Damage and Destruction If all or any part of the Premises shall be damaged or destroyed by fire or other casualty, this Lease shall continue in full force and effect, unless terminated as hereinafter provided, and Landlord shall repair, restore or rebuild the Premises to the condition existing at the time of the occurrence of the loss; provided, however, Landlord shall not be obligated to commence such repair, restoration or rebuilding until insurance proceeds are received by Landlord, and Landlord’s obligation hereunder shall be limited to the proceeds actually received by Landlord under any insurance policy or policies, if any, less those amounts (i) which have been required to be applied towards the reduction of any indebtedness secured by a mortgage covering the Premises or any portion thereof, and (ii) which are used to reimburse Landlord for all costs and expenses, including but not limited to attorneys’ fees, incurred by Landlord to recover any such insurance proceeds. Tenant agrees to notify Landlord in writing not less than thirty (30) days prior, to the date Tenant opens for business in the Premises of the actual cost of all permanent leasehold improvements and betterments installed or to be installed by Tenant in the Premises (whether same have been paid for entirely or partially by Tenant), but exclusive of Tenant’s personal property, movable trade fixtures and inventory. Similar notifications shall be given to Landlord not less than thirty (30) days prior to the commencement of any proposed alterations, additions or improvements to the Premises. If Tenant fails to comply, with the foregoing provisions, any loss or damage Landlord shall sustain by reason thereof shall be borne by Tenant and shall be paid immediately by Tenant upon receipt of a xxxx therefore and evidence of such loss, and in addition to any other rights or remedies reserved by Landlord under this Lease, Landlord’s obligations under this Article to repair, replace and/or rebuild the Premises shall be deemed inapplicable, and in lieu thereof, Landlord may, at its election, either restore or require Tenant to restore the Premises to the condition which existed prior to such loss, and in either case Tenant shall pay the cost of such restoration. Tenant covenants and agrees to repair or replace Tenant’s fixtures, furniture, furnishings, floor coverings, equipment and stock in trade and reopen for business in the Premises within thirty (30) days after notice from Landlord that the Premises are ready for re-occupancy. No damage or destruction to the Premises shall allow Tenant to surrender possession of the Premises nor affect Tenant’s liability for the payment of rents or charges or any other covenant herein contained, except as may be specifically provided in this Lease. Notwithstanding anything to the contrary contained in this Section or elsewhere in this Lease, Landlord, at its option, may terminate this Lease by giving Tenant notice thereof within one hundred and eighty (180) days from the date of the casualty if:
(a) The Premises or the building in which the Premises are located shall be damaged or destroyed as a result of an occurrence which is not covered by Landlord’s insurance; or
(b) The Premises shall be damaged or destroyed during the last two (2) years of the Term or any renewals thereof; or
(c) The Premises are damaged or destroyed to the extent of twenty five-percent (25%) or more of the replacement cost thereof, in which event Landlord will have the option of terminating this Lease or any renewal thereof by serving written notice upon Tenant and any prepaid Rent or Additional Rent will be prorated as of the date of destruction and the unearned portion of such Rent will be refunded to Tenant without interest. If the Premises shall be damaged or destroyed and in the event that Landlord has elected to continue this Lease, Landlord and Tenant shall commence their respective obligations under this Article as soon as is reasonably possible and prosecute the same to completion with all due diligence. Except where the damage or destruction results from the wrongful or negligent act or omission of Tenant, the Minimum Rent shall be abated proportionately with the degree to which Tenant’s use of the Premises is impaired during the period of any damage, repair or restoration provided for in this Article; provided further, that in the event Landlord elects to repair any damages as herein contemplated, any abatement of Minimum Rent shall end ten (10) days after notice by Landlord to Tenant that the Premises have been repaired. Tenant shall continue the operation of its business on the Premises during any such period to the extent reasonably practicable from the standpoint of prudent business management, and any obligation of Tenant under the Lease to apply charges reserved as Additional Rent shall remain in full force and nothing in the Section shall be construed to xxxxx Additional Rent. Except for the abatement of Minimum Rent hereinabove provided, Tenant shall not be entitled to any compensation or damage for loss in the use of the whole or any part of the Premises and/or any inconvenience or annoyance occasioned by any damage, destruction, repair or restoration. If Minimum Rent is abated there shall be all corresponding and appropriate reduction made to the Minimum Annual Volume. Unless this Lease is terminated by Landlord, Tenant shall repair, restore and re-fixture all parts of the Premises not insured under any insurance policies insuring Landlord in a manner and to a condition equal to that existing prior to its destruction or damage, including, without limitation, all exterior signs, trade fixtures, equipment, display cases, furniture, furnishings and other installations of personality of Tenant. The proceeds of all insurance carried by Tenant on its property and improvements shall be held in trust by Tenant for the purpose of said repair and replacement. Tenant shall give to Landlord prompt written notice of, any damage to or destruction of any portion of the Premises resulting from fire or other casualty.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
