Additional Programme Requirements Sample Clauses

Additional Programme Requirements. A Level III programme is to be submitted with the Tender documentation, including Milestone dates. The Contractor uses the Critical Path Method (CPM) technique for programming and planning. The preparation of the programme contains a programme basis document. This basis document describes the programme and planning methodology, format, project execution philosophy, resource assumptions, qualifications and any other items that may have a substantive impact on the schedule. The programme is to be free of obvious errors related to sequence or timings of the works. The execution philosophy, programme and planning methodology, are to be described in the programme / schedule basis document for submission together with the tender documentation. The programme layout takes into account the functional group breakdown (WBS) reflecting the manner in which the works are to be performed and how control data are summarised, reported and monitored. The Project Calendar for installation/Execution will be discussed and the calendar must be clearly defined and accepted by the Project Manager in the Contract Document. Activity ID Numbers must clearly define the level of the WBS and take into account the functional group. The Level III Schedule will be composed of respective detailed Activities tied together logically. The detailed activity shall comprise of the following:  Sufficient information such as activity duration and description so as to be able to measure accurate progress within the required update period.  A clearly defined starting point.  A clearly defined completion point.  A clear description of the activity to be performed.  A single source of responsibility or ownership.
Sample 1Sample 2
AutoNDA by SimpleDocs
Additional Programme Requirements. The Consultant shall use the Critical Path Method (CPM) technique for programme and planning and shall submit the programme basis document to the Employer’s Agent. The programme basis document describes the programme and planning methodology, format, project execution philosophy, resource assumptions, qualifications and any other items that may have a substantive impact on the programme. The programme layout takes into account the Key Dates provided above and the Work Breakdown Structure (WBS). The following levels of programme are to be used for this project for dynamic integrated project control: Management level programme (Level 1) Project level programme (Level 2) Control level programme (Level 3) Discipline speciality programme (Level 4)
Sample 1
Additional Programme Requirements. The Contractor shall use the Critical Path Method (CPM) technique for programme and planning and shall submit the programme basis document to the Project Manager. The programme basis document describes the programme and planning methodology, format, project execution philosophy, resource assumptions, qualifications and any other items that may have a substantive impact on the schedule. The programme layout takes into account the Key Dates provided above and the Work Breakdown Structure (WBS). The following levels of programme are to be used for this project for dynamic integrated project control:  Management level programme (Level 1)  Project level programme (Level 2)  Control level programme (Level 3)  Discipline speciality programme (Level 4) The Contractor submits a Resource Loaded Level 4 Detailed Programme with the tender documentation. The Level 4 Detailed Programme is to be submitted within one month of contract award for review and acceptance by the Project Manager.
Sample 1
Additional Programme Requirements a. A level 4 (up to level activity) programme is to be submitted with the tender documentation. The CPM (Critical Path Method) technique is to be used for planning programme.
Sample 1
Additional Programme Requirements a. A programme is to be submitted after 14 days of contract award, stipulating high level execution of this project.
Sample 1

Related to Additional Programme Requirements

  • Software Requirements 7 Developer shall prepare the Project Schedule using Oracle’s Primavera P6.

  • Basic Requirements To be eligible for PayPal’s Seller Protection program, all of the following basic requirements must be met, as well as any applicable additional requirements: • The primary address for your PayPal account must be in the United States. • The item must be a physical, tangible good that can be shipped, except for items subject to the Intangible Goods Additional Requirements. Transactions involving items that you deliver in person in connection with payment made in your physical store, may also be eligible for PayPal’s Seller Protection program so long as the buyer paid for the transaction in person by using a PayPal goods and services QR code. • You must ship the item to the shipping address on the Transaction Details page in your PayPal account for the transaction. If you originally ship the item to the recipient’s shipping address on the Transaction Details page but the item is later redirected to a different address, you will not be eligible for PayPal’s Seller Protection program. We therefore recommend not using a shipping service that is arranged by the buyer, so that you will be able to provide valid proof of shipping and delivery. • The shipping requirement does not apply to eligible transactions involving items that you deliver in person; provided, however, that you agree to provide us with alternative evidence of delivery or such additional documentation or information relating to the transaction that we may request. • You must respond to PayPal’s requests for documentation and other information in a timely manner as requested in our email correspondence with you or in our correspondence with you through the Resolution Center. If you do not respond to PayPal’s request for documentation and other information in the time requested, you may not be eligible for PayPal’s Seller Protection program. • If the sale involves pre-ordered or made-to-order goods, you must ship within the timeframe you specified in the listing. Otherwise, it is recommended that you ship all items within 7 days after receipt of payment. • You provide us with valid proof of shipment or delivery. • The payment must be marked “eligible” or “partially eligible” in the case of Unauthorized Transaction claims, or “eligible” in the case of Item Not Received claims, for PayPal’s Seller Protection program on the Transaction Details page. • In the case of an Unauthorized Transaction claim, you must provide valid proof of shipment or proof of delivery that demonstrates that the item was shipped or provided to the buyer no later than two days after PayPal notified you of the dispute or reversal. For example, if PayPal notifies you of an Unauthorized Transaction claim on September 1, the valid proof of shipment must indicate that the item was shipped to the buyer no later than September 3 to be eligible for PayPal’s Seller Protection program. PayPal determines, in its sole discretion, whether your claim is eligible for PayPal’s Seller Protection program. PayPal will make a decision, in its sole discretion, based on the eligibility requirements, any information or documentation provided during the resolution process, or any other information PayPal deems relevant and appropriate under the circumstances. Item Not Received additional requirements To be eligible for PayPal’s Seller Protection program for a buyer’s Item Not Received claim, you must meet both the basic requirements and the additional requirements listed below: • Where a buyer files a chargeback with the issuer for a card-funded transaction, the payment must be marked “eligible” for PayPal’s Seller Protection on the Transaction Details page. • You must provide proof of delivery as described below.

