COORDINATION WITH OTHER CONTRACTS Sample Clauses

COORDINATION WITH OTHER CONTRACTS a. The District reserves the right to do other work or award other contracts in connection with this Project. By entering into this Contract, Contractor acknowledges that there may be other contractors on or adjacent to the Project site whose work must be coordinated with that of its own. Contractor expressly warrants and agrees that it will cooperate with other contractors and will do nothing to delay, hinder, or interfere with the work of other contractors, or that of the District, its Architect and Project Manager. Contractor also expressly agrees that in the event its work is hindered, delayed, interfered with, or otherwise affected by a separate contractor, its sole remedy will be a direct action against the separate contractor. To the extent allowed by law, the Contractor expressly waives any remedy against the District, its Architect and Project Manager on account of delay, hindrance, interference or other such events caused by a separate contractor. b. If any part of Contractor's work depends upon the work of a separate contractor, Contractor shall inspect such other work and promptly report in writing to the District and Project Manager any defects in such other work that render it unsuitable to receive the work of Contractor. Failure of the Contractor to so inspect and report shall constitute an acceptance of the other contractor's work, except as to defects which the Contractor could not have detected through the reasonable inspection of the other contractor's work prior to the execution of Contractor's work. c. If Contractor is aware of a current or potential conflict between Contractor’s work and the work of another contractor on the site, and is unable to informally resolve the conflict directly with the other contractor, Contractor shall promptly provide written notice to the District, with a copy to the Project Manager and the other contractor, specifying the nature of the conflict, the date upon which the conflict arose, and the steps taken to attempt to resolve the conflict. The District may issue written instructions to address the conflict. d. If, through Contractor’s negligence, any other contractor or subcontractor shall suffer loss or damage to the work, Contractor shall make a reasonable effort to settle with such other contractor and subcontractor by agreement or arbitration. If such other contractor or subcontractor shall assert any claim against the District or Project Manager, on account of any damage alleged to have been so sus...
Sample 1Sample 2Sample 3See All (25)
AutoNDA by SimpleDocs
COORDINATION WITH OTHER CONTRACTS. The Authority and third parties such as Utility Owners, railroads, cities, counties and other Governmental Persons may award contracts for work at or near the Site. The Contractor shall fully cooperate with the other contractors and with employees of the Authority, and shall carefully adapt scheduling and performing the Work under this Contract to accommodate the said other contract work, heeding any direction that may be provided by the Authority. The Contractor shall not commit or permit any act that will interfere with the performance of work by any other contractor. If the Contractor asserts that any of the Authority’s other contractors have interfered with the Work, then the Contractor’s sole remedy shall be to seek recourse against such other contractors.
Sample 1

Related to COORDINATION WITH OTHER CONTRACTS

  • Compliance with Other Agreements Employee represents and warrants that the execution of this Agreement by him and his performance of his obligations hereunder will not conflict with, result in the breach of any provision of or the termination of or constitute a default under any agreement to which Employee is a party or by which Employee is or may be bound.

  • No Other Contracts Other than this Agreement, there are no contracts, agreements or understandings between the Company or any of its Subsidiaries and any person that would give rise to a valid claim against the Company or any of its Subsidiaries or the Placement Agent for a brokerage commission, finder’s fee or other like payment with respect to the consummation of the transactions contemplated by this Agreement.

  • Conflicts with Other Agreements In the event of any conflict or inconsistency between the terms of this Agreement and any employment, severance or other agreement between the Company and the Participant, the terms of this Agreement shall govern.

  • No Conflict With Other Instruments The execution of this Agreement and the consummation of the transactions contemplated by this Agreement will not result in the breach of any term or provision of, constitute a default under, or terminate, accelerate or modify the terms of, any indenture, mortgage, deed of trust, or other material agreement or instrument to which the Company is a party or to which any of its assets, properties or operations are subject.

  • Compliance with Contracts The District will comply with, keep, observe and perform all agreements, conditions, covenants and terms, expressed or implied, required to be performed by it contained in all contracts for the use of the Enterprise and all other contracts affecting or involving the Enterprise to the extent that the District is a party thereto.

  • Other Contracts The Board of Supervisors may undertake or award other contracts for additional Work, and the Contractor shall fully cooperate with such other contractors and County employees and carefully fit his own Work to such additional Work as may be directed by OC Public Works. The Contractor shall not commit or permit any act, which will interfere with the performance of Work by any other contractor or by County employees.

  • Waivers; Other Agreements No term or provision of this Agreement may be waived or modified unless such waiver or modification is in writing and signed by the party against whom such waiver or modification is sought to be enforced.

  • Compliance with Other Instruments The execution, delivery and performance by the Purchaser of this Agreement and the consummation by the Purchaser of the transactions contemplated by this Agreement will not result in any violation or default (i) of any provisions of its organizational documents, (ii) of any instrument, judgment, order, writ or decree to which it is a party or by which it is bound, (iii) under any note, indenture or mortgage to which it is a party or by which it is bound, (iv) under any lease, agreement, contract or purchase order to which it is a party or by which it is bound or (v) of any provision of federal or state statute, rule or regulation applicable to the Purchaser, in each case (other than clause (i)), which would have a material adverse effect on the Purchaser or its ability to consummate the transactions contemplated by this Agreement.

  • Other Contractors District reserves the right to enter into other agreements for work additional or related to the subject matter of this Contract, and Contractor agrees to cooperate fully with these other contractors and with the District. When requested by District, Contractor shall coordinate its performance under this Contract with such additional or related work. Contractor shall not interfere with the work performance of any other contractor or District employees.

  • Authorization; Other Agreements The Secured Parties are hereby authorized, without notice to or demand upon any Guarantor and without discharging or otherwise affecting the obligations of any Guarantor hereunder and without incurring any liability hereunder, from time to time, to do each of the following: (a) (i) modify, amend, supplement or otherwise change, (ii) accelerate or otherwise change the time of payment or (iii) waive or otherwise consent to noncompliance with, any Guaranteed Obligation or any Loan Document; (b) apply to the Guaranteed Obligations any sums by whomever paid or however realized to any Guaranteed Obligation in such order as provided in the Loan Documents; (c) refund at any time any payment received by any Secured Party in respect of any Guaranteed Obligation; (d) (i) Sell, exchange, enforce, waive, substitute, liquidate, terminate, release, abandon, fail to perfect, subordinate, accept, substitute, surrender, exchange, affect, impair or otherwise alter or release any Collateral for any Guaranteed Obligation or any other guaranty therefor in any manner, (ii) receive, take and hold additional Collateral to secure any Guaranteed Obligation, (iii) add, release or substitute any one or more other Guarantors, makers or endorsers of any Guaranteed Obligation or any part thereof and (iv) otherwise deal in any manner with the Borrower and any other Guarantor, maker or endorser of any Guaranteed Obligation or any part thereof; and (e) settle, release, compromise, collect or otherwise liquidate the Guaranteed Obligations.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!