Contractor's Representative (CR Sample Clauses

Contractor's Representative (CR. A. Upon award, the Contractor shall furnish to the Contracting Officer the name of the person he has designated and assigned exclusively to this contract as his agent or representative. The Contractor's Representative shall exercise overall management responsibility for the contract effort, receive technical direction, and handle problems arising under the contract, such as, dismissals, disciplinary matters, etc. The CR is further responsible for coordinating matters of mutual concern with the BEP representatives. In the event questions of responsibility arise, they shall be resolved by the Contracting Officer or his authorized representative. B. The CR may not be diverted to other projects for 14 consecutive days or more without giving prior written notification to the Contracting Officer or his representative. Such notification shall include a justification for the diversion, together with information on the proposed substitute in sufficient detail to permit analysis of any potential negative effects on Contract performance. No substitution shall be made without the written consent of the Contracting Officer; provided, however, that the Contracting Officer may grant such consent retroactively. Any such substitution of a permanent nature will be made a part of this contract through the issuance of a modification. C. When the CR is temporarily unavailable to manage the contract effort for a period longer than 72 hours, including absences due to vacation or illness, the Contractor shall provide to the COR written designation of an alternate representative, itemizing any limitations in the alternate's authority. The procedures of paragraph (A) above do not apply to such temporary designations unless they are expected to exceed the time period indicated in that paragraph.
Sample 1

Related to Contractor's Representative (CR

  • Contractor’s Representative Contractor hereby designates [***INSERT NAME OR TITLE***], or his or her designee, to act as its representative for the performance of this Agreement (“Contractor’s Representative”). Contractor’s Representative shall have full authority to represent and act on behalf of the Contractor for all purposes under this Agreement. The Contractor’s Representative shall supervise and direct the Services, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

  • Owner’s Representatives 9.1.1 Owner designates the individual listed below as its Senior Representative (“Owner Senior Representative”), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2 of the General Conditions: 9.1.2 Owner designates the individual listed below as its Owner’s Representative, which individual has the authority and responsibility set forth in Section 3.3 of the General Conditions:

  • City’s Representative The City hereby designates Xxx Xxxxx, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. Consultant shall not accept direction or orders from any person other than the City’s Representative or his or her designee.

  • Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxxx Xxxxxxxxx Executive Director 00000 Xxxxxxxxx Xxxx Xxxxxxx, XX 00000 Phone: 000-000-0000 Email: xxxxxxxxxxxx@xxxxx.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx Xxxxxxx, XX 00000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx The Contractor shall contact only the designated Contract Administrator with any Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.

  • Buyers’ representatives After this Agreement has been signed by the Parties and the Deposit has been lodged, the Buyers have the right to place two (2) representatives on board the Vessel at their sole risk and expense. These representatives are on board for the purpose of familiarisation and in the capacity of observers only, and they shall not interfere in any respect with the operation of the Vessel. The Buyers and the Buyers’ representatives shall sign the Sellers’ P&I Club’s standard letter of indemnity prior to their embarkation.

  • Sellers’ Representative By execution of this Agreement, the Sellers hereby irrevocably and unconditionally appoint Nephron Pharmaceuticals Corporation as the Sellers’ Representative of all Sellers, as the attorney-in-fact for and on behalf of each such Seller, and irrevocably agree that the taking by the Sellers’ Representative of any and all actions and the making of any decisions required or permitted to be taken by it or by a Seller under this Agreement or any Transaction Documents to which the Sellers are a party are hereby authorized and approved in all respects, including without limitation the exercise of the power to (i) receive from Buyer and disburse to Sellers any payments constituting any part of the Purchase Price and receive and disburse from and to any Party or any Third Party which may be contemplated to be made under the Transaction Documents, (ii) agree to, negotiate, enter into settlements and compromises of and comply with orders of courts with respect to any indemnification claims or disputes, (iii) resolve any indemnification claims or disputes, and (iv) take all actions necessary in the judgment of the Sellers’ Representative for the accomplishment of the other terms, conditions and limitations of this Agreement and the Transaction Documents. The Sellers’ Representative has authority and power to act on behalf of the Sellers with respect to this Agreement and the other Transaction Documents and the disposition, settlement or other handling of all indemnification claims, rights or obligations arising from and taken pursuant to this Agreement and the other Transaction Documents. The Sellers irrevocably agree to be bound by all and any such actions taken by the Sellers’ Representative in connection with this Agreement and the other Transaction Documents to which the Sellers are a party, and Sellers and Buyer shall only be required to acknowledge or act upon written communication signed by the Sellers’ Representative. Each Seller agrees that he, she or it has not, and will not, threaten or commence or join any legal action, which term includes, without limitation, any demand for arbitration proceedings and any complaint to any foreign, federal, state or local agency, court or other tribunal, to assert any claim against the Sellers’ Representative or its advisors for acting in such capacity with respect to this Agreement or the other Transaction Documents. If any Seller commences or joins any such prohibited legal action against the Sellers’ Representative, such Seller agrees to promptly indemnify Sellers’ Representative and advisers of Sellers’ Representative for all losses, liabilities, reasonable costs or expenses, including without limitation all reasonable fees, disbursements and other charges of attorneys incurred by Sellers’ Representative and/or its advisers in defending such action as well as any monetary judgment obtained against the Sellers’ Representative in such action. The Sellers’ Representative may resign at any time upon 30 days written notice to the Sellers.

  • Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.

  • Parties’ Representatives Both Parties shall ensure that throughout the term of this Agreement, a duly appointed Representative is available for communications between the Parties. The Representatives shall have full authority to deal with all day-to-day matters arising under this Agreement. If a Party’s Representative becomes unavailable, the Party shall promptly appoint another Representative. Acts and omissions of Representatives shall be deemed to be acts and omissions of the Party. Owner and CAISO shall be entitled to assume that the Representative of the other Party is at all times acting within the limits of the authority given by the Representative’s Party. Owner’s Representatives and CAISO’s Representatives shall be identified on Schedule J.

  • Nurse Representatives The Employer agrees to recognize two (2) Nurse Representatives for the purpose of dealing with grievances and conducting Union interviews.

  • Contractor Representative The Contractor shall appoint a Contractor Representative fluent in English, who shall: