Buyer’s delays Sample Clauses

Buyer’s delays. Region 10 ESC will not be responsible for any late fees due the prime contractor by the participating Member. The prime contractor will negotiate with the participating agency for the recovery of damages related to expenses incurred by the vendor for a delay for which the Member is responsible, which is unreasonable, and which was not within the contemplation of the parties to the contract between the two parties.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Buyer’s delays. In the event Bevcorp should be requested by Buyer to delay any aspect of Bevcorp’s obligation (including but not limited to manufacture, transport, delivery, installation, test, handover and/or acceptance) related to any Goods or Services purchased under the Agreement, or if any delay is caused by a default of the Buyer or its agents, representatives or affiliates including (without limitation) delay caused by Buyer’s breach of the Agreement, breach of the law (including any tort) or willful misconduct, the Buyer understands and accepts that Bevcorp’s overall production and project schedules may be adversely impacted, and Buyer will indemnify Bevcorp against any costs associated with any such delay such as, but not limited to: a. If the delay requires storage of Goods beyond the scheduled delivery date, a storage fee will be assessed for all delayed Goods pending final delivery and installation at Buyer’s site(s). b. Any additional costs incurred by Bevcorp in repairing and refurbishing the Goods to original condition following such storage period and prior to delivery to Buyer. c. Any extra handling costs incurred in extra or double handling of the Goods to accommodate such Buyer caused or requested delays. d. Any costs associated with labor and material cost increases. e. Payment in full for the Goods completed in accordance with the Agreement schedule but placed into storage to accommodate the Buyer. f. For any such delay that lasts for more than thirty (30) calendar days, Bevcorp will be entitled to revise its delivery dates, project completion schedule, and prices (including the Price).
Sample 1
Buyer’s delays. Buyer may delay delivery or acceptance occasioned by reason of force majeure or other causes beyond its control. Seller shall hold such goods at the direction of Buyer and shall deliver them when the cause affecting the delay has been removed. Buyer shall be responsible only for Seller's direct additional costs in holding the goods or delaying performance of this contract at Buyer's request. Causes beyond Buyer's control shall include, without limitation, government action or failure of the government to act where such action is required, terrorist action or imminent threat, cessation of commercial transportation systems, strike or other labor trouble, fires or unusually severe weather.
Sample 1

Related to Buyer’s delays

  • Buyer’s Deliveries At Closing of the Hotel, Buyer shall deliver the following:

  • Seller’s Deliveries At Closing, Seller shall execute and/or deliver to Purchaser the following items (referred to collectively herein as the “Seller’s Closing Items”): (a) a limited warranty deed conveying to Purchaser good and insurable fee simple title to the Property, free and clear of all liens, encumbrances, restrictions, and easements, except for the Permitted Title Exceptions (the “Deed”); (b) a quitclaim deed conveying the Property to Purchaser as described on the Survey, if required by Section 7.5 above; (c) the Project Agreements; (d) an owner’s affidavit in the form required by Title Company and such other documentation as may be required by Title Company to issue a standard 2006 ALTA Owner’s Policy with respect to the Property (hereinafter referred to as the “Title Policy”) free and clear of all liens, encumbrances, restrictions, and easements whatsoever except for the Permitted Title Exceptions and the “standard printed” survey exception; (e) such documents, certificates and affidavits reasonably requested by Purchaser Or Title Company to evidence Seller’s authority to enter into this Agreement, perform its obligations hereunder and consummate the sale and purchase transaction contemplated hereby; (f) a certificate and affidavit signed on behalf of Seller certifying that Seller is not a “foreign corporation”, “foreign partnership”, “foreign trust”, “foreign estate” or “foreign person” as defined in Section 1445 of the Internal Revenue Code of 1954, as amended; (g) a certificate in favor of Purchaser, its successors, assigns and lenders, certifying that all of the representations and warranties in Article 4 above are true and correct in all material respects as of the date of Closing; (h) a closing statement, itemizing and approving all receipts and disbursements made in connection with Closing; (i) a general assignment conveying to Purchaser, without representation or warranty and to the extent assignable, Seller’s rights with respect to any and all tangible and intangible rights, privileges and appurtenances pertaining to the Property, except for the Permitted Title Exceptions; and (j) any and all other documents or items reasonably necessary or appropriate to complete the Closing, including, but not limited to, any transfer tax forms, affidavits, or broker lien waivers required by applicable law, rule, regulation or otherwise required by the Title Company for the removal of any and all “standard exceptions” on Purchaser’s Title Policy. All of the Seller’s Closing Items shall be in a commercially reasonable form customarily utilized in the jurisdiction where the Property is located in transactions similar to the one contemplated hereby.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Buyer’s Deliveries at Closing At the Closing, Buyer shall deliver the following to the Seller:

