COMPLETION OF THE SECTION Sample Clauses

COMPLETION OF THE SECTION. 3.1 The SELLER hereby undertakes to procure that the SECTION is erected substantially in accordance with the PLAN and is sufficiently complete for beneficial occupation, by the DATE OF POSSESSION, provided the PURCHASER has paid or duly secured the Total Consideration referred to in 1.3 of the AGREEMENT (as contemplated in paragraph 3 of the CONTRACT). 3.2 The PURCHASER shall not give any instructions of any nature to the ARCHITECT, contractor, or sub-contractor(s). Should the SELLER agree to any deviation from the PLAN, such deviation shall be reduced to writing and any amounts payable in terms of such deviation shall be payable by the PURCHASER to the SELLER on demand, and prior to any deviations being carried out by the SELLER. 3.3 The PURCHASER shall, within 30 (THIRTY) days of the DATE OF POSSESSION, deliver to the SELLER a list, signed by himself, enumerating any defects in the SECTION where same are due to defective materials or workmanship, and the SELLER shall procure that such defects are made good as expeditiously as possible in the circumstances. Once such defects have been made good to the satisfaction of the ARCHITECT (acting as an expert and not an arbitrator and whose decision shall be final and binding on the parties), the PURCHASER shall have no further claim against the SELLER, save as otherwise provided for herein. Should the PURCHASER fail to deliver the aforesaid list to the SELLER within the aforesaid 30 (THIRTY) day period, then in that event, the PURCHASER shall be deemed to have inspected the SECTION and not found any defects therein. 3.4 Save as provided in this CONTRACT, the PURCHASER purchases the PROPERTY voetstoots and shall have no claim against the SELLER in respect of any defects whether latent or patent in the PROPERTY or the common property of the SCHEME. 3.5 If there is any dispute between the PURCHASER and the SELLER as to whether the SECTION has been constructed substantially in accordance with the PLAN and/or has been erected in substantially the position as reflected in the SITE PLAN and/or is sufficiently complete for beneficial occupation and/or whether there are any defects in the SECTION due to defective materials or workmanship, then such dispute shall be referred to the ARCHITECT (acting as an expert and not as an arbitrator) whose decision shall be final and binding upon the parties. 3.6 The PURCHASER acknowledges that after the completion of the SECTION the SELLER and/or its agents, contractors and workmen m...
Sample 1Sample 2See All (9)
AutoNDA by SimpleDocs
COMPLETION OF THE SECTION. 5.1 The Seller hereby undertakes to procure that the Section is erected substantially in accordance with the Plan and in a proper and workmanlike manner in compliance with National Building Regulations and the requirements of the local authority. 5.2 The Seller may, in its sole discretion, elect not to install any item on the Schedule of Finishes, provided that the Seller installs a similar item of a similar quality in its place. If there is any dispute as to whether the Seller has installed an item of similar quality, such disputes shall be referred to the Architect, acting as an expert and not an arbitrator, whose decision shall be final and binding on the parties 5.3 The Purchaser acknowledges that he shall not be entitled to give any instructions of any nature to the building contractors, subcontractors, the Architect or anyone else engaged upon the building work. If at the time when occupation of the Section is given to the Purchaser the building work in respect of the rest of the scheme has not been completed, then the provisions of this clause shall apply to the Buildings still to be erected, or still in the course of erection, and to those areas of the Land where building work is being performed. 5.4 The Purchaser acknowledges that the Seller has established several basic configurations for sections to be built on the Land. The Seller shall have the right at its sole discretion to determine the number of sections to be built in terms of each configuration notwithstanding the plan and estimated participation quota schedule lodged in the Deeds Registry by virtue of Section 25 of Act 95/1986. The Purchaser acknowledges that the Seller's right will not be prejudicial to the Purchaser and undertakes not to make application to Court as provided for in Section 25(13) of Act 95/1986. 5.5 In the event of the Purchaser utilising his own sub-contractors for any part of the construction of the Section, or should the Purchaser purchase any materials from suppliers other than those nominated by the Seller, the Purchaser shall not be entitled to delay payment of the purchase price as a result of any delays in the completion of the construction of the Section. 5.6 In no way detracting from the Seller’s rights in terms of the Contract or at Law, it is specifically recorded that the Purchaser shall not be entitled to delay or refuse to comply with his obligations in terms of the Contract, if he disputes that the Property has been erected and completed as aforesaid i...
Sample 1Sample 2See All (6)
COMPLETION OF THE SECTION. 8.1 If the Section is not fully complete as at date of sale then the SELLER hereby undertakes to procure that the SECTION is erected substantially in accordance with the PLAN and is sufficiently complete for occupation, by the OCCUPATION DATE, provided the PURCHASER has paid or duly secured the Total Consideration referred to in
Sample 1

Related to COMPLETION OF THE SECTION

  • Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.

  • Description of the service 10.1.1 Automatic transfer service implies a transfer by the bank of the funds from the client’s account without further consent of the client, on the basis of fixed amount determined by the client in its application form or of information provided by the client’s creditor to the bank on the client’s debt. 10.1.2 The parties agree that the payment order created (generated) by the bank for the purposes of automatic transfer services shall have the legal force equal to the document having been printed on the paper and executed by the person(s) authorized to manage of the account. 10.1.3 The bank shall carry out the automatic transfer services in accordance with requirements and conditions stipulated in this agreement, the application on registration for automatic transfer service and the sources disseminated by the bank. 10.1.4 For the purposes of obtaining automatic transfer services the client shall apply to the bank with the application as per paragraph 1.2 of this agreement.

  • Application of the Agreement (1) This Agreement shall apply to investments made in the territory of either Contracting Party in accordance with its legislation by investors of the other Contracting Party prior as well as after the entry into force of this Agreement. (2) This Agreement shall not apply to claims which have been settled or procedures which have been initiated prior to its entry into force.

  • Implementation of the Agreement Regulations of this Agreement relating to investments who investors of one Contracting Party realized before or after the entry into force of this Agreement, with what shall apply from the moment of its entry into force, provided that such investments conducted in accordance with the laws of that Party Contracting.

  • Completion of Negotiations This Agreement represents complete collective bargaining and full agreement by the District and the Federation with respect to wages, hours of employment, and all other terms and conditions of employment which shall prevail during the term or terms hereof. This Agreement expresses the entire understanding between the parties and supersedes all previous agreements between them, written or oral. Any matter or subject not herein covered has been satisfactorily adjusted, compromised, or waived by the parties for the life of this Agreement.

  • Operation of the Agreement The Parties recognize that it is impractical in this Agreement to provide for every contingency which may arise during the life of the Agreement, and the Parties hereby agree that it is their intention that this Agreement shall operate fairly as between them, and without detriment to the interest of either of them, and that, if during the term of this Agreement either Party believes that this Agreement is operating unfairly, the Parties will use their best efforts to agree on such action as may be necessary to remove the cause or causes of such unfairness, but failure to agree on any action pursuant to this Clause 8.2 shall not give rise to a dispute subject to arbitration in accordance with Clause 9 hereof.

  • Description of the Services 1.1 The scope of the service to be rendered is described more fully in the Annexures and Schedules referred to below: ❑ Annexure A – Scope / Specification ❑ Annexure C – Pricing Schedule The Deliverables, due for completion by and governed by this Schedule 1. In the event that the Service Provider fails to meet the delivery dates as agreed, the following penalties will be imposed:

  • Description of the Transfer The details of the transfer and of the personal data are specified in Annex B. The parties agree that Annex B may contain confidential business information which they will not disclose to third parties, except as required by law or in response to a competent regulatory or government agency, or as required under clause I(e). The parties may execute additional annexes to cover additional transfers, which will be submitted to the authority where required. Annex B may, in the alternative, be drafted to cover multiple transfers.

  • Survival of Provisions After Termination (1) If this Settlement Agreement is not approved, is terminated or otherwise fails to take effect for any reason, the provisions of Sections 3.1(8), 3.2(3), 4.1(6)(b), 5.1(3), 5.2, 5.3, 5.4, 8.1, 8.2, 10.1(2) and 11.2(4), and the definitions and Schedules applicable thereto shall survive the termination and continue in full force and effect. The definitions and Schedules shall survive only for the limited purpose of the interpretation of Sections 3.1(8), 3.2(3), 4.1(6)(b), 5.1(3), 5.2, 5.3, 5.4, 8.1, 8.2, 10.1(2) and 11.2(4), within the meaning of this Settlement Agreement, but for no other purposes. All other provisions of this Settlement Agreement and all other obligations pursuant to this Settlement Agreement shall cease immediately.

  • Description of the Project THIS SHOULD BE NO MORE THAN A TWO PARAGRAPH DESCRIPTION THAT PROVIDES A BACKGROUND OF THE PROBLEM, AS WELL AS HOW THE CONTRACTOR INTENDS TO SOLVE THE PROBLEM. KEEP IN MIND THAT THE CONTRACT SHOULD “STAND ON ITS OWN,” I.E. ANYONE SHOULD BE ABLE TO PICK IT UP AND FIGURE OUT WHAT IS GOING ON.)

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!