County’s Right to Withhold Payment Sample Clauses

County’s Right to Withhold Payment. Where Contractor or any subcontractor it employs to perform work under this Agreement has been found in violation of any applicable wage and hour law by a final judgment, decision, or order of a court or government agency, the County reserves the right to withhold payment to Contractor until such judgment, decision, or order has been satisfied in full.
Sample 1Sample 2Sample 3See All (20)
AutoNDA by SimpleDocs
County’s Right to Withhold Payment. Notwithstanding any other provision of this Agreement, and in addition to any rights of County given by law or provided in this Agreement, County may upon written notice to Contractor withhold payment for any deliverable while Contractor, with no fault of County, is in default hereunder or default related to Work.
Sample 1Sample 2Sample 3See All (6)
County’s Right to Withhold Payment. Notwithstanding any other provision of this Contract, and in addition to any rights of the County given by law or provided in this Contract, the County may upon written notice to Contractor withhold payment for any deliverable while Contractor, with no fault of the County, is in default hereunder or default related to Work.
Sample 1Sample 2Sample 3See All (6)
County’s Right to Withhold Payment. When it reasonably believes (i) that Substantial Completion will be inexcusably delayed; or (ii) that the Construction Manager will fail to achieve Final Completion by the date of Final Completion, the County may withhold from any amounts otherwise due the Construction Manager the daily amount specified for liquidated damages in this Article for each calendar day of the unexcused delay.
Sample 1Sample 2Sample 3
County’s Right to Withhold Payment. Where City or any contractor or subcontractor City employs to perform work under this Agreement has been found in violation of any applicable wage and hour law by a final judgment, decision, or order of a court or government agency, the County reserves the right to withhold payment to City until such judgment, decision, or order has been satisfied in full. (6)
Sample 1
County’s Right to Withhold Payment. Notwithstanding any other provision of this Agreement, and in addition to any rights of COUNTY given by law or provided in this Agreement, COUNTY may upon written notice to CONTRACTOR withhold payment for any Deliverable while CONTRACTOR is in default hereunder, or at any time that CONTRACTOR has not provided a COUNTY-approved Deliverable which under the approved Project Control Document pursuant to Deliverable 1 (Project Control Document) of Exhibit A (Statement of Work - Remittance Processing & Image Archive) or Exhibit A.1 (Statement of Work - Optima 3 IMS), as applicable, is identified as dependent on, and is scheduled to be delivered prior to or concurrently with, the Deliverable for which payment would otherwise be due and is withheld.
Sample 1
County’s Right to Withhold Payment. Where Developer or any Contractor has been found in violation of any applicable wage and hour law by a final judgment, decision, or order of a court or government agency, the County reserves the right to withhold payment to Developer until such judgment, decision, or order has been satisfied in full.
Sample 1
AutoNDA by SimpleDocs

Related to County’s Right to Withhold Payment

  • RIGHT TO WITHHOLD PAYMENT LEA may withhold payment to CONTRACTOR when: (a) CONTRACTOR has failed to perform, in whole or in part, under the terms of this contract; (b) CONTRACTOR has billed for services rendered on days other than billable days of attendance or for days when student was not in attendance and/or did not receive services; (c) CONTRACTOR was overpaid by XXX as determined by inspection, review, and/or audit of its program, work, and/or records; (d) CONTRACTOR has failed to provide supporting documentation with an invoice, as required by EC 56366(c)(2); (e) education and/or related services are provided to students by personnel who are not appropriately credentialed, licensed, or otherwise qualified; (f) LEA has not received prior to school closure or contract termination, all documents concerning one or more students enrolled in CONTRACTOR’s educational program; (g) CONTRACTOR fails to confirm a student’s change of residence to another district or confirms the change or residence to another district, but fails to notify LEA within five (5) days of such confirmation; or (h) CONTRACTOR receives payment from Medi-Cal or from any other agency or funding source for a service provided to a student. It is understood that no payments shall be made for any invoices that are not received by six (6) months following the close of the prior fiscal year, for services provided in that year. Final payment to CONTRACTOR in connection with the cessation of operations and/or termination of a Master Contract will be subject to the same documentation standards described for all payment claims for regular ongoing operations. In addition, final payment may be withheld by the LEA until completion of a review or audit, if deemed necessary by the LEA. Such review or audit will be completed within ninety (90) days. The final payment may be adjusted to offset any previous payments to the CONTRACTOR determined to have been paid in error or in anticipation of correction of documentation deficiencies by the CONTRACTOR that remain uncorrected.

  • Right to withdraw Sale to withdraw, postpone and call off the sale of the Property at any time prior to the auction date and before the fall of the hammer; and

Time is Money Join Law Insider Premium to draft better contracts faster.