Concessioning Authority’s Obligations Sample Clauses

Concessioning Authority’s Obligations. Except in the event of expiry of the Concession by efflux of time, the Concessioning Authority shallpay Termination Payment payable to the Concessionaire in accordance with Article 17.1 of this Agreement, to the Senior Lenders, or deposit the same in the Escrow Account or on the written instructions of the Senior Lenders to any designated bank account in India, or to the Concessionaire,as the case may be. The Concessionaire confirms that upon such payment being made, the Concessioning Authority shall stand duly discharged of its obligations regarding payment of compensation under this Agreement and the charge created by the Concessionaire in favour of theSenior Lenders on any of the assets shall stand satisfied and all such assets shall on and from theTransfer Date be free from such charge. The Concessionaire further confirms that payment of compensation by Concessioning Authority in accordance with this Article 18.3 shall be a valid discharge to the Concessioning Authority in respectof Concessioning Authority’s obligation regarding payment of compensation to the Concessionaireunder this Agreement.
AutoNDA by SimpleDocs
Concessioning Authority’s Obligations. Except in the event of expiry of the Concession by efflux of time, the Concessioning Authority shall pay compensation payable to the Concessionaire in accordance with Article 17.1 of this Agreement, to the Senior Lenders, or deposit the same in the Escrow Account or on the written instructions of the Senior Lenders to any designated bank account in India, or to the Concessionaire, as the case may be. The Concessionaire confirms that upon such payment being made, the Concessioning Authority shall stand duly discharged of its obligations regarding payment of compensation under this Agreement and the charge created by the Concessionaire in favour of the Senior Lenders on any of the assets shall stand satisfied and all such assets shall on and from the Transfer Date be free from such charge. The Concessionaire further confirms that payment of compensation by Concessioning Authority in accordance with this Article 18.3 shall be a valid discharge to the Concessioning Authority in respect of Concessioning Authority’s obligation regarding payment of compensation to the Concessionaire under this Agreement. Until transfer in accordance with this Article 18, the Port’s Assets and the Project Facilities and Services shall remain at the sole risk of the Concessionaire except for any loss or damage caused to or suffered by the Concessionaire due to any act or omission or negligence on the part of the Concessioning Authority under this Agreement.
Concessioning Authority’s Obligations. Except in the event of expiry of the Concession by efflux of time, the Concessioning Authority shall pay compensation payable to the Concessionaire in accordance with Article 16 to the Concessionaire. The Concessionaire confirms that upon such payment being made, the Concessioning Authority shall stand duly discharged of its obligations regarding payment of compensation under this Agreement. The Concessionaire further confirms that payment of compensation by the Concessioning Authority in accordance with this Article 16 shall be a valid discharge to the Concessioning Authority in respect of the Concessioning Authority’s obligation regarding payment of compensation to the Concessionaire under this Agreement.
Concessioning Authority’s Obligations. Subject to and in accordance with the provisions of this Agreement, the Concessioning Authority shall have the following obligations:
Concessioning Authority’s Obligations. Except in the event of expiry of the Concession by efflux of time, the Concessioning Authority shall pay compensation payable to the Concessionaire in accordance with Article 16 to the Concessionaire. The Concessionaire confirms that upon such payment being made, the Concessioning Authority shall stand duly discharged of its obligations regarding payment of compensation under this Agreement. The Concessionaire further confirms that payment of compensation by the Concessioning Authority in accordance with this Article 16 shall be a valid discharge to the Concessioning Authority in respect of the Concessioning Authority’s obligation regarding payment of compensation to the Concessionaire under this Agreement. Risk Until transfer in accordance with this Article 18, the Port’s Assets and the Project Facilities and Services shall remain at the sole risk of the Concessionaire except for any loss or damage caused to or suffered by the Concessionaire due to any act or omission or negligence on the part of the Concessioning Authority under this Agreement.
Concessioning Authority’s Obligations. In addition to and not in derogation or substitution of any of its other obligations under this Agreement, the Concessioning Authority shall have the following obligations: 6.1. Specific Obligations-‌ The Concessioning Authority shall: a) meet the Conditions Precedent for Concessioning Authority – P&D in timely manner or in extended time as may be agreed between the Parties. b) execute the Project Site (s) Lease Deed (s)/ Processing &Disposal Facilities Lease Deed; c) collect, transport and supply the Assured Quantity of MSW as per the Applicable Laws; Provided that in the event, the Concessioning Authority fails to transport and supply the Quarterly Minimum Assured Quantity of MSW (which will be calculated for a quarter comprising of three months) and this has not occurred as a result of breach of this Agreement by the Concessionaire or due to Force Majeure, the Concessioning Authority shall compensate to the Concessionaire for shortfall in Quarterly Minimum Assured Quantity of MSW. Such compensation would be as per the following clause. (i) In case of Positive Tipping Fee, the compensation for shortfall in Quarterly Minimum Assured Quantity of MSW will be equivalent to the Tipping Fee on a per ton basis. For an example, if the Quarterly Minimum Assured Quantity of MSW is 90 x30 x3 i.e. 8100 metric ton and there is shortfall of 20 metric ton, then the Concessioniare shall be compensated by an amount equal to Positive Tipping Fee x 20, i.e. if the Positive Tipping Fee is Rs. 250 per metric ton, then the compensation becomes Rs. 250 x 20, i.e. Rs. 5000 ( five thousand). (ii) In case of Zero Tipping Fee or Negative Tipping Fee, the Concessionaire shall be compensated at the rate of Rs. 300 (three hundred) for 1 MT ( one metric ton) of shortfall. Further, in case the Concessioning Authority fails to supply the Assured Quantity of MSW for more than 4 days in any month and this has not occurred due to any Public Holiday (declared holidays of Govt. of Punjab including Sundays), or breech of this Agreement by the Concessionaire or due to Force Majeure, then on 5th day onwards, the Concessionaire will be compensated at the rate of Rs. 100 (hundred) for 1 MT (One metric ton) of shortfall for the number of applicable no-supply days. (no supply days means the number of applicable days in which the Authority fails to supply the Assured Quantity of MSW as per the conditions of RFP) For an example, if the Assured Quantity of MSW is 112 TPD, then the Minimum Assured Qu...
Concessioning Authority’s Obligations. The Concessioning Authority shall, subject to the Concessioning Authority’s right to encash Performance Security towards carrying out works/jobs listed under Article 10.2 and 10.3, which have not been carried out by the Concessionaire, or any outstanding dues, which may have accrued in respect of the Project during the Concession Period, duly discharge and release to the Concessionaire any amounts / Performance Security due to the Concessionaire in accordance with the Agreement.
AutoNDA by SimpleDocs

