Amendments to Building Budget Sample Clauses

Amendments to Building Budget. The Building Budget for the Project may be amended from time to time only in the manner set forth herein and subject to the limitations and satisfaction of the requirements in Section 4.1.2(m). Subject to the limitations and satisfaction of the requirements of Section 4.1.2(m), the Borrower shall have the right, from time to time, to amend the Building Budget without the consent of the Construction Consultant, the Collateral Agent, the Disbursement Agent or the Administrative Agent to change the amounts allocated for specific Line Items in accordance with the provisions hereof. Notwithstanding the foregoing, to the extent that, at any time, the Remaining Costs with regard to a particular Line Item of the Building Budget shall exceed the Remaining Budgeted Amount with respect to such Line Item, then the Borrower shall, within the next thirty (30) days or on or prior to the next succeeding submission of a Disbursement 41 Request (whichever occurs first), amend the Building Budget in accordance with the provisions hereof to eliminate such excess; provided, however, that, notwithstanding anything herein to the contrary, the Total Budgeted Amount with respect to the “Debt Financing Cost” Line Item may not be modified (except in conjunction with an extension of the Scheduled Casino Opening Date and/or Casino Opening Deadline pursuant to Section 6.15 hereof) without the prior written consent of the Administrative Agent in its sole discretion. With respect to any amendment of the Building Budget: (a) the Borrower may not add any new Line Item or modify the description of any Line Item, without the consent of the Administrative Agent in consultation with the Construction Consultant (such approval not to be unreasonably withheld, delayed or conditioned), (b) for each Line Item, the Remaining Budgeted Amount must equal or exceed the Remaining Costs contemplated by such Line Item, and (c) the requirements of Section 4.1.2(m) shall be satisfied with respect to any such amendment which results in a change to the Section 22 Lien Law Affidavit.
Sample 1
AutoNDA by SimpleDocs

Related to Amendments to Building Budget

  • Amendments to Lease The Lease is hereby amended as follows:

  • Construction Budget Administrative Agent shall have received each of the Construction Budget in form and substance reasonably satisfactory to Administrative Agent (in consultation with the Independent Engineer).

  • Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.

  • Operating Budget (a) No less than forty-five (45) days prior to the Substantial Completion of each train of the Project, and no less than forty-five (45) days prior to the beginning of each calendar year thereafter, the Borrower shall prepare a proposed operating plan and a budget setting forth in reasonable detail the projected requirements for Operation and Maintenance Expenses for the Borrower and the Project for the ensuing calendar year (or, in the case of the initial Operating Budget, the remaining portion thereof) and provide the Independent Engineer, the Common Security Trustee, and the Senior Facility Agent with a copy of such operating plan and budget (the “Operating Budget”). Each Operating Budget shall be prepared in accordance with a form approved by the Independent Engineer, shall set forth all material assumptions used in the preparation of such Operating Budget, and shall become effective upon approval of the Senior Facility Agent, acting reasonably and in consultation with the Independent Engineer; provided, that if the Senior Facility Agent shall not have approved or disapproved the Operating Budget within thirty (30) days after receipt thereof, such Operating Budget shall be deemed to have been approved; and provided, further that the Senior Facility Agent shall have neither the right nor the obligation to approve costs for Gas purchase contracts for the Project contained in the Operating Budget. If the Borrower does not have an effective annual Operating Budget before the beginning of any calendar year, until such proposed Operating Budget is approved, the Operating Budget most recently in effect shall continue to apply; provided, that (A) any items of the proposed Operating Budget that have been approved shall be given effect in substitution of the corresponding items in the Operating Budget most recently in effect, (B) costs for Gas purchase contracts for the Project shall be as provided by the Borrower and (C) all other items shall be increased by the lesser of (x) two and one-half percent (2.5%) and (y) the increase proposed by the Borrower for such item in such proposed Operating Budget.

  • Amendments to Exhibits Exhibits A and B may be amended by Company in its sole discretion from time to time, without prior notice, to delete or add Contracts. The provisions of this Agreement shall apply to such Exhibits, as they may from time to time be amended, unless the context otherwise requires. In addition, the Compensation Schedules that are part of Exhibits A and B may be amended, modified and/or replaced by Company in its sole discretion, from time to time, without prior notice.

  • Lease Amendments To Agent, within two (2) Business Days after receipt thereof, copies of all material amendments to real estate leases.

  • Site Plan The Landlord covenants that the Center is or shall be developed in accordance with the Site Plan and that it shall be used as a retail shopping center throughout the term of this Lease. The Landlord may not modify or replace the Site Plan without the prior written consent of the Tenant, which consent shall not be unreasonably withheld or delayed. No such modification or replacement shall (i) reduce the ratio of parking spaces to gross leasable area of buildings in the Center shown on the Site Plan, (ii) reduce or rearrange the parking spaces cross-hatched on the Site Plan, (ii) interfere with truck access to the loading doors of the Premises, (iv) interfere with customer access to the Premises or the parking areas closest to the Premises, (v) interfere with the visibility of the Premises from the roads providing direct access to the Center or (vi) result in the construction of any buildings in the area designated "No Build Area" on the Site Plan.

  • Operating Budgets The initial Operating Budget for 2010 is attached as Exhibit “D” which has been approved by both Managing Members. No later than the first (1st) day of the last quarter of each Company Year, the Skechers Managing Member shall submit a proposed Operating Budget (which shall include capital expenditures which are the landlord’s obligation under the Lease, and a business plan) for the next ensuing Company Year for approval by the HF Managing Member. Proposed amendments to any Approved Operating Budget may be submitted by the Skechers Managing Member to the HF Managing Member at any time. Such proposed Operating Budget (or any proposed amendment thereto) shall not be deemed to be effective until such time as it has been approved by the HF Managing Member. The HF Managing Member shall respond in writing to each such proposed Operating Budget (or any proposed amendment thereto) within thirty (30) days after receipt thereof. In such response, the HF Managing Member shall specify in detail its disapproval of any item or items therein or its disapproval of the whole, and any proposed modifications requested by the HF Managing Member or recommended changes therein. Within fifteen (15) days after receipt by the Skechers Member of the HF Managing Member’s disapproval of any proposed Operating Budget (or any proposed amendment thereto), the Skechers Managing Member may re-submit to the HF Managing Member a revised Operating Budget (or amendment) for its approval. The HF Managing Member shall not unreasonably withhold or delay approval of any Operating Budget or amendment (with the issue of reasonableness being determined by expedited arbitration under Article 15). In the event that any Company Year shall commence without an Operating Budget approved by both the Skechers Managing Member and the HF Managing Member pursuant to the terms of this Section, the Managing Members shall be entitled to make expenditures for items specified in the Operating Budget for the most recent Company Year which has been approved by both Managing Members, and for the actual amount of the utility cost, property taxes, insurance premiums or special assessments incurred by the Company or a Subsidiary in the current Company Year and any other non-discretionary items (including Debt service and stated increases in Company obligations or Subsidiary obligations under contracts for the year), and for any expenditures on the Project which, in the Managing Members’ reasonable good faith judgment, is necessary to prevent imminent damage to the Project and/or injury to Persons. The Operating Budget shall not include the budget for development of the Project (although the Members acknowledge that a development budget has been approved and a copy is attached as an exhibit to the Development Management Agreement).

  • Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2

Time is Money Join Law Insider Premium to draft better contracts faster.