After the Possession Date Sample Clauses

After the Possession Date. Tenant shall defend, indemnify and hold harmless Landlord and the City from and against any and all liabilities, losses, damages, costs, expenses, claims, obligations, penalties, and causes of action (including without limitation, reasonable attorneys' fees and expenses) whether based upon negligence, strict liability, absolute liability, product liability, misrepresentation, contract, implied or express warranty or any other principle of 169 law or equity, that are imposed upon, incurred by or asserted against Landlord or the City or which Landlord or the City may suffer or be required to pay (except (A) to the extent caused by the intentional acts or omissions, or the sole negligence of Landlord or the City or their employees, agents, or contractors or (B) where Landlord or the City or their employees, agents or contractors are liable with a third party or parties other than Tenant or JCC Development or their respective employees, agents, or contractors) and which arise out of or relate in any manner to: (i) the ownership, possession, use, condition or occupancy of the Leased Premises or any part thereof or any Improvement thereon; (ii) the operation or management of the Development; (iii) any failure on the part of Tenant to perform or comply with any of the terms of this Lease, the Second Floor Non-Gaming Sublease, the GDA or any other agreement affecting the Casino or the Development to which Tenant is a party; (iv) any failure on the part of JCC Development to perform or comply with any of the terms of the Second Floor Non-Gaming Sublease; (v) the construction or remodeling of the Casino (including any Alterations) or the performance of any labor or services or the furnishing of any 170 material for or on the Development or any part thereof, any enforcement thereon after the Possession Date or the failure to pay for such labor, service or furnishing of material as and when required; (vi) any personal injury, death or property damage suffered or alleged to have been suffered by Tenant or JCC Development (including Tenant's or JCC Development's employees, agents or servants), the Casino Manager/Operator (including its employees, agents or servants), any Space Tenant or any third person on or about the Development after the Possession Date; (vii) any work or things whatsoever done in, on or about the Development or any portion thereof after the Possession Date; (viii) any act or omission of a design professional, contractor, subcontractor, equipment les...
Sample 1
AutoNDA by SimpleDocs
After the Possession Date. Landlord or its employees, agents or contractors has Tenant's permission to enter the Premises as needed for testing shell and core construction and Building systems as required to obtain any necessary permits for the Building. Landlord will not be liable for any delay in opening of Tenant's Premises as a result of such testing. Landlord will use reasonable efforts to conduct such testing so as not to unreasonably interfere with the construction of the Tenant Improvements.
Sample 1

Related to After the Possession Date

  • Possession and Control The Grantor has exclusive possession and control of its Equipment and Inventory.

  • TERM; POSSESSION The Term of this Lease shall commence on the Commencement Date and shall end on the Expiration Date, unless extended or sooner terminated in accordance with this Lease. If Landlord is delayed in delivering possession of all or any portion of the Premises to Tenant as of the Commencement Date, Tenant will take possession on the date Landlord delivers possession, which date will then become the Commencement Date (and the Expiration Date will be extended so that the length of the Term remains unaffected by such delay). Subject to this Section 4, Landlord shall not be liable for any loss or damage to Tenant resulting from any delay in delivering possession due to the holdover of any existing tenant or other circumstances outside of Landlord’s reasonable control. In the event that the Tenant Improvements are not Substantially Completed within one hundred (100) days following the date that Landlord receives a building permit to commence the Tenant Improvements in the Premises (the “Delivery Date”), subject to Tenant Delay or force majeure (in the event of either, the Delivery Date shall be extended by one (1) day for each one (1) day of Tenant Delay or force majeure), Landlord shall credit Tenant against Minimum Annual Rent due under this Lease an amount equal to the holdover portion of Tenant’s existing rental obligations under Tenant’s existing Lease actually incurred by Tenant following the Delivery Date, which Tenant represents to Landlord is equal to $17,031.13 per month. Notwithstanding anything in this Lease to the contrary, if the Commencement Date has not occurred on or before one hundred ninety (190) days following the date that Landlord receives a building permit for the Tenant Improvements, for any reason other than Tenant Delay or force majeure, then Tenant shall have the right to terminate this Lease by written notice to Landlord, as Tenant’s sole and exclusive remedy with respect to such delay, except as provided above, subject to Tenant giving Landlord thirty (30) days’ advance written notice of its intention to terminate this Lease if Substantial Completion shall not occur within such thirty (30) day period, in which event all amounts prepaid or deposited by Tenant hereunder shall be promptly returned to Tenant.

