Annual Operating Assessments After the Turnover Date. (i) Prior to the beginning of each fiscal year of the Association, the Association shall estimate, and divide equally among the Lots, the expenses of the Association consisting of the following:
Annual Operating Assessments After the Turnover Date Sample Clauses
Related to Annual Operating Assessments After the Turnover Date
Construction Period The term “Construction Period” shall mean the period from the date of this Lease to the date that Landlord completes construction of the Landlord’s Work (including any “Additional Base Building Items”, as defined in Section 3(f) of the Tenant Work Letter), and Common Areas, regardless of the occurrence of any Tenant Delay and without regard to the effect of any provision of this Lease pursuant to which the Premises are deemed to be Ready for Occupancy in advance of its actual occurrence. Notwithstanding any provision of this Lease to the contrary (including Exhibit B), during the Construction Period only, the following provisions shall be applicable:
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Annual Operating Budget As soon as available but, in any event, within sixty (60) days prior to (i) the Cooperation Period Commencement Date in respect of the initial Plant to be completed and, thereafter, (ii) the commencement of each Fiscal Year, an annual operating budget (the "Annual Budget") (including budgeted statements of income and sources and uses of cash and balance sheets) prepared by the Borrower and accompanied by a statement of the chief financial officer of the Borrower to the effect that, the best of his or her knowledge, the budget is a reasonable estimate for the period covered thereby. The first Annual Budget shall cover the period from the Cooperation Period Commencement Date through the end of the Fiscal Year in which the Cooperation Period Commencement Date occurs, and, if such period consists of less than six (6) months, for the immediately succeeding Fiscal Year. Each Annual Budget shall contain complete, fair and accurate estimates (by principal components) of Sales Proceeds, Operating and Maintenance Costs and Debt Service for each Month covered by such Annual Budget based on the Borrower's best projections at such time. Unless otherwise consented to by Eximbank, the Annual Budget from year to year shall be based on the same format as the Base Case Forecast, including any amounts allocated for contingencies, and be maintained on the same basis and provide sufficient detail to permit a meaningful comparison. For each Annual Budget that is expected to cover any period occurring after the Disbursement Date, Eximbank (in consultation with the Independent Engineer) shall review such Annual Budget, and Eximbank's response shall not be unreasonably delayed. If Eximbank does not approve an Annual Budget, Eximbank shall notify the Borrower of the items which are disapproved and the reason for such disapproval. Until such Annual Budget is so approved, the Annual Budget most recently in effect shall continue to apply, except that any items of the then proposed Annual Budget that have been approved shall also be given effect. From time to time, but not more frequently than once per Quarter, the Borrower may propose amendments to an Annual Budget, and Eximbank (in consultation with the Independent Engineer) may reject such proposal within thirty (30) Business Days from the date the Borrower submits such proposal if in Eximbank's reasonable judgment such amendment is not reasonably necessary or advisable for operation of the Project and, if no such rejection is made, such amendments shall become effective. Not later than three (3) Business Days after the effective date of each Annual budget and of any amendment thereto, the Borrower shall provide a copy of the same to the Collateral Trustee.
Annual Operating Plan Manager shall implement the Operating Plan prepared by Owner. The Operating Plan shall constitute a standard to which Manager shall reasonably attempt to adhere in the operation of the Project; provided, however, as the Operating Plan is a budget, Manager makes no representation or warranty that the actual operations of the Project shall conform to such plan. Except in an emergency, Manager shall not expend funds in any fiscal year in excess of the budgeted line item amounts in the Operating Budget without Owner's prior written approval. In the event any Fiscal Year shall commence without an approved Operating Plan, until the Operating Plan for such Fiscal Year is approved, Manager shall be entitled to make expenditures for items specified in the approved Operating Plan for the past Fiscal Year, at a rate not in excess of the rate permitted under that prior Operating Plan (other than for utilities, taxes, insurance premiums and mortgage payments), without the prior consent of Owner.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Total Operating Expenses All costs and expenses paid or incurred by the Company, as determined under GAAP, that are in any way related to the operation of the Company or its business, including the Advisory Fee, but excluding (i) the expenses of raising capital such as Organization and Offering Expenses, legal, audit, accounting, underwriting, brokerage, listing, registration, and other fees, printing and other such expenses and taxes incurred in connection with the issuance, distribution, transfer and registration of securities, (ii) interest payments, (iii) taxes, (iv) non-cash expenditures such as depreciation, amortization and bad debt reserves, (v) incentive fees paid in compliance with the NASAA REIT Guidelines; (vi) acquisition fees and Acquisition Expenses, (vii) real estate commissions on the sale of Real Property, and (viii) other fees and expenses connected with the acquisition, disposition, management and ownership of real estate interests, mortgages or other property (including the costs of foreclosure, insurance premiums, legal services, maintenance, repair, and improvement of property). The definition of “Total Operating Expenses” set forth above is intended to encompass only those expenses which are required to be treated as Total Operating Expenses under the NASAA REIT Guidelines. As a result, and notwithstanding the definition set forth above, any expense of the Company which is not part of Total Operating Expenses under the NASAA REIT Guidelines shall not be treated as part of Total Operating Expenses for purposes hereof. 2%/25% Guidelines. 2%/25% Guidelines shall have the meaning set forth in Section 14.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
Phase I A copy of the existing “Phase I” environmental assessment of the Project, if any, in Seller’s possession; and
