Service Delivery Requirements All services provided by the Vendor under the terms and conditions of this Contract shall be delivered in accordance with:
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Conformance with Sample(s Submission of a sample (whether or not such sample is tested by, or for, the Commissioner) and approval thereof shall not relieve the Contractor from full compliance with all terms and conditions, performance related and otherwise, specified in the Bid Specifications. If in the judgment of the Commissioner the sample or product submitted is not in accordance with the specifications or testing requirements prescribed in the Bid Specifications, the Commissioner may reject the Bid. If an award has been made, the Commissioner may cancel the Contract at the expense of the Contractor.
Compliance with Audit and Reporting Requirements; Maintenance of Records A. The Grantee shall submit to an audit of funds paid through this Grant Agreement and shall make all books, accounting records and other documents available at all reasonable times during the term of this Grant Agreement and for a period of three (3) years after final payment for inspection by the State or its authorized designee. Copies shall be furnished to the State at no cost
Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .
Compliance with Accessibility Standards All parties to this Agreement shall ensure that the plans for and the construction of all projects subject to this Agreement are in compliance with standards issued or approved by the Texas Department of Licensing and Regulation (TDLR) as meeting or consistent with minimum accessibility requirements of the Americans with Disabilities Act (P.L. 101-336) (ADA).
SERVICE DELIVERABLES You will receive service on the Covered Product as described below: Carry-In: Unless otherwise provided in this Agreement, the Covered Product must be shipped or delivered and retrieved by You at Our authorized service center during normal business hours. In-Home/On-Site: Service will be performed in Your home or on-site as indicated on the Declarations Page of this Agreement, or on Your sales receipt or invoice provided You have fulfilled the following requirements: (1) provide Our authorized technician with accessibility to the Covered Product; (2) provide a non-threatening and safe environment for Our authorized technician; and (3) an adult over the age of 18 must be present for the period of time Our authorized technician is scheduled to provide service and while Our authorized technician is on Your property servicing the Covered Product. In-Home Service will be provided by Our authorized service provider during regular business hours, local time, Monday through Friday, except holidays. Our authorized service center may opt to remove the Covered Product to perform service in-shop. The Covered Product will be returned upon completion. Additional time and mileage charges for in-home repairs outside of twenty-five (25) contiguous land miles or the normal service radius of Our authorized service center are not covered by this Agreement, and are Your responsibility.
Compliance with Standards Although the standards for workmanship, material, and equipment have been selected in these specifications as a basis of reference, standards and specifications of the other bank member countries and recommendations of standards international organizations will be acceptable provided they are substantially equivalent to the designated standards and provided furthermore that the contractor submits for approval detailed specifications which he proposes to use. Reference to brand names or catalog numbers if any in these specifications have been made only for that equipment for which it has been determined that a degree of standardization is necessary to maintain certain essential features. And in certain cases such references have also been made for purposes of convenience to specify the requirements, in either case offers of alternative goods, which have similar characteristics and provide performance and quality at lease equal to those specified are acceptable. If the contractor offers materials, equipment, design calculations or tests, which conform to standards other than those specified, full details of the differences between the proposed standards and that specified in so far as they affect the design or purpose of the equipment, are to be supplied by the contractor if called upon to do so by the engineer, where required by the engineer for approval purposes, the contractor shall supply, without charge, duplicate copies of the proposed standards with English translations of the relevant portions. The contractor shall have available in his place of business (or in his supplier’s works) the relevant copies of standards or codes used for the use of the Engineer.
Service Delivery Grantee shall:
Access to Network Interface Device (NID 2.4.3.1. Due to the wide variety of NIDs utilized by BellSouth (based on subscriber size and environmental considerations), Mpower may access the on-premises wiring by any of the following means: BellSouth shall allow Mpower to connect its loops directly to BellSouth’s multi-line residential NID enclosures that have additional space and are not used by BellSouth or any other telecommunications carriers to provide service to the premise. Mpower agrees to install compatible protectors and test jacks and to maintain the protection system and equipment and to indemnify BellSouth pursuant to Section 8 of the General Terms and Conditions of this Agreement.