DAMAGES, DESTRUCTION AND EMINENT DOMAIN (a) If, prior to closing, the Property or any part thereof be destroyed or further damaged by fire, the elements, or any cause, due to events occurring subsequent to the date of this Agreement to the extent that the cost of repair exceeds $10,000.00, this Agreement shall become null and void, at Buyer's option exercised, if at all, by written notice to Seller within ten (10) days after Buyer has received written notice from Seller of said destruction or damage. Seller, however, shall have the right to adjust or settle any insured loss until (i) all contingencies set forth in Paragraph 6 hereof have been satisfied, or waived; and (ii) any ten-day period provided for above in this Subparagraph 16a for Buyer to elect to terminate this Agreement has expired or Buyer has, by written notice to Seller, waived Buyer's right to terminate this Agreement. If Buyer elects to proceed and to consummate the purchase despite said damage or destruction, there shall be no reduction in or abatement of the purchase price, and Seller shall assign to Buyer the Seller's right, title, and interest in and to all insurance proceeds (pro-rata in relation to the Entire Property) resulting from said damage or destruction to the extent that the same are payable with respect to damage to the Property, subject to rights of any Tenant of the Entire Property. If the cost of repair is less than $10,000.00, Buyer shall be obligated to otherwise perform hereinunder with no adjustment to the Purchase Price, reduction or abatement, and Seller shall assign Seller's right, title and interest in and to all insurance proceeds pro-rata in relation to the Entire Property, subject to rights of any Tenant of the Entire Property.
(b) If, prior to closing, the Property, or any part thereof, is taken by eminent domain, this Agreement shall become null and void, at Buyer's option. If Buyer elects to proceed and to consummate the purchase despite said taking, there shall be no reduction in, or abatement of, the purchase price, and Seller shall assign to Buyer the Seller's right, title, and interest in and to any award made, or to be made, in the condemnation proceeding pro-rata in relation to the Entire Property, subject to rights of any Tenant of the Entire Property. In the event that this Agreement is terminated by Buyer as provided above in Subparagraph 16a or 16b, the First Payment shall be immediately returned to Buyer (after execution by Buyer of such documents reasonably requested by Seller to evidence the termination hereof).
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral.
(b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies.
(c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in
(i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Condemnation/Eminent Domain In the event that the Premises or any part thereof, or the whole or any part of the Building, shall be taken or appropriated by eminent domain or shall be condemned for any public or quasi-public use, or (by virtue of any such taking, appropriation or condemnation) shall suffer any damage (direct, indirect or consequential) for which Landlord or Tenant shall be entitled to compensation, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Landlord by a notice in writing of its election so to terminate which shall be given by Landlord to Tenant within sixty (60) days following the date on which Landlord shall have received notice of such taking, appropriation or condemnation. In the event that a material part of the Premises or the means of access thereto shall be so taken, appropriated or condemned, and in either case, the remainder of the Premises or the mode of access thereto is, in Tenant’s reasonable judgment, unsuitable for the operation of Tenant’s business in the Premises, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Tenant by a notice in writing of its election so to terminate which shall be given by Tenant to Landlord within sixty (60) days following the date on which Tenant shall have received notice of such taking, appropriation or condemnation. Upon the giving of any such notice of termination (either by Landlord or Tenant) this Lease and the Term hereof shall terminate on or retroactively as of the date on which Tenant shall be required to vacate any part of the Premises or shall be deprived of a substantial part of the means of access thereto, provided, however, that Landlord may in Landlord’s notice elect to terminate this Lease and the Term hereof retroactively as of the date on which such taking, appropriation or condemnation became legally effective. In the event of any such termination, this Lease and the Term hereof shall expire as of such effective termination date as though that were the Expiration Date as stated in Exhibit 1, and the Yearly Rent (together with Operating Costs Excess and Tax Excess) shall be apportioned as of such date. If neither party (having the right so to do) elects to terminate Landlord will, with reasonable diligence and at Landlord’s expense, restore the remainder of the Premises, or the remainder of the means of access, as nearly as practicably may be to the same condition as obtained prior to such taking, appropriation or condemnation in which event (i) the Total Rentable Area shall be equitably adjusted, (ii) a just proportion of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resulting permanent injury to the Premises and the means of access thereto, shall be permanently abated, and (iii) a just proportion of the remainder of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resultant injury sustained by the Premises and the means of access thereto, shall be abated until what remains of the Premises and the means of access thereto shall have been restored as fully as may be for permanent use and occupation