Compliance with Contract Time Requirements Sample Clauses

Compliance with Contract Time Requirements. 8.3.1. The Contractor shall prosecute the Work with the diligence necessary to ensure its completion within the Contract Times. The Contractor shall provide sufficient management, supervision, labor, materials and equipment, and the Contractor shall undertake appropriate action promptly to recover schedule when necessary to comply with the Contract Times. 8.3.2. Unless disallowed by any Law or modified in another Section of the Specifications, a daily schedule from 06:00 AM to 06:00 PM, during Business Days, shall be normal working hours. Except in an Emergency, or as may be required by the Contractor's safety and protection obligations, or as the Owner and Contractor may otherwise agree, all Work at the site shall take place during normal working hours. The Contractor shall provide written notice to the Owner at least twenty-four (24) hours and up to seventy-two
Sample 1
AutoNDA by SimpleDocs
Compliance with Contract Time Requirements. 7.2.1 The Contractor shall prosecute the Work with the diligence necessary to ensure its completion within the Contract Time. The Contractor shall provide sufficient labor, materials and equipment, and shall promptly undertake appropriate action to recover schedule, as may be necessary to comply with the Contract Time requirements. Except as otherwise may be permitted by the Contract Documents, all Work at the site shall be performed during normal working hours, unless the Contractor has obtained the City's prior written consent. 7.2.2 Normal working hours shall be as per the City’s Noise Ordinance, secs. 20-13--20-19 of the Revised Ordinances of the City of Xxxxxx, or based on a schedule beginning no earlier than 7:00 A.M. and ending no later than 7:00 P.M. on weekdays (excluding legal holidays), but not exceeding forty-eight (48) hours per week. If Work during other than normal working hours is scheduled by the Contractor, he shall reimburse the City for all of the City's associated extra costs; such costs to include, but not necessarily limited to, the Architect's related charges to the City and other costs assessed against or incurred by the City as designated in the Contract Documents, and if not designated, which the Contractor could reasonably have been expected to be aware of. 7.2.3 Given the Contract Time requirements of the Contract Documents, Early Dates in the Progress Schedule shall be based on proceeding with all or part of the Work exactly on the date when the Contract Time for the Work, or designated part of the Work, commences to run. Late Dates shall be based on completing the Work, or specified part of the Work, exactly on the corresponding Contract Time. 7.2.4 No Work shall be performed in other than daylight conditions unless adequate lighting has been provided by the Contractor after securing all required written approvals. 7.2.5 The Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with the City. No Work shall be delayed or postponed pending resolution of any disputes or disagreements. The Contractor shall exercise reasonable precautions, efforts and measures to avoid or mitigate situations that would cause delays.
Sample 1

Related to Compliance with Contract Time Requirements

  • Compliance with Conditions All of the terms, covenants, conditions and obligations of this Agreement and each other Transaction Document required to be complied with and performed by Seller on or prior to the Closing Date shall have been duly complied with and performed in all material respects.

  • Compliance with Contracts The District will comply with, keep, observe and perform all agreements, conditions, covenants and terms, expressed or implied, required to be performed by it contained in all contracts for the use of the Enterprise and all other contracts affecting or involving the Enterprise to the extent that the District is a party thereto.

  • Compliance with Requirements Any investment program furnished, and any activities performed, by the Manager or by a Sub-Adviser under this Section shall at all times conform to, and be in accordance with, any requirements imposed by: (1) the Act and any rules or regulations in force thereunder; (2) any other applicable laws, rules and regulations; (3) the Declaration of Trust and By-Laws of the Fund as amended from time to time; (4) any policies and determinations of the Board of Trustees of the Fund; and (5) the fundamental policies of the Fund, as reflected in its Registration Statement under the Act or as amended by the shareholders of the Fund.

  • Compliance with ERISA Requirements For purposes of ensuring compliance with the requirements of the "underwriter's exemption" (U.S. Department of Labor Prohibited Transaction Exemption 2000-58, 65 Fed. Reg. 67765 (Nov. 13, 2000)), issued under ERISA, and for the avoidance of any doubt as to the applicability of other provisions of this Agreement, to the fullest extent permitted by applicable law and except as contemplated by this Agreement, (1) the Trust shall not be a party to any merger, consolidation or reorganization, or liquidate or sell its assets and (2) so long as any Certificates are outstanding, none of the Company, the Trustee or the Delaware Trustee shall institute against the Trust, or join in any institution against the Trust of, any bankruptcy or insolvency proceedings under any federal or state bankruptcy, insolvency or similar law.

  • Time Requirements The Independent Contractor will not be required to follow or establish a regular or daily work schedule, but shall devote during the term of this Agreement the time, energy and skill as necessary to perform the services of this engagement and shall, periodically or at any time upon the request of the Company, submit information as to the amount of time worked and scope of work performed.

  • Compliance with Applicable Requirements In carrying out its obligations under this Agreement, the Sub-Adviser shall at all times comply with: (a) all applicable provisions of the 1940 Act, and any rules and regulations adopted thereunder; (b) the provisions of the registration statement of the Trust, as it may be amended or supplemented from time to time, under the Securities Act and the 1940 Act; (c) the provisions of the Declaration of Trust of the Trust, as it may be amended or supplemented from time to time; (d) the provisions of any By-laws of the Trust, if adopted and as it may be amended from time to time, or resolutions of the Board as may be adopted from time to time; (e) the provisions of the Internal Revenue Code of 1986, as amended, applicable to the Trust or the Funds; (f) any other applicable provisions of state or federal law; and In addition, any code of ethics adopted by the Sub-Adviser must comply with Rule 17j-1 under the 1940 Act, as it may be amended from time to time, and any broadly accepted industry practices, if requested by the Trust or the Adviser.

  • Compliance with OFAC None of the Company and its Subsidiaries or, to the Company’s knowledge, any director, officer, agent, employee or affiliate of the Company and its Subsidiaries or any other person acting on behalf of the Company and its Subsidiaries, is currently subject to any U.S. sanctions administered by the Office of Foreign Assets Control of the U.S. Department of the Treasury (“OFAC”), and the Company will not, directly or indirectly, use the proceeds of the Offering hereunder, or lend, contribute or otherwise make available such proceeds to any subsidiary, joint venture partner or other person or entity, for the purpose of financing the activities of any person currently subject to any U.S. sanctions administered by OFAC.

  • Compliance with Orders The Company is not in violation of any material judgment, decree, or order of any court, arbitrator or other governmental authority.

  • Compliance with Rules To comply with, and to require the Contractors to comply with, all rules, regulations, ordinances and laws bearing on the conduct of the work on the Improvements, including the requirements of any insurer issuing coverage on the Project and the requirements of any applicable supervising boards of fire underwriters.

  • Compliance with Code comply and will procure that any Operator will comply with and ensure that the Ship and any Operator will comply with the requirements of the Code, including (but not limited to) the maintenance and renewal of valid certificates pursuant thereto throughout the Security Period;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!