  • Buyer’s Due Diligence Prior to Closing, Buyer shall have the right to perform due diligence at the property, including without limitation commissioning an appraisal of the Property, a survey, and a property condition assessment. Buyer may obtain a survey of the Property before the Closing to assure that there are no defects, encroachments, overlaps, boundary line or acreage disputes, or other such matters, that would be disclosed by a survey ("Survey Problems"). The cost of the survey, appraisal and property condition assessment shall be paid by the Buyer. Not later than , Buyer shall notify Seller of any Survey Problems, and any such Survey Problem which shall prevent the issuance of title clear of any encroachment shall be deemed a defect in the title to the Property. Seller shall be required to remedy any such defects within days prior to the Closing. If Seller is unwilling or unable to remedy any such defects, Buyer shall have the right to cancel this Agreement, in which event Buyer shall receive a full refund of the Deposit.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Buyer’s Default Seller’s remedies shall be limited to liquidated damages in the amount of the Xxxxxxx Money set forth in Section IV. It is agreed that such payments and things of value are liquidated damages and are Seller’s sole and only remedy for Buyer’s failure to perform the obligations of this Agreement. The Parties agree that Seller’s actual damages in the event of Buyer’s default would be difficult to measure, and the amount of the liquidated damages herein provided for is a reasonable estimate of such damages.

  • Purchaser’s Deliveries Subject to the fulfillment or waiver of the conditions set forth in Sections 6.2, Purchaser shall execute and/or deliver to Seller all of the following: (i) Payment of the Purchase Price as required under Section 3.3(a) hereof. (ii) An assumption agreement, duly executed by Purchaser, under which Purchaser assumes those Assumed Liabilities described in Section 2.2 hereof. (iii) An incumbency and specimen signature certificate with respect to the officers of Purchaser executing this Agreement and Purchaser's Ancillary Documents on behalf of Purchaser. (iv) A certified copy of resolutions of Purchaser's Board of Directors, authorizing the execution, delivery and performance of this Agreement and Purchaser's Ancillary Documents (v) A closing certificate executed by an executive officer of Purchaser (or any other officer of Purchaser specifically authorized to do so), on behalf of Purchaser, pursuant to which Purchaser represents and warrants to Seller that Purchaser's representations and warranties to Seller are true and correct as of the Closing Date as if then originally made (or, if any such representation or warranty is untrue in any respect, specifying the respect in which the same is untrue), that all covenants required by the terms hereof to be performed by Purchaser on or before the Closing Date, to the extent not waived by Purchaser in writing, have been so performed (or, if any such covenant has not been performed, indicating that such covenant has not been performed), and that all documents to be executed and delivered by Purchaser at the Closing have been executed by duly authorized officers of Purchaser. (vi) Such other documents from Purchaser as may reasonably be required in order to effectuate the transactions contemplated (i) hereby and (ii) by the Purchaser's Ancillary Documents.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Seller’s Deliveries at Closing At the Closing and unless otherwise waived in writing by the Buyer, the Sellers shall deliver to the Buyer the following, each of which shall be in a form reasonably acceptable to the Buyer (collectively, "Sellers' Closing Documents"): (a) The Bill of Sale, duly executed and notarized by XeQute; (b) All Third Party Consents and the release of all Liens on the Assets by the Lien Holders, together with the Instruments of Assignment and Assumption, duly executed by XeQute; (c) The Sellers' Officer's Certificates, duly executed on behalf of Vertex and XeQute; (d) Certified copies of any resolutions required to duly authorize and approve the Contemplated Transaction and the execution, performance and delivery of this Agreement, Sellers' Closing Documents and of all of the other documents to be executed and performed by the Sellers in connection with the Contemplated Transaction; (e) The duly executed opinion of the Sellers' counsel, dated as of the Closing Date and addressed to the Buyer ("Sellers' Opinion"), in form and substance as set forth in the form annexed to this Agreement as Exhibit C and subject to the standard exceptions set forth in Sellers' Opinion. In rendering Sellers' Opinion, the Sellers' counsel may rely upon certificates of governmental officials and may place reasonable reliance upon certificates of the Sellers; and (f) Such other instrument and documents, as the Buyer and the Buyer's counsel reasonably deem necessary or desirable in order to consummate the Contemplated Transaction, including without limitation evidence of the Sellers having taken all steps required to be taken by them prior to or at Closing under Article VI and Article VII hereof, including evidence of having obtained directors and officers liability insurance with the coverage described therein and paid the premium for same at the Closing.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!