Annual Operating Plan Purchaser may be required to submit a written annual operating plan, as specified by, and at the request of the Forest Officer.
Annual Operating Budget Manager shall, on or before December 20 in each calendar year during the Term, deliver to Owner for Owner’s approval, an annual operating budget for the Community for the next calendar year (the “Annual Operating Budget”) which shall include separate line items for Capital Replacements and set forth an estimate, on a monthly basis, of Gross Revenues and Community Expenses, together with an explanation of anticipated changes to Tenants charges, payroll rates and positions, non-wage cost increases, the proposed methodology and formula employed by Manager in allocating shared Community Expenses, and all other factors differing from the then current calendar year. The Annual Operating Budget shall be accompanied by a narrative description of operating objectives and assumptions. If Owner does not approve an Annual Operating Budget or any portion thereof, it shall do so, to the extent practicable, on a line item basis. Manager and Owner shall cooperate to resolve disputed items, provided if the Annual Operating Budget is not approved by Owner within thirty (30) days of Owner’s receipt, Manager shall operate under the expired Annual Operating Budget until a new Annual Operating Budget is approved, provided that line items for Impositions, insurance premiums and utilities shall be the amounts actually incurred for such items. If agreement on the Annual Operating Budget cannot be reached within forty-five (45) days of Owner’s receipt (which time may be extended upon mutual agreement of the parties), the matter shall be resolved by arbitration. The Annual Operating Budget as approved by Owner, or as resolved by arbitration, will be the “Approved Budget” for the applicable calendar year. Manager will obtain Owner’s prior approval for any expenditure which will, or is reasonably expected to, result in a variance of 5% or more of any Approved Budget.
Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."
Operating Plan To Agent and Lenders, as soon as available, but not later than thirty (30) days after the end of each Fiscal Year, an annual combined operating plan (the "Operating Plan") for Parent and its Subsidiaries, approved by the Board of Directors of Parent, for the following Fiscal Year, which (i) includes a statement of all of the material assumptions on which such plan is based, (ii) includes projected monthly income statement, balance sheets and source and use of funds for the following year and (iii) Borrowing Availability projections, all prepared on the same basis and in similar detail as that on which operating results are reported (and in the case of cash flow projections, representing management's good faith estimates of future financial performance based on historical performance), and including plans for personnel, Capital Expenditures and facilities.
Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System.
4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System.
4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA.
4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code.
4.1.5 The Power Producer shall commission the Project within SCOD.
4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer.
4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.
Annual Operating Budget and Financial Projections Within sixty (60) days after the end of each fiscal year of Borrower Representative (and promptly and within five (5) days of any material modification thereto), an annual operating budgets, on a consolidating basis (including income statements, balance sheets and cash flow statements, by month) for the upcoming fiscal year of Borrower Representative, as approved by Borrower Representative’s Board, together with any related business forecasts used in the preparation of such annual financial projections.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Construction Change Directives 1.1.1, 3.4.2, 3.11, 3.12.8, 4.2.8, 7.1.1, 7.1.2, 7.1.3, 7.3,
9.3.1.1 Construction Schedules, Contractor’s 3.10, 3.11, 3.12.1, 3.12.2, 6.1.3, 15.1.6.2
