or of any of its Affiliates (including the Company), or (4) breach a confidentiality or other obligation to a Third Party (provided that Buyer shall use commercially reasonable efforts to obtain the consent of any Third Party with regards to such disclosure), or (B) any consolidated, combined, affiliated or unitary Tax Return which includes Buyer or any of its Affiliates (including the Company) or any Tax-related work papers.
(c) Following the Closing, for so long as such information is retained by Seller in accordance with Section 5.8(a), Seller shall permit Buyer and its authorized Representatives, at Buyer’s sole cost and expense, to have reasonable access and duplication rights during normal business hours, upon reasonable prior written notice to Seller, to the information described in Section 5.8(a) to the extent that such access may be reasonably required in connection with (i) the preparation of any Tax Return, accounting records or with any Tax Claim or similar proceedings, (ii) any Action relating to the Company or the Rolling Mill Business, (iii) any Governmental Filing or matter (including investigations by Governmental Authorities) or (iv) any other valid legal or business purpose. Notwithstanding the foregoing, Buyer shall have no right of access to, and Seller shall have no obligation to provide, (A) any information if doing so would reasonably be expected to (1) violate any Contract or Law to which Seller or any of its Affiliates is a party or is subject,
Lane closure (i) The Contractor shall not close any lane of the Project Highway for undertaking maintenance works except with the prior written approval of the Authority’s Engineer. Such approval shall be sought by the Contractor through a written request to be made at least 10 (ten) days before the proposed closure of lane and shall be accompanied by particulars thereof. Within 5 (five) business days of receiving such request, the Authority’s Engineer shall grant permission with such modifications as it may deem necessary and a copy of such permission shall be sent to the Authority.
(ii) Upon receiving the permission pursuant to Clause 14.5 (i), the Contractor shall be entitled to close the designated lane for the period specified therein, and for all lane closures extending a continuous period of 48 (forty-eight) hours, the Contractor shall, in the event of any delay in re-opening such lane, for every stretch of 250 (two hundred and fifty) metres, or part thereof, pay Damages to the Authority calculated at the rate of 0.1% (zero point one per cent) of the monthly maintenance payment for each day of delay until the lane has been re-opened for traffic. In the event of any delay in re-opening such lanes or in the event of emergency decommissioning and closure to traffic of the whole or any part of the Project Highway due to failure of the Contractor, the Contractor shall pay damages to the Authority at double the above rate, without prejudice the rights of the Authority under this Agreement including Termination thereof.
Post-Closing Conditions On or before the date specified in this Section 4.3 (unless a longer period is agreed to in writing by the Administrative Agent, in its reasonable discretion), the Borrower shall satisfy each of the following items specified in the subsections below:
ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Post Closing Agreements From and after the Closing, the parties shall have the respective rights and obligations which are set forth in the remainder of this Article VI.
Unbundled Loop Modifications (Line Conditioning 2.5.1 Line Conditioning is defined as routine network modification that BellSouth regularly undertakes to provide xDSL services to its own customers. This may include the removal of any device, from a copper Loop or copper Subloop that may diminish the capability of the Loop or Subloop to deliver high-speed switched wireline telecommunications capability, including xDSL service. Such devices include, load coils, excessive bridged taps, low pass filters, and range extenders. Excessive bridged taps are bridged taps that serves no network design purpose and that are beyond the limits set according to industry standards and/or the BellSouth’s TR 73600 Unbundled Local Loop Technical Specification.
2.5.2 BellSouth will remove load coils only on copper Loops and Subloops that are less than eighteen thousand (18,000) feet in length.
2.5.3 For any copper loop being ordered by NewPhone which has over six thousand (6,000) feet of combined bridged tap will be modified, upon request from NewPhone, so that the loop will have a maximum of six thousand (6,000) feet of bridged tap. This modification will be performed at no additional charge to NewPhone. Loop conditioning orders that require the removal of bridged tap that serves no network design purpose on a copper Loop that will result in a combined total of bridged tap between two thousand five hundred (2,500) and six thousand (6,000) feet will be performed at the rates set forth in Exhibit A.
2.5.4 NewPhone may request removal of any unnecessary and non-excessive bridged tap (bridged tap between zero (0) and two thousand five hundred (2,500) feet which serves no network design purpose), at rates pursuant to BellSouth’s SC Process as mutually agreed to by the Parties.
2.5.5 Rates for ULM are as set forth in Exhibit A.
2.5.6 BellSouth will not modify a Loop in such a way that it no longer meets the technical parameters of the original Loop type (e.g., voice grade, ADSL, etc.) being ordered.
2.5.7 If NewPhone requests ULM on a reserved facility for a new Loop order, BellSouth may perform a pair change and provision a different Loop facility in lieu of the reserved facility with ULM if feasible. The Loop provisioned will meet or exceed specifications of the requested Loop facility as modified. NewPhone will not be charged for ULM if a different Loop is provisioned. For Loops that require a DLR or its equivalent, BellSouth will provide LMU detail of the Loop provisioned.
2.5.8 NewPhone shall request Loop make up information pursuant to this Attachment prior to submitting a service inquiry and/or a LSR for the Loop type that NewPhone desires BellSouth to condition.
2.5.9 When requesting ULM for a Loop that BellSouth has previously provisioned for NewPhone, NewPhone will submit a SI to BellSouth. If a spare Loop facility that meets the Loop modification specifications requested by NewPhone is available at the location for which the ULM was requested, NewPhone will have the option to change the Loop facility to the qualifying spare facility rather than to provide ULM. In the event that BellSouth changes the Loop facility in lieu of providing ULM, NewPhone will not be charged for ULM but will only be charged the service order charges for submitting an order.
Post-Closing Matters Execute and deliver the documents and complete the tasks set forth on Schedule 6.14, in each case within the time limits specified on such schedule, as such time limits may be extended from time to time by Agent in its reasonable discretion.
School Closure The following shall apply in the event of an NPS school closure due to an emergency consistent with guidelines followed by LEAs under Education Code Section 41422 and 46392: In the event of a NPS School Closure for the reasons set forth in Education Code section 41422, if the LEA is able to obtain alternative placement for the student, CONTRACTOR shall not receive payment for days the student is not in attendance due to CONTRACTOR’S school closure. If the LEA is unable to obtain an alternative placement, CONTRACTOR shall receive payment consistent with the student’s approved ISA, contingent upon the provision of agreed upon services consistent with the Emergency Circumstances documented in the pupil’s IEP in accordance with Education Code section 56345(a)(9). When the emergency school closure is lifted, CONTRACTOR shall notify the LEAs it serves of any lost instructional minutes. CONTRACTOR and XXXx shall work collaboratively to determine the need for make-up days or service changes, and shall work together to amend IEP and ISA paperwork as appropriate.
