CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. If the work shall be stopped by order of the Court or any public authority, Federal or State agency, for a period of three (3) months through no act or fault of the Contractor or any of his agents, servants, employees, materialmen, or subcontractors, the Contractor may, upon ten (10) days notice to the TOWN DISTRICT, discontinue his performance of the work and/or terminate the Contract. Upon termination by the Contractor the TOWN DISTRICT may take possession of the work and complete the work by Contract or otherwise, as the TOWN DISTRICT solely may deem expedient. If the Contract is terminated by the Contractor, the liability of the TOWN DISTRICT to the Contractor shall be for all work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment, including reasonable profit and damages.
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. .1 If the work should be stopped under an order of any court, or other public authority, through no act or fault of the Contractor or of anyone employed by him, then the Contractor may, upon three (3) days' written notice to the Metropolitan Regional Housing Authority and the Project Manager, stop work or terminate this contract and recover from the Metropolitan Regional Housing Authority payment for all work executed and any loss sustained upon any plant or material with reasonable profit and damages.
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. If CITY ENGINEER received CONTRACTOR’s proper invoice and/or bill and/or request for payment and/or application for payment, and should CITY ENGINEER fail to review and approve or state in writing reasons for not approving, or for rejecting, of the Application for Payment within twenty-five
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. If CITY ENGINEER received CONTRACTOR’s proper invoice and/or bill and/or request for payment and/or application for payment, and should CITY ENGINEER fail to review and approve or state in writing reasons for not approving, or for rejecting, of the Application for Payment within twenty-five (25) business days after it is presented, then CONTRACTOR shall provide CITY with written notice of same, and if CITY fails either to pay CONTRACTOR within four (4) business days after CITY receives CONTRACTOR’s notice, CITY shall notify CONTRACTOR in writing of any objection to the Application for Payment, then CONTRACTOR shall, give a second written notice to CITY of such delay, neglect or default, specifying the same and if CITY, within a period of ten (10) calendar days after such second notice shall not remedy the delay, neglect, or default upon which the notice is based, then CONTRACTOR may stop work or terminate this Contract and recover from CITY payment for all work executed and reasonable expenses sustained therein plus reasonable termination expenses. In such event, the contract shall be deemed terminated for convenience, and CONTRACTOR shall be paid for all work executed and expenses incurred prior to termination in addition to termination settlement costs reasonably incurred by CONTRACTOR relating to commitments, which had become firm prior to the termination. Payment shall include reasonable profit for work/services performed. No payment shall be made for profit for work or services that have not been performed or for consequential damages.
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. If Owner fails to pay to Contractor within seven (7) days of its maturity and presentation, any sum certified by Owner, then Contractor may, upon seven (7) days’ simultaneous written notice to Owner, stop work or terminate this Contract. If Contractor elects to stop work by written notice, work shall be resumed promptly upon payment by Owner. If Contractor elects to terminate this Contract, by written notice, he or she shall recover from Owner payment for all work executed to date of notice.
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. If the PROJECT MANAGER received CONTRACTOR’s proper invoice and/or bill and/or request for payment and/or application for payment, and should the PROJECT MANAGER fail to review and approve or state in writing reasons for not approving, or for rejecting, of the Application for Payment within twenty-five (25) business days after it is presented, then CONTRACTOR shall provide CITY with written notice of same, and if CITY fails either to pay CONTRACTOR within four
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. 26.1 If PROJECT MANAGER fails to review and approve or state in writing reasons for rejection of any Application for Payment within twenty (20) days after it is properly presented, or if CITY fails either to pay CONTRACTOR within thirty (30) days after presentation by PROJECT MANAGER of any sum certified by PROJECT MANAGER, or to notify CONTRACTOR in writing of any objection to the Application for Payment, then CONTRACTOR may give written notice to CITY of such delay, neglect or default, specifying the same. If CITY (where applicable), within a period of ten (10) calendar days after such notice shall not remedy the delay, neglect, or default upon which the notice is based, then CONTRACTOR may stop work or terminate this Contract and recover from CITY payment for all work executed and reasonable expenses sustained therein plus reasonable termination expenses. Any objection made by CITY to an Application for Payment shall be submitted to CONSULTANT in accordance with the provisions of Article 27 hereof.
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. If the work shall be stopped under an order of any court or other public authority for a period of ninety (90) consecutive days through no act or fault of the Contractor or any one employed by him, then the Contractor may on seven consecutive days' written notice to the Owner and the owner's authorized representative stop work or terminate this Contract and recover from the owner payment for all work executed, any losses sustained on any plant or material, and a reasonable profit. If the owner's authorized representative shall fail to issue any certificate for payment within ten (10) days after it is due, or if the owner shall fail to pay the Contractor within fifteen (15) days after its maturity and presentation any sum certified by the Owner's authorized representative, then the Contractor may on seven days' prior written notice to the Owner and the Owner's authorized representative stop work and give written notice of intention to terminate this Contract. If the owner shall thereafter fail to pay the Contractor within seven days after receipt of such notice, then the Contractor may terminate the Contract and recover from the Owner payment for all work executed any losses sustained upon any plant or materials and a reasonable profit.
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. 26.1 If Owner fails to issue any certificate for payment within fifteen (15) days after it is due, or if Owner fails to pay to Contractor within thirty (30) days of its maturity and presentation, any sum certified by Owner, then Contractor may, upon seven
CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT. 53.1 If the Owner should be adjudged bankrupt or insolvent, or makes a general assignment for the benefit of credi- tors, or if a receiver is appointed on account of insolvency, the Contractor may, without prejudice to any other right or remedy, by giving the Owner written notice, terminate the Contract.