  • Happen After We Receive Your Letter When we receive your letter, we must do two things:

  • Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.

  • POSSESSION AND CLOSING Possession of the Property shall be delivered to Purchaser by Seller at the Closing, subject to the Permitted Exceptions and the rights of the Tenants under Tenant Leases. Purchaser shall make its own arrangements for the provision of public utilities to the Property and Seller shall terminate its contracts with such utility companies that provide services to the Property.

  • Peaceful Possession The Authority hereby warrants that: a) The Project Site has been acquired through the due process of law and belongs to and is vested with the Authority and that the Authority has full powers to hold, dispose of and deal with the same consistent, inter alia, with the provisions of this Agreement. b) In the event the Developer is obstructed by any Person claiming any right, title or interest in or over the Project Site or any part thereof, or in the event of any enforcement action including any attachment, distrait, appointment of receiver or liquidator being initiated by any Person claiming to have any interest in/charge or the Project Site or any part thereof, the Authority shall, if called upon by the Developer, defend such claims and proceedings and also keep the Developer indemnified against any consequential loss or damages which the Developer may suffer, on account of any such right, title, interest or charge.

  • Books and Records; Certain Funds Received After the Cut-Off Date From and after the sale of the Mortgage Loans to the Purchaser, record title to each Mortgage (other than with respect to any Outside Serviced Mortgage Loan) and each Note shall be transferred to the Trustee subject to and in accordance with this Agreement. Any funds due after the Cut-Off Date in connection with a Mortgage Loan received by the Seller shall be held in trust on behalf of the Trustee (for the benefit of the Certificateholders) as the owner of such Mortgage Loan and shall be transferred promptly to the Certificate Administrator. All scheduled payments of principal and interest due on or before the Cut-Off Date but collected after the Cut-Off Date, and all recoveries and payments of principal and interest collected on or before the Cut-Off Date (only in respect of principal and interest on the Mortgage Loans due on or before the Cut-Off Date and principal prepayments thereon), shall belong to, and shall be promptly remitted to, the Seller. The transfer of each Mortgage Loan shall be reflected on the Seller’s balance sheets and other financial statements as the sale of such Mortgage Loan by the Seller to the Purchaser. The Seller intends to treat the transfer of each Mortgage Loan to the Purchaser as a sale for tax purposes. Following the transfer of the Mortgage Loans by the Seller to the Purchaser, the Seller shall not take any actions inconsistent with the ownership of the Mortgage Loans by the Purchaser and its assignees. The transfer of each Mortgage Loan shall be reflected on the Purchaser’s balance sheets and other financial statements as the purchase of such Mortgage Loan by the Purchaser from the Seller. The Purchaser intends to treat the transfer of each Mortgage Loan from the Seller as a purchase for tax purposes. The Purchaser shall be responsible for maintaining, and shall maintain, a set of records for each Mortgage Loan which shall be clearly marked to reflect the transfer of ownership of each Mortgage Loan by the Seller to the Purchaser pursuant to this Agreement. It is expressly agreed and understood that, notwithstanding the assignment of the Loan Documents, it is expressly intended that the Seller will receive the benefit of any securitization indemnification provisions in the Loan Documents.

  • NO VACANT POSSESSION 14.1 The Purchaser shall upon full payment of the Balance Purchase Price together with all interest on late payment (if any) be entitled at his own costs and expenses to take possessions of the Property. 14.2 The Bank shall not be under any obligation whatsoever to deliver vacant possession of the Property or to forward to the Purchaser or any party any keys to the Property. 14.3 The Property is sold subject to all existing easements, leases, tenancies, occupiers, charges, caveats, previous Sale and Purchase, previous assignment, covenants, liabilities subsisting thereon or thereover and the Purchaser shall be deemed to have full knowledge of the state and condition of the Property.

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

  • Documents Records and Funds in Possession of Master Servicer to be Held for the Trustee Notwithstanding any other provisions of this Agreement, the Master Servicer shall transmit to the Trustee as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Master Servicer from time to time and shall account fully to the Trustee for any funds received by the Master Servicer or which otherwise are collected by the Master Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, Distribution Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!