Related to Concessioning Authority’s Obligations

  • Regulatory Approvals; No Defaults (a) No consents or approvals of, or waivers by, or filings or registrations with, any Governmental Authority or with any third party are required to be made or obtained by NBT or any of its Subsidiaries in connection with the execution, delivery or performance by NBT or NBT Bank of this Agreement or to consummate the transactions contemplated hereby, except for filings of applications, notices or waiver requests, and consents, approvals or waivers described in Section 4.08(b). As of the date hereof, NBT has no Knowledge of any reason why the approvals set forth above and referred to in Section 6.01(a) will not be received in a timely manner. (b) Subject to the receipt of all consents, approvals, waivers or non-objections of a Governmental Authority required to consummate the transactions contemplated by this Agreement, including, without limitation, (1) approvals, waivers or non-objections of each of the FRB and the OCC, as required (“Regulatory Approvals”), (2) the required filings under federal and state securities laws, (3) the declaration of effectiveness of the Merger Registration Statement by the SEC, and (4) approval of the listing of NBT Stock to be issued in connection with the Merger on NASDAQ, the execution, delivery and performance of this Agreement and the consummation of the transactions contemplated hereby (including, without limitation, the Merger) by NBT and NBT Bank do not and will not (i) constitute a breach or violation of, or a default under, result in a right of termination, or the acceleration of any right or obligation under, any law, rule or regulation or any judgment, decree, order, permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, franchise or other agreement of NBT or of any of its Subsidiaries or to which NBT or any of its Subsidiaries, properties or assets is subject or bound, (ii) constitute a breach or violation of, or a default under, the Restated Certificate of Incorporation, as amended, and Amended and Restated Bylaws of NBT or other organizational documents of NBT or NBT Bank, or (iii) require the consent or approval of any third party or Governmental Authority under any such law, rule, regulation, judgment, decree, order, permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, franchise or other agreement, except, in the case of clauses (i) and (iii), for such violations, conflicts, breaches or defaults which, either individually or in the aggregate, would not reasonably be expected to have a Material Adverse Effect on NBT or NBT Bank. (c) As of the date of this Agreement, NBT has no Knowledge of any reasons relating to NBT or NBT Bank (including, without limitation, compliance with the CRA or the USA PATRIOT Act) why any of the Regulatory Approvals shall not be received from the applicable Governmental Authorities having jurisdiction over the transactions contemplated by this Agreement.

  • Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System. 4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System. 4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA. 4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code. 4.1.5 The Power Producer shall commission the Project within SCOD. 4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer. 4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.

  • Contractor Licensing, etc. Notwithstanding Section 14.c, District may terminate this Contract immediately by written notice to Contractor upon denial, suspension, revocation, or non-renewal of any license, permit, or certificate that Contractor must hold to provide services under this Contract.

  • Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever. (ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties. (iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority. (iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i). (v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party. (vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway. (vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Design Development Documents See Section 2, Part 1, Article 2.1.5.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

  • Reporting Obligations and Regulatory Approvals Applicable laws and regulations may require holders and beneficial owners of Shares, including the Holders and Beneficial Owners of ADSs, to satisfy reporting requirements and obtain regulatory approvals in certain circumstances. Holders and Beneficial Owners of ADSs are solely responsible for determining and complying with such reporting requirements and obtaining such approvals. Each Holder and each Beneficial Owner hereby agrees to make such determination, file such reports, and obtain such approvals to the extent and in the form required by applicable laws and regulations as in effect from time to time. Neither the Depositary, the Custodian, the Company or any of their respective agents or affiliates shall be required to take any actions whatsoever on behalf of Holders or Beneficial Owners to determine or satisfy such reporting requirements or obtain such regulatory approvals under applicable laws and regulations.

  • Procurement Standards For projects being managed by the Local Government and on the State highway system or that include state funding, the Local Government must obtain approval from the State for its proposed procurement procedure for the selection of a professional services provider, a contractor for a construction or maintenance project, or a materials provider.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!