  • Additional Requirements As a condition precedent to the execution and Delivery, the registration of issuance, transfer, split-up, combination or surrender, of any ADS, the delivery of any distribution thereon, or the withdrawal of any Deposited Property, the Depositary or the Custodian may require (i) payment from the depositor of Shares or presenter of ADSs or of an ADR of a sum sufficient to reimburse it for any tax or other governmental charge and any stock transfer or registration fee with respect thereto (including any such tax or charge and fee with respect to Shares being deposited or withdrawn) and payment of any applicable fees and charges of the Depositary as provided in Section 5.9 and Exhibit B, (ii) the production of proof reasonably satisfactory to it as to the identity and genuineness of any signature or any other matter contemplated by Section 3.1, and (iii) compliance with (A) any laws or governmental regulations relating to the execution and Delivery of ADRs or ADSs or to the withdrawal of Deposited Securities and (B) such reasonable regulations as the Depositary and the Company may establish consistent with the provisions of the representative ADR, if applicable, the Deposit Agreement and applicable law.

  • Training Requirements Grantee shall:

  • Additional Service Requirements Grantee shall:

  • Interface Requirements 9.3.1 BellSouth shall offer LIDB in accordance with the requirements of this subsection.

  • Equipment and Software Requirements In order to view and retain electronic communications that we make available to you, you must have: • A PC or other device with an Internet browser that has “cookies” enabled and supports 128 bit encryption • An Internet connection • An email address • A PDF viewer (such as Adobe Reader) • A printer or computer with sufficient electronic storage space All communications shall be delivered to the last address we have on file for you. These notices will be sent through electronic delivery (email) and will be considered delivered the same day as sent. If you have opted out of electronic delivery, communications sent to you through the United States Postal Service are considered delivered 5 business days after the postmark date. It is your responsibility to notify the Custodian of any email address change or residential address change. We will not be held liable for any losses or damages if you have not provided Custodian with the most current address information. The electronically signed copy of this document should be considered equivalent to a printed hard copy form. It is considered a true and complete record of the document, admissible in arbitration and/or administrative hearings or proceedings. Your electronic signature on the Application and other electronic forms such as the Investment Direction are considered valid and the same as if the paper form or Application were signed.

  • ON SITE REQUIREMENTS While on Purchaser’s premises, Contractor, its agents, employees, or subcontractors shall comply, in all respects, with Purchaser’s physical, fire, access, safety, and other security requirements.

  • Time Requirements The Independent Contractor will not be required to follow or establish a regular or daily work schedule, but shall devote during the term of this Agreement the time, energy and skill as necessary to perform the services of this engagement and shall, periodically or at any time upon the request of the Company, submit information as to the amount of time worked and scope of work performed.

  • Schedule Requirements The Contractor shall submit an electronic and a paper copy of the initial Work Progress Schedule reflecting accurate and reliable representations of the planned progress of the Work, the Work to date if any, and of the Contractor’s actual plans for its completion. The Contractor shall organize and provide adequate detail so the Work Progress Schedule is capable of measuring and forecasting the effect of delaying events on completed and uncompleted activities.

Time is Money Join Law Insider Premium to draft better contracts faster.