Change Order Due to Change of Law Sample Clauses

Change Order Due to Change of Law. Subject to Section 9.5.1, if and to the extent that a Change of Law occurs that (a) directly delays Contractor in its ability to achieve any Key Milestone, then Owner will, via Change Order, extend the Project Schedule as described in Section 9.5.2, and/or (b) directly increases Contractor’s Direct Costs of performing the Work by more than $[ ], then Owner will, via Change Order, increase the Contract Price as described in Section 9.5.3. Change Order(s) issued under this Section 9.5.1(f) shall be Contractor’s sole and exclusive remedy and compensation for any additional costs and/or delays resulting from any Change of Law, and Contractor will not be entitled to any additional payment, damages or other compensation in connection therewith.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Change Order Due to Change of Law. Subject to Section 9.5.1, if and to the extent that a Change of Law occurs that (a) directly delays Contractor in its ability to achieve any Key Milestone, then Owner will, via Change Order, extend the Project Schedule as described in Section 9.5.2, and/or (b) directly increases Contractor’s Direct Costs of performing the Work by more than $[____], then Owner will, via Change Order, increase the Contract Price as described in Section 9.5.3. Change Order(s) issued under this Section 9.5.1(f) shall be Contractor’s sole and exclusive remedy and compensation for any additional costs and/or delays resulting from any Change of Law, and Contractor will not be entitled to any additional payment, damages or other compensation in connection therewith. Changes Involving Schedule Extensions. To the extent that Contractor demonstrates that an event for which it is entitled to a Change as described in Section 9.5.1 is the sole cause of critical path delay to Contractor’s ability to perform the Work despite Contractor’s use of commercially reasonable efforts to mitigate and avoid any such delay, Owner shall issue a Change Order to extend the dates in the Project Schedule as necessary to accommodate such delay. Contractor’s demonstration of the impact on the critical path of the Work must be made on a basis that analyzes the actual impacts of the given event on the then-current schedule for completion of the Work. In no event will Contractor be entitled to an extension of time under this Section 9.5.2 to the extent that the performance of the Work for which the extension is sought would have been suspended, delayed or interrupted by the concurrent fault, actions or omissions of Contractor.
Sample 1Sample 2

Related to Change Order Due to Change of Law

  • Change of Law In this Agreement, unless the context otherwise requires, references to a statutory provision include references to that statutory provision as from time to time amended, extended or re- enacted and any regulations made under it, provided that in the event that the amendment, extension or re-enactment of any statutory provision or introduction of any new statutory provision has a material impact on the obligations of either Party, the Parties will negotiate in good faith to agree such amendments to this Agreement as may be appropriate in the circumstances. If, within a reasonable period of time, the Supplier/Service Provider and Transnet cannot reach agreement on the nature of the changes required or on modification of Prices, delivery schedules, warranties, or other terms and conditions, either Party may seek to have the matter determined in accordance with clause 32 [Dispute Resolution] above.

  • Termination for Changes in Budget or Law The JBE’s payment obligations under this Agreement are subject to annual appropriation and the availability of funds. Expected or actual funding may be withdrawn, reduced, or limited prior to the expiration or other termination of this Agreement. Funding beyond the current appropriation year is conditioned upon appropriation of sufficient funds to support the activities described in this Agreement. The JBE may terminate this Agreement or limit Contractor’s Services (and reduce proportionately Contractor’s fees) upon Notice to Contractor without prejudice to any right or remedy of the JBE if: (i) expected or actual funding to compensate Contractor is withdrawn, reduced or limited; or (ii) the JBE determines that Contractor’s performance under this Agreement has become infeasible due to changes in applicable laws.

  • Change of Schedule (a) (applicable to full-time employees only) Where an employee's schedule is changed by the Hospital with less than twenty-four (24) hours notice, she shall receive time and one-half (1½) of her regular straight time hourly rate for all hours worked on her next shift. (b) (applicable to regular part-time employees only) Where a regular part-time employee's scheduled shift is cancelled by the Hospital with less than twelve (12) hours notice, she shall receive time and one-half (1½) of her regular straight time hourly rate for all hours worked on her next shift. (The following clause related to No Pyramiding will be incorporated into all collective agreements:)

  • CHANGE OF T-PIN The Account Holder may change his T-PIN from time to time in accordance with the Bank’s prescribed procedure then prevailing. The Bank shall be entitled, in its reasonable discretion but without liability and without giving any reason, to reject any selection made by the Account Holder as his substituted T-PIN; if the Bank so approves, such substituted T-PIN, shall take effect from the time of receipt by the Bank of such instructions from the Account Holder. The Account Holder shall take all steps not to select such numbers as a substitute T-PIN which may easily be ascertained or otherwise facilitate fraud or forgery.

  • Effect of Later Determination In the event the parties agree or a court of competent jurisdiction determines (or the parties agree to settle with a consent determination) that a default is wrongful or not the fault of the Contractor, the termination shall be considered to be a Termination for Convenience and the sole remedy available to the Contractor shall be the contractual treatment of the termination as termination for convenience pursuant to Section 23.0 above and without any other damages or relief.

  • Waiver or Change of Policy Provisions A waiver or change of a provision of this policy must be in writing by us to be valid. Our request for an appraisal or examination will not waive any of our rights.

  • Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract.‌ If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.

  • Changes in Capital Adequacy Regulations If a Lender determines the amount of capital required or expected to be maintained by such Lender, any Lending Installation of such Lender or any corporation controlling such Lender is increased as a result of a Change, then, within 15 days of demand by such Lender, the Borrower shall pay such Lender the amount necessary to compensate for any shortfall in the rate of return on the portion of such increased capital which such Lender determines is attributable to this Agreement, its Loans or its Commitment to make Loans hereunder (after taking into account such Lender's policies as to capital adequacy). "Change" means (i) any change after the date of this Agreement in the Risk-Based Capital Guidelines or (ii) any adoption of or change in any other law, governmental or quasi-governmental rule, regulation, policy, guideline, interpretation, or directive (whether or not having the force of law) after the date of this Agreement which affects the amount of capital required or expected to be maintained by any Lender or any Lending Installation or any corporation controlling any Lender. "Risk-Based Capital Guidelines" means (i) the risk-based capital guidelines in effect in the United States on the date of this Agreement, including transition rules, and (ii) the corresponding capital regulations promulgated by regulatory authorities outside the United States implementing the July 1988 report of the Basle Committee on Banking Regulation and Supervisory Practices Entitled "International Convergence of Capital Measurements and Capital Standards," including transition rules, and any amendments to such regulations adopted prior to the date of this Agreement.

  • Effect of a Change in Control In the event of a Change in Control, Sections 6 through 13 of this Agreement shall become applicable to Executive. These Sections shall continue to remain applicable until the third anniversary of the date upon which the Change in Control occurs. On such third anniversary date, and provided that the employment of Executive has not been terminated on account of a Qualifying Termination (as defined in Section 5 below), this Agreement shall terminate and be of no further force or effect.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!