Warranty Obligations
(a) Project Co represents, warrants and covenants that:
(i) the Works shall conform to the requirements of this Project Agreement, Good Industry Practice, Applicable Law and all professional engineering principles generally accepted as standards of the industry in the Province of Ontario;
(ii) the Works shall be free of defects, including design defects, errors and omissions; and
(iii) materials and equipment shall be of good quality and in compliance with this Project Agreement.
(b) During the Warranty Period and subject to Section 11.15(c), Project Co shall promptly, at its sole cost and expense, correct and Make Good all Construction Defects arising in respect of the Works. For greater certainty, Project Co is required to correct and Make Good Construction Defects related to any Product during the applicable Warranty Period despite Project Co having obtained on Contracting Authority’s behalf industry- standard or other equipment warranties in accordance with Section 11.15(f). For all work to correct Construction Defects, the applicable Warranty Period shall be extended for a further two years from the date of the last work completed in respect of such corrective Works. For clarity, any extension of a Warranty Period for the purposes of a correction shall only apply to the relevant Construction Defect and not the Works as a whole.
(c) In addition to the obligation to correct and Make Good Construction Defects during the Warranty Period, Project Co shall at its expense correct and Make Good any Construction Defects that could not reasonably have been ascertained by a competent person in accordance with Good Industry Practice during a visual inspection of the Works (“Construction Latent Defect”), provided Contracting Authority gives Project Co written Notice of the Construction Latent Defect within the time frame applicable to such Construction Latent Defect pursuant to the Limitations Act, 2002 (Ontario).
(d) The warranties described in this Section 11.15 shall cover labour and material, including, the costs of removal and replacement of covering materials. The warranties shall not limit extended warranties on any Product or item of equipment called for elsewhere in the Output Specifications or otherwise provided by any manufacturer of such Product or equipment.
(e) If Project Co fails to correct and Make Good any Construction Defects or Construction Latent Defects in accordance with Sections 11.15(b) and 11.15(c) and in the time period specified in Section 11.16(a) or Section 11.16(b), as applicable, without prejudice to any other right or remedy Contracting Authority may have, Contracting Authority may correct such Construction Defects or Construction Latent Defects at Project Co’s sole cost and expense.
(f) Project Co shall obtain warranties from the manufacturers of each of the Products for the duration(s) and in accordance with the applicable requirements specified in the Output Specifications in the name of and to the benefit of both Project Co and Contracting Authority. Where, in respect of a Product warranty, the Output Specifications do not specify a specific duration and/or other requirements, Project Co shall obtain industry-standard warranties from the applicable manufacturers in the name of and to the benefit of Project Co and Contracting Authority which shall extend no less than two years from the Substantial Completion Date. Each Product warranty shall be issued by the applicable manufacturer and delivered to Project Co no later than 30 days prior to the Substantial Completion Date. Project Co shall ensure that each Product warranty, including any Product warranty extended under this Section 11.15(f), is fully assigned to Contracting Authority, at no cost or expense to Contracting Authority, at the end of the Warranty Period, as such Warranty Period may be extended in accordance with Section 11.15(b).
Breach of Warranty Any representation or warranty made at any time by any of the Loan Parties herein or by any of the Loan Parties in any other Loan Document, or in any certificate, other instrument or statement furnished pursuant to the provisions hereof or thereof, shall prove to have been false or misleading in any material respect as of the time it was made or furnished;
Breach of Warranties In the event of any breach, or reasonably anticipated breach, of any of the foregoing warranties, in addition to any other remedies available at law or in equity, Exodus will have the right immediately, in Exodus' sole discretion, to suspend any related Internet Data Center Services if deemed reasonably necessary by Exodus to prevent any harm to Exodus and its business.
Breach of other obligations any Security Party commits any breach of or omits to observe any of its obligations or undertakings expressed to be assumed by it under any of the Security Documents (other than those referred to in clauses 10.1.1 and 10.1.2 above) unless such breach or omission, in the opinion of the Agent (following consultation with the Banks) is capable of remedy, in which case the same shall constitute an Event of Default if it has not been remedied within fifteen (15) days of the occurrence thereof; or
Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract:
a) Terminate the Contract immediately, pursuant to Section K herein;
b) Afford the Contractor written notice of the breach and ten (10) calendar days or such shorter time that may be specified in this Contract within which to cure the breach;
c) Discontinue payment to the Contactor for and during the period in which the Contractor is in breach; and
d) Offset against any monies billed by the Contractor but yet unpaid by the County those monies disallowed pursuant to the above.
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.]
19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor:
12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims.
12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University.
12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
REMEDY FOR BREACH OF WARRANTY 3.1. Subject to the exclusions and limitations set out above, if the Product fails to comply with the Limited Warranty in clauses 1.2 or 1.3, BYD will repair or replace the non-conforming Product or parts thereof within the warranty term at no charge (or provide a partial refund) on the following conditions.