by Tenant hereunder. Except for any award specifically reimbursing Tenant for moving or relocation expenses or for Tenant’s personal property, or for the unamortized value of any leasehold improvements paid for by Tenant (in excess of any Landlord contribution), there are expressly reserved to Landlord all rights to compensation and damages created, accrued or accruing by reason of any such taking, appropriation or condemnation, in implementation and in confirmation of which Tenant does hereby acknowledge that Landlord shall be entitled to receive all such compensation and damages, grant to Landlord all and whatever rights (if any) Tenant may have to such compensation and damages, and agree to execute and deliver all and whatever further instruments of assignment as Landlord may from time to time reasonably request. In the event of any taking of the Premises or any part thereof for temporary (i.e., not in excess of one (1) year) use, (i) this Lease shall be and remain unaffected thereby, and (ii) Tenant shall be entitled to receive for itself any award made to the extent allocable to the Premises in respect of such taking on account of such use, provided, that if any taking is for a period extending beyond the Term of this Lease, such award shall be apportioned between Landlord and Tenant as of the Expiration Date or earlier termination of this Lease.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
EMINENT DOMAIN/CONDEMNATION 7.1 Lessor to notify Lessee 7.2 Whole taking, rents prorated 7.3 Taking
CASUALTY LOSS AND CONDEMNATION (a) If after the date of execution of this Agreement and prior to the Closing any part of the Assets suffers a Casualty Loss or if any part of the Assets is taken in condemnation or under the right of eminent domain or if proceedings for such purposes are pending or Threatened, Seller shall promptly give Buyer written notice of such occurrence, including reasonable particulars with respect thereto, and this Agreement shall remain in full force and effect notwithstanding any such destruction, taking, proceeding, or threat, subject to Sections 11.08 and 11.14.
(b) With regard to a Casualty Loss or condemnation occurring after the date of execution of this Agreement, without Buyer’s prior consent, no insurance or condemnation proceeds shall be committed or applied by Seller to repair, restore, or replace a lost, damaged, destroyed or taken portion of the Assets if the cost to repair, restore, or replace a lost, damaged, destroyed or taken portion of the Assets is projected to exceed $50,000. To the extent such proceeds are not committed or applied by Seller prior to the Closing Date in accordance with this Section 11.16(b), Seller shall at the Closing pay to Buyer all sums paid to Seller by reason of such loss, damage, destruction or taking, less any reasonable costs and expenses incurred by Seller in collecting such proceeds. In addition and to the extent such proceeds have not been committed or applied by Seller in accordance with this Section 11.16(b), in such repair, restoration, or replacement, Seller shall transfer to Buyer, at Closing, without recourse against Seller, all of the right, title, and interest of Seller in and to any unpaid insurance or condemnation proceeds arising out of such loss, damage, destruction or taking, less any reasonable costs and expenses incurred by Seller in collecting such proceeds. Any such funds which have been committed by Seller for repair, restoration, or replacement as aforesaid shall be paid by Seller for such purposes or, at Seller’s option, delivered to Buyer upon Seller’s receipt from Buyer of adequate assurance and indemnity that Seller shall incur no liability or expense as a result of such commitment.
(c) If and to the extent any portion of the loss attributable to a Casualty Loss occurring after the date of execution of this Agreement and before Closing is not covered by insurance (such uncovered portion of the Casualty Loss being referred to in this Section as an "uninsured loss"), Buyer and Seller shall attempt to agree on the value of the uninsured Casualty Loss on or before the date five (5) days after Buyer receives written notice of the Casualty Loss. If the parties are not able to agree on such value within such 5-day period, the value shall be determined by an independent casualty adjuster, experienced in determining casualty losses in matters similar to the disputed Casualty Loss, who shall be selected by Seller from a list of three (3) such independent casualty adjusters that is provided to Seller by Buyer. Said independent casualty adjuster shall be selected by Seller within five (5) days of the written receipt by Seller of Buyer’s written listing of independent casualty adjusters and shall provide both Seller and Buyer with a complete and documented report as to his findings within ten (10) Business Days after being selected by Seller. For purposes of this Section, the value of the uninsured Casualty Loss shall be equal to the lesser of (i) the aggregate reduction in Allocated Value of the affected Assets resulting from the uninsured Casualty Loss, if such affected Assets are not repaired, or (ii) the amount required to repair the affected portion of the Assets to its condition immediately preceding the occurrence of the Casualty Loss plus any other Damages which may be suffered on account of such Casualty Loss. The Purchase Price shall be reduced by the amount of the value of such an uninsured Casualty Loss as finally determined pursuant to this Section, and if such final determination is not available on the scheduled Closing Date, Closing shall not be delayed, but rather, the amount paid at Closing shall be reduced by the value of the uninsured Casualty Loss estimated in good faith by Buyer, and the difference between such good faith estimate and the value finally determined pursuant hereto shall be included as part of the final adjustments to be made after Closing as contemplated by Section 2.05.
