Critical Illness Three (3) days per year, with pay, shall be granted in the case of a critical illness or accident to a member of the employee's immediate family as defined in Section 9.4.2. A statement by the physician verifying the need for the employee to be present with the immediate family member shall be attached to the absence form.
Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.
Substantial Completion Section 7.4.1 When Supplier believes that it has achieved the requirements of Substantial Completion, Supplier shall provide written notice (the “Notice of Substantial Completion”) to System Owner stating that Supplier has achieved Substantial Completion, together with copies of all documents (as identified in the definition of Substantial Completion) that are required to be delivered to System Owner to meet Substantial Completion that have not been previously delivered.
Section 7.4.2 Upon receipt of the Notice of Substantial Completion, System Owner shall promptly proceed to obtain Independent Engineer’s review and approval of the Notice of Substantial Completion and the Commissioning Report within a reasonable time, but in no event more than ten (10) Business Days following receipt of the Notice of Substantial Completion and all accompanying documents or such longer period of time as specified in the Construction Schedule (the “Substantial Completion Review Period”).
Section 7.4.3 Supplier shall provide System Owner with reasonable notice of the date and time of the inspection or review of the System by a representative of the applicable Governmental Authority or Host Utility, if required, for purposes of achieving Substantial Completion, and System Owner shall have the right to have one or more representatives and the Independent Engineer present during such inspection or review. If the representative of the applicable Governmental Authority or Host Utility notifies Supplier or System Owner that the requirements for achieving Substantial Completion have not been achieved, then Supplier shall promptly take such action as necessary to achieve such requirements and, to the extent applicable, schedule another inspection or review of the System. Such procedure shall be repeated until such inspection or review has been satisfactorily completed and approved.
Section 7.4.4 If System Owner and the Independent Engineer approve the Notice of Substantial Completion, System Owner shall, within the Substantial Completion Review Period, (a) notify Supplier of its approval and (b) issue written notice to Supplier to complete the Work (the “Notice to Complete”).
Section 7.4.5 If System Owner or the Independent Engineer has a reasonable basis not to approve the Notice of Substantial Completion because the requirements for Substantial Completion have not been met, System Owner shall, within the Substantial Completion Review Period, notify Supplier of its non-approval and include a detailed explanation for the basis thereof. Supplier shall promptly undertake such action or work as necessary to achieve such requirements and shall then issue another Notice of Substantial Completion to System Owner stating that Supplier believes that such requirements have been achieved. Such procedure shall be repeated until Substantial Completion is achieved. If Supplier disputes the reasons stated in System Owner’s notification, then such dispute shall be resolved in accordance with Article XIX.
Cultural Competence 1. Grantee will make reasonable efforts to provide services that meet each client’s individual needs and takes into consideration the intellectual functioning, literacy, level of education and comprehension ability of each client in order to ensure that all information is presented in a way that meets each client’s individual needs.
2. Grantee will provide services in the client's primary language either directly by Grantee or by a DFPS approved translator.
3. Grantee will have a cultural competence mission statement, core values or other similar guidance that provides how the Grantee will effectively provide these services to clients of various cultures, races, ethnic backgrounds and religions in a manner that recognizes and affirms the client’s worth, protects and preserves the client’s dignity and ensures equity of service delivery.
Critical Illness Leave (i) An Employee who has completed at least ninety (90) days of employment, and is a family member of a critically ill child or a critically ill qualified adult relative, is entitled to leave of absence without pay or benefits: • for a period of up to thirty-six (36) weeks to care for their critically ill child; or, • for a period of up to sixteen (16) weeks to care for a critically ill qualified adult relative.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be:
§ 3.2 The Contract Time shall be measured from the date of commencement of the Work.
Teaching Experience Recognized Years of Experience: Uncredited Experience:
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