3.2. Whether to repair or replace the Product will be determined by BYD in its sole discretion.
3.3. The Product or any of its parts to be replaced will have the same performance and reliability as the original Product. If the Production of the relevant type of the Product or any of its parts has been discontinued, withdrawn from the market, or are otherwise unavailable, BYD may replace the Product or parts with a similar Product or part (which may include previously used parts that are equivalent to new in performance and reliability).
3.4. If BYD does not repair or replace the defective Product or parts, BYD will refund You an amount of money calculated as follows:
a) If the Product fails to comply with the Limited Performance Warranty in clause 1.3, BYD may calculate the refund using one of the two refund formulas below:
i) Refund = maximum claim amount* x (warranted Minimum Throughput Energy - output energy of the Product recorded in the control module of the Product)/ warranted Minimum Throughput Energy; or
ii) Refund = maximum claim amount* x (warranted remaining Useable Energy - remaining Useable Energy)/ warranted Usable Energy; and
b) If the Product cannot be operated, BYD will calculate the refund as follows: Refund = (maximum claim amount*/120) x (120 - number of months since Warranty Start Date). *The maximum claim amount is the market value of the Product (or an equivalent Product) determined by BYD if it were purchased new with no defects.
3.5. The remedies as set out above are the sole and exclusive obligations of BYD to You under this Limited Warranty, and BYD will have no other liability to You if the Product fails to comply with the Limited Warranty.
DEFECT LIABILITY It is agreed that in case any structural defect or any other defect in workmanship, quality or provision of services or any other obligations of the Promoter as per the agreement for sale relating to such development is brought to the notice of the Promoter within a period of 5 (five) years by the Allottee from the date of handing over possession, it shall be the duty of the Promoter to rectify such defects without further charge, within 30 (thirty) days, and in the event of Promoter's failure to rectify such defects within such time, the aggrieved Allottees shall be entitled to receive appropriate compensation in the manner as provided under the Act.
Indemnity Obligations (a) Parent shall indemnify and hold harmless SpinCo from and against, and will reimburse SpinCo for, (i) all liability for Taxes allocated to Parent pursuant to Article II, (ii) all Tax Related Costs and Expenses allocated to Parent pursuant to Section 6.7, (iii) all Taxes, Tax Related Costs and Expenses and Tax Related Losses (without duplication) to the extent arising out of, based upon, or relating or attributable to any breach of or inaccuracy in, or failure to perform, as applicable, any representation, covenant or obligation of any member of the Parent Group pursuant to this Agreement and (iv) the amount of any Refund received by any member of the Parent Group that is allocated to SpinCo pursuant to Section 2.5(a).
(b) Without regard to whether a Post-Distribution Ruling or an Unqualified Tax Opinion may have been provided or whether any action is permitted or consented to hereunder and notwithstanding anything to the contrary in this Agreement, SpinCo shall indemnify and hold harmless Parent from and against, and will reimburse Parent for, (i) all liability for Taxes allocated to SpinCo pursuant to Article II, (ii) all Tax Related Costs and Expenses allocated to SpinCo pursuant to Section 6.7, (iii) all liability for Taxes, Tax Related Costs and Expenses and Tax Related Losses (without duplication) arising out of, based upon, or relating or attributable to any breach of or inaccuracy in, or failure to perform, as applicable, any representation, covenant or obligation of any member of the SpinCo Group pursuant to this Agreement, (iv) the amount of any Refund received by any member of the SpinCo Group that is allocated to Parent pursuant to Section 2.5(a) and (v) any Distribution Taxes and Tax Related Losses attributable to a Prohibited Act, or otherwise attributable to a SpinCo Disqualifying Action (regardless of whether the conditions set forth in Section 4.2(c) are satisfied). To the extent that any Tax, Tax Related Costs and Expenses or Tax Related Loss is subject to indemnity pursuant to both Section 5.1(a) and Section 5.1(b), responsibility for such Tax, Tax Related Costs and Expenses or Tax Related Loss shall be shared by Parent and SpinCo according to relative fault as determined by Parent in its sole and absolute discretion. The amount of any liability for Taxes which are indemnifiable pursuant to this Section 5.1(b)(iii) and (v) shall be determined, in Parent’s sole and absolute discretion, without regard to any Tax Attributes of the Parent Group or the Parent Business.
Breach of Obligations The Parties acknowledge that a breach of any of the obligations contained herein would result in injuries. The Parties further acknowledge that the amount of the liquidated damages or the method of calculating the liquidated damages specified in this Agreement is a genuine and reasonable pre-estimate of the damages that may be suffered by the non-defaulting party in each case specified under this Agreement.
