CONDONATION OF DELAY Sample Clauses

CONDONATION OF DELAY. The Company may condone delay in claim intimation/ document submission on merit, where it is proved that delay in reporting of claim or submission of claim documents, is due to reasons beyond the control of the Insured. Notwithstanding the above, delay in claim intimation or submission of claim documents due to reasons beyond the control of the Insured shall not be condoned where such claims would have otherwise been rejected even if reported in time. SUPPLIMENTARY CLAUSES & CONDITIONS APPLICABLE TO PROPERTY DAMAGE- (Optional Covers unless opted) DEBRIS REMOVAL This Policy includes, within the Sum Insured, expenses incurred in the removal from the insured location of debris of insured property directly destroyed or damaged by an Insured Event. The cost of removal of debris shall not be considered in determination of the valuation of the property insured.
Sample 1
AutoNDA by SimpleDocs
CONDONATION OF DELAY. The Company may condone delay in claim intimation/ document submission on merit, where it is proved that delay in reporting of claim or submission of claim documents, is due to reasons beyond the control of the insured. Notwithstanding the above, delay in claim intimation or submission of claim documents due to reasons beyond the control of the insured shall not be condoned where such claims would have otherwise been rejected even if reported in time.
Sample 1

Related to CONDONATION OF DELAY

  • Notification of Delay The Design Professional shall immediately notify the City in writing if Design Professional experiences or anticipates experiencing a delay in performing the Professional Services within the time frames set forth in the Task Order. The written notice shall include an explanation of the cause for, and a reasonable estimate of the length of, the delay. If in the opinion of the City, the delay affects a material part of the Task, the City may exercise its rights under Sections 2.5-2.7 of this Agreement.

  • Termination of Development Grant Agreement The obligations of the Recipient under the Development Grant Agreement shall terminate on the date 20 years after the date of the Development Grant Agreement.”

  • Completion of Development Upon the completion of the whole development or complete phases of the development, Council may review this Agreement, in whole or in part, and may:

  • Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.

  • NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.

  • Termination of Deduction The University Administration’s responsibility for deducting dues and other authorized deductions from a faculty member’s salary shall terminate automatically upon either

  • Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.

  • PUBLICATION OF DEED The Department will publish an abridged version of this Deed on the WA Health internet site, in accordance with Schedule D9 of the National Health Reform Agreement. Any subsequent amendments to this Deed together with the Service Agreement will also be published in accordance with Schedule D9 of the National Health Reform Agreement.

  • Notification of Deduction The Union shall inform the Employer in writing of the authorized deduction to be checked off for Employees mentioned in Article 11.01.

  • Cyber incident damage assessment activities If DoD elects to conduct a damage assessment, the Contracting Officer will request that the Contractor provide all of the damage assessment information gathered in accordance with paragraph (e) of this clause.

Time is Money Join Law Insider Premium to draft better contracts